The Little Ice Age and Delay Claims
January 24, 2018 —
Wally Zimolong - Supplemental ConditionsMuch of the Eastern United States is just now emerging from a historic two week cold snap. In much of the Northeast and Mid-Atlantic, the temperature stayed below freezing for 15 days straight. Cities recorded the lowest temperatures in a quarter century. Winter Storm Grayson reeked havoc along the Eastern Coast bringing snow to places like Charleston and a crippling blizzard to Boston.
The record cold snap also impacted the construction industry. Delivery delays, the inability to apply weather sensitive applications (like cast in place concrete), and the unavailability of labor are just a few things that extreme weather can cause on a construction project. If they happen at the wrong time, delays can destroy project schedules and make previous delays even worse. Delays cost money and can mean the difference between a profitable project from both the owner and contractors perspective.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
Maryland Court Affirms Condo Association’s Right to Sue for Construction Defects
November 27, 2013 —
CDJ STAFFThe Maryland Court of Appeals, that state’s highest court, recently reaffirmed that condominium association have broad discretion in suing for construction defects in when they are representing at least two unit owners. Nicholas D. Cowie of the Baltimore-based construction defect legal firm Cowie & Mott, gives his summary of the case on his firm’s web site.
Mr. Cowie notes that the Council of Unit Owners of Bentley Place Condominium sued the developer and builder for construction defects in both common areas and within units, representing itself and “two or more” unit owners. A jury awarded $6.6 million; the builder and developer appealed.
The court ruled on the appeal that the Council of Unit Owners had a right to pursue these claims, and could recover full damage to common elements, even if some owners are time-barred due to their date of purchase. Mr. Cowie represented the Council of Unit Owners during the lawsuit.
Read the court decisionRead the full story...Reprinted courtesy of
Legal Battle Kicks Off to Minimize Baltimore Bridge Liabilities
May 06, 2024 —
Brendan Murray - BloombergThe owner of the ship that destroyed Baltimore’s Francis Scott Key Bridge, causing the indefinite closure of the port a week ago, is seeking to limit its liability to about $44 million.
According to reporting by my Bloomberg News colleagues citing legal experts, the company — Grace Ocean — could face hundreds of millions of dollars in damage claims.
On Monday it filed a petition jointly with Synergy Marine, which was operating the Singapore-flagged container ship Dali. They claim the collapse of the bridge was “not due to any fault, neglect, or want of care” of the companies and that they shouldn’t be held liable for any loss or damage from the disaster.
Read the court decisionRead the full story...Reprinted courtesy of
Brendan Murray, Bloomberg
Although Property Damage Arises From An Occurrence, Coverage Barred By Business Risk Exclusions
July 08, 2011 —
Tred R. Eyerly - Insurance Law HawaiiThe homeowners hired the insured to raise the structure of their home twenty-four inches above the flood zone. Lafayette Ins. Co. v. Peerboom, 2011 U.S. Dist. LEXIS 58985 (S.D. Miss. June 2, 2011). When the insured’s crew returned from lunch one day, they found the house had fallen from hydraulic jacks being used to raise the structure a few inches at a time. There was substantial damage to the entire structure.
The homeowners sued, asserting several claims, including negligence and breach of contract. The complaint alleged the homeowners entered a contract with the insured to raise their structure while maintaining its integrity. However, the insured failed to use proper equipment, which caused the house to fall and be completely destroyed.
The insured tendered the claim to its insurer, Lafayette Insurance Company. Lafayette defended under a reservation of rights and filed suit for a declaratory judgment. Lafayette’s subsequent motion for summary judgment contended there was no “occurrence” alleged in the underlying complaint and, even if there was, the business risk exclusions barred coverage.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
Arbitration—No Opportunity for Appeal
October 22, 2014 —
Craig Martin – Construction Contractor AdvisorLast week I presented to the Great Plains Chapter of the American Society of Professional Estimators on arbitration and litigation. Some of the questions related to the difficulty of appealing an arbitrator’s decision. A Florida appellate court recently confirmed this difficulty.
In Village at Dolphin Commerce Center, LLC v. Construction Service Solutions, LLC, a contractor filed an arbitration claim against the owner to get paid for its work. The owner claimed that the contractor could not maintain the claim to get paid because the contractor was not licensed. Apparently, there is a law in Florida that a contractor unlicensed at the time of the contract cannot maintain an action in Florida for unpaid work.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
Construction Manager’s Win in Michigan after Michigan Supreme Court Finds a Subcontractor’s Unintended Faulty Work is an ‘Occurrence’ Under CGL
August 03, 2020 —
Gabrielle Szlachta-McGinn - Newmeyer DillionOn June 29, 2020, the Michigan Supreme Court overturned a longstanding precedent that commercial general liability (“CGL”) insurers have historically relied upon to deny insurance coverage for claims involving pre-1986 CGL policies. See Hawkeye-Security Ins. Co. v. Vector Const. Co., 185 Mich. App. 369, 372, 460 N.W.2d 329, 331 (1990). In its recent ruling, the state Supreme Court unanimously agreed that an Insurance Services Office, Inc. (“ISO”) 1986 standard CGL policy, which is sold to construction contractors across the United States, provides coverage for property damage to a policyholder’s work product that resulted from a subcontractor’s unintended faulty workmanship. Skanska USA Bldg. Inc. v. M.A.P. Mech. Contractors, Inc., No. 159510, 2020 WL 3527909 (Mich. June 29, 2020).
In 2008, Skanska USA Building, Inc., the construction manager on a renovation project for Mid-Michigan Medical Center, signed a subcontract with defendant M.A.P. Mechanical Contractors (“MAP”) to install a new heating and cooling (“HVAC”) system. Id. During the renovation, MAP installed some of the expansion joints in the new HVAC system backwards. Id. The defective installation caused approximately $1.4 million in property damage to concrete, steel and the heating system, which Skanska discovered nearly two years after MAP completed the project. Id. After performing the repairs and replacing the damaged property, Skanska sought repayment for the repair costs from MAP and also submitted a claim to Amerisure seeking coverage as an insured under the CGL policy. Id. When Amerisure rejected Skanska’s claim, Skanska sued both parties. Id. Amerisure relied on the holding in Hawkeye and argued that MAP’s defective workmanship was not a covered “occurrence” under the CGL policy, which the policy defined as an accident. Id. at *4.
The Michigan Court of Appeals ignored the express language contained in the CGL policy and applied a prior appellate court precedent from Hawkeye, finding that MAP’s faulty work was not an “occurrence” and thus, did not trigger CGL coverage. Id. at *4. The Court of Appeals further reasoned that Skanska was an Amerisure policyholder and that the only property damage was to Skanska’s own work, which was not covered under the CGL policy. Id. at *5.
In a landmark decision, the Michigan Supreme Court reversed, holding unanimously that the Court of Appeals incorrectly applied the holding of Hawkeye because it failed to consider the impact of the 1986 revisions to standard CGL insurance policies. Id. at *10. Chief Justice Bridget M. McCormack explained that the Hawkeye decision rested on the 1973 version of the ISO form insurance policy, which specifically excluded certain business risks from coverage such as property damage to a policyholder’s own work. Id. The Supreme Court agreed that while Hawkeye was correctly decided, it did not apply here because the 1986 revised ISO policy includes an exception for property damage caused by a subcontractor’s unintentional faulty work. Id.
The Supreme Court said that under the plain reading of the current CGL policy language, an “accident” could include a subcontractor’s unintentional defective work that damaged a policyholder’s work product and thus, may qualify as an “occurrence” covered under the policy. Id. at *9. The Supreme Court defined an “accident” (which was not defined in the Amerisure policy) as “an undefined contingency, a casualty, a happening by chance, something out of the usual course of things, unusual, fortuitous, not anticipated, and not naturally to be expected.” Id. at *5; see Allstate Ins. Co. v. McCarn, 466 Mich. 277, 281, 645 N.W.2d 20, 23 (2002). The Supreme Court noted that there was no evidence suggesting that MAP purposefully installed the expansion joints backwards, nor was there evidence indicating that the parties affected by MAP’s negligence anticipated, foresaw, or expected MAP’s defective installation or property damage. Skanska, 2020 WL 3527909, at *4. Therefore, the Supreme Court concluded that an “occurrence” may have happened, which would trigger coverage under the CGL policy. Id. at *10.
Although this landmark decision changes Michigan law, the decision is limited to cases involving the 1986 ISO policy language revisions to CGL insurance policies. Id. The Supreme Court's decision does not overturn Hawkeye, but rather limits Hawkeye’s authority to cases involving the 1973 ISO form. Id.
Gabrielle Szlachta-McGinn was a summer associate at Newmeyer Dillion as part of the firm's 2020 summer class. You may learn more about Newmeyer Dillion's construction litigation services and find the group's key contacts at https://www.newmeyerdillion.com/construction-litigation/.
Read the court decisionRead the full story...Reprinted courtesy of
Best Lawyers® Recognizes 49 White and Williams Attorneys
September 16, 2024 —
White and Williams LLPThirty-eight White and Williams lawyers were recognized in Best Lawyers in America® 2025. Inclusion in Best Lawyers® is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers® employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services.
In addition, eleven lawyers were recognized as Best Lawyers: Ones to Watch® in America. This recognition is given to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States.
The firm is also pleased to announce Best Lawyers® has recognized three attorneys as "Lawyer of the Year” including: Chuck Eppolito, Litigation - Health Care, Philadelphia, who focuses his practice on medical malpractice defense as well as other insurance-related defense; William D. Kennedy, Litigation – Insurance, Philadelphia, who focuses his practice on complex claims of injury and damage arising in both the professional and general liability contexts; and, Michael O. Kassak, Litigation – Insurance, Cherry Hill, who focuses his practice on large complex commercial matters including insurance coverage and healthcare disputes.
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams LLP
7 Sustainability Ideas for Modular Classrooms in the Education Industry (guest post)
June 10, 2015 —
Melissa Dewey Brumback – Construction Law in North CarolinaToday, a guest post on sustainable modular classrooms from Kathy Werder, a freelance architect by profession and a researcher by nature. According to Kathy, most of her research papers focus on promoting integration that leads to sustainable and lean design and construction practices. Kathy is obsessed with the latest rage in the construction industry – modular building solutions. She is also an avid writer, and loves blogging about green buildings and portable construction units. Welcome, Kathy!
According to Wikipedia, a sustainable building refers to “ a structure and using process that is environmentally responsible and resource-efficient throughout a building’s life-cycle from sitting, to design, construction, operation, maintenance, renovation, and demolition.”
So if we accept this definition to be true, in order to make an actual sustainable building we have to consider the entire process of building right from the blueprint stage all the way to demolition, and ensure that at every step of the way there is minimal or no negative impact on the environment, especially in terms of resource efficiency.
Read the court decisionRead the full story...Reprinted courtesy of
Melissa Dewey Brumback, Construction Law in North CarolinaMs. Brumback may be contacted at
mbrumback@rl-law.com
