SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Franchisors Should Consider Signing a Conditional Lease Assignment Rather Than a Franchisee’s Lease

November 17, 2016 — Richard H. Herold – Real Estate Litigation Blog
In Franchise & High Properties, LLC v. Happy’s Franchise, LLC, a 2015 decision issued by the Court of Appeals in Michigan, the franchisor, Happy’s Pizza Franchise, LLC, signed a five-year lease for the commercial space to be occupied by its franchisee, Happy’s Pizza #19, Inc. The franchisor did so to secure a right of first refusal to purchase the property and to enforce the franchise agreement to have the lease assigned to the franchisor if the franchisee defaulted. The issue in the case was whether the term “tenant” referred solely to Happy’s Pizza #19 or whether it also included Happy’s Franchise as a co-tenant. “Tenant” was defined as follows: “Happy’s Pizza #19, Inc., 29102 Telegraph Road, Suite 607, Southfield, MI 48034, the lessee, and Happy’s Pizza Franchise, LLC, a Michigan limited liability company (hereinafter referred to as `Franchisor’), hereinafter designated as the Tenant.” Read the court decision
Read the full story...
Reprinted courtesy of Richard H. Herold, Real Estate Litigation Blog
Mr. Herold may be contacted at rherold@swlaw.com

---

Don’t Believe Everything You Hear: Liability of Asbestos Pipe Manufacturer Upheld Despite Exculpatory Testimony of Plaintiff

May 24, 2021 — Garret Murai - California Construction Law Blog
In the next case, Morgan v. J-M Manufacturing Company, Inc. 60 Cal.App.5th 1078 (2021), the 2nd District Court of Appeal upheld a $7 million personal injury verdict against an asbestos-cement pipe manufacturer despite exculpatory testimony from the plaintiff, holding that the testimony was an issue of witness credibility rather than sufficiency of the evidence, and holding that the trial court’s denial of a jury instruction requested by the pipe manufacturer was appropriate because, while the requested jury instruction was a recitation of undisputed facts, the purpose of jury instructions is to recite the law rather than facts, even undisputed ones. The Morgan Case Norris Morgan was exposed to asbestos at construction sites where he worked in the 1970s and 80s. After he was diagnosed with mesothelioma in December 2017, Morgan and his wife sued a number of defendants, including J-M Manufacturing for personal injuries and loss of consortium. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Court Says KBR Construction Costs in Iraq were Unreasonable

August 27, 2014 — Beverley BevenFlorez-CDJ STAFF
Mike Bosse of Bernstein Shur, analyzed a case involving Kellogg Brown and Root Services Inc. (KBR) and the U.S. Army for services that KBR provided during Operation Iraqi Freedom, according to JDSupra Business Advisor: “The court case involved KBR’s construction of dining facility services near Mosul, Iraq under a cost-plus fee arrangement. Under this contractual arrangement, all allowable costs were reimbursed by the government plus the contractor was paid an additional fee.” KBR first started on a prefabricated metal dining hall that would serve 2,500 people, but part way into building they were told to stop construction and to instead start on a new reinforced concrete building that would serve almost three times as many people. “After construction was finished, a defense contract auditing agency suspended some of the payments to KBR and instead of the $12.5 million it expected to receive, KBR was paid only $6.7 million,” reported JDSupra Business Advisor. “After trial, the court concluded KBR did not meet its burden to show the costs it incurred were reasonable under the circumstances.” Read the court decision
Read the full story...
Reprinted courtesy of

---

More Hensel Phelps Ripples in the Statute of Limitations Pond?

February 03, 2020 — Christopher G. Hill - Construction Law Musings
As is always the case when I attend the Virginia State Bar’s annual construction law seminar, I come away from it with a few posts on recent cases and their implications. The first of these is not a construction case, but has implications relating to the state project related statute of limitations and indemnification issues for construction contracts brought out in stark relief in the now infamous Hensel Phelps case. In Radiance Capital Receivables Fourteen, LLC v. Foster the Court considered a waiver of the statute of limitations found in a loan contract. The operative facts are that the waiver was found in a Continuing Guaranty contract and that the default happened more than 5 years prior to the date that Radiance filed suit to enforce its rights. When the defendants filed a plea in bar stating that the statute of limitations had run and therefore the claim was barred, Radiance of course argued that the defendants had waived their right to bring such a defense. The defendants responded that the waiver was invalid in that it violated the terms of Va. Code 8.01-232 that states among other things:

an unwritten promise not to plead the statute shall be void, and a written promise not to plead such statute shall be valid when (i) it is made to avoid or defer litigation pending settlement of any case, (ii) it is not made contemporaneously with any other contract, and (iii) it is made for an additional term not longer than the applicable limitations period.

The Circuit Court and ultimately the Supreme Court agreed with the defendants. In doing so, the Virginia Supreme Court rejected arguments of estoppel and an argument that a “waiver” is not a “promise not to plead.” Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Lump Sum Subcontract? Perhaps Not.

August 20, 2019 — David Adelstein - Florida Construction Legal Updates
Lump sum subcontract? Perhaps not due to a recent ruling where the trial court said “No!” based on the language in the subcontract and contract documents generally incorporated into the subcontract. This is a ruling on an interpretation of a subcontract and contract documents incorporated into the subcontract that I do not agree with and struggle to fully comprehend. The issue was whether the subcontract amount was a lump sum or subject to an audit, adjustment, and definitization based on actual costs incurred. Of course, the subcontractor (or any person in any business) is not just interested in recouping actual costs, but there needs to be a margin to cover profit and home office overhead that does not get factored into field general conditions. In United States v. Travelers Casualty and Surety Company, 2018 WL 6571234 (M.D.Fla. 2018), a prime contractor was hired to perform work on a federal project. During the work, the Government issued the prime contractor a Modification that had a not-to-exceed value and required the prime contractor to track its costs for this Modification separate from other contract costs. In other words, based on this Modification, the prime contractor was paid its costs up to a maximum amount and the prime contractor would separately cost-code and track the costs for this work differently than other work it was performing under the prime contract. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

2017 California Construction Law Update

December 15, 2016 — Garret Murai – California Construction Law Blog
To say it’s been an exciting year in politics would be an understatement. While most of the nation’s attention was focused on the presidential election, state legislatures, including California’s, were busy at work. The California State Legislature introduced 3099 bills during the second session of the 2015-2016 session of which 808 bills were signed into law. 2016 saw the enactment of several bills of interest to the construction industry including bills related to alternative project delivery methods, prevailing wages, and licensing. Each of the bills discussed below takes effect on January 1, 2017. Project Delivery AB 2126 – Amends Public Contract Code section 6701 to increase the number of projects the Department of Transportation may use the construction manager/general contractor method of project delivery from no more than 6 projects, to 12 projects, of which 8 of the 12 projects would be required to use Department employees or consultants under contract with the Department to perform all project design and engineering services. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Ohio Supreme Court Case to Decide Whether or Not to Expand Insurance Coverage Under GC’s CGL Insurance Policies

August 14, 2018 — David Suggs – Bert L. Howe & Associates, Inc.
According to W. Matthew Bryant of Saul Ewing Arnstein & Lehr LLP, the Ohio Supreme Court will be deciding whether or not a general contractor's commercial general liability ("CGL") insurance policy may provide coverage for damage caused by a subcontractor's defective construction work. Bryant explained the status quo in Ohio: “Since 2012, Ohio has followed the rule that a CGL policy would not cover damage caused by a contractor to the contractor's own work.” That could change depending on how the Ohio Supreme Court rules in an upcoming case: “The Ohio Supreme Court will decide whether to affirm or overturn Ohio Northern University v. Charles Construction Services, Inc., 77 N.E.3d 538 (Ohio Ct. App. 2017) ("ONU"), an Ohio Court of Appeals decision holding that CGL coverage may exist for property damage caused by faulty work performed by the subcontractor of an insured general contractor.” Read the court decision
Read the full story...
Reprinted courtesy of

---