Fairfield Connecticut Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Giant Floating Solar Flowers Offer Hope for Coal-Addicted Korea

March 21, 2022 — Heesu Lee - Bloomberg
More than 92,000 solar panels in the shape of plum blossoms, floating on the surface of a reservoir in South Korea, offer a vision of how land-scarce developed nations can overcome local resistance to giant renewable-energy projects. The 17 giant flowers on the 12-mile-long reservoir in the southern county of Hapcheon are able to generate 41 megawatts, enough to power 20,000 homes, according to Hanwha Solutions Corp., which built the plant. It’s one of the biggest floating solar plants in the world, and it’s in a nation that has been a laggard in adopting renewable energy, even though South Korea’s industrialized economy relies heavily on imported fossil fuels. Read the court decision
Read the full story...
Reprinted courtesy of Heesu Lee, Bloomberg

25 Days After Explosion, Another Utility Shuts Off Gas in Boston Area

October 30, 2018 — Johanna Knapschaefer - Engineering News-Record
Three hundred thirty-nine homes in Woburn, Mass., were without power on Oct. 8 after National Grid shut off gas meters following the inadvertent over-pressurization of the natural gas line on Oct. 8, according to the Woburn Fire Dept. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Protect Workers From Falls: A Leading Cause of Death

August 14, 2018 — Mark McGhiey - Construction Executive
One of the leading causes of death for construction workers is falls from elevated surfaces, according to the Bureau of Labor Statistics. In 2016, these accidents accounted for more than 30 percent of all construction fatalities. The top four causes of worker deaths (excluding highway collisions) in the private sector construction industry are:

falls: 384 (38.7%);
struck by object: 93 (9.4 percent);
electrocutions: 82 (8.3 percent); and
caught-in/between:1 72 (7.3 percent).

One of the most common — and costly — causes of claims occur when construction workers fall from elevated surfaces. These accidents represent more than 30 percent of all construction claim payments. Reprinted courtesy of Mark McGhiey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Understanding the Miller Act

February 26, 2015 — Beverley BevenFlorez-CDJ STAFF
John P. Ahlers of Ahlers & Cressman PLLC, explained who is covered by the Miller Act in regards to Federal public works projects on the firm’s blog. Ahlers stated that “[t]he Miller Act requires that all general contractors post payment bonds on contracts in excess of $25,000.00.” In his blog post, Ahlers goes over coverage and the distinction between subcontractor and supplier. Ahlers commented, “While, at first glance, it may seem fairly simple to sort out who is and who is not covered by the Miller Act payment bond, the analysis can at times be factually and legally complex. This is an area that, if faced, the contractor should seek legal advice of an experienced construction lawyer before jumping to conclusions.” Read the court decision
Read the full story...
Reprinted courtesy of

Blog Completes Fifteenth Year

December 13, 2022 — Tred R. Eyerly - Insurance Law Hawaii
Insurance Law Hawaii completes its fifteenth year of existence this month. We began posting in December 2007, 1656 posts ago. We strive to keep readers abreast of new developments in insurance-related cases from Hawaii and across the country. Coverage issues in the past year have again been dominated by COVID-19, business interruption, construction defect, and cyber claims. This trend will likely continue over the next year and we will do our best to track developments. Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert Mr. Eyerly may be contacted at te@hawaiilawyer.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Sometimes You Get Away with Unwritten Contracts. . .

July 28, 2018 — Christopher G. Hill - Construction Law Musings
I have spoken often regarding the need for a well written construction contract that sets out the “terms of engagement” for your construction project. A written construction contract sets expectations and allows the parties to the contract to determine the “law” of their project. An unwritten “gentleman’s agreement” can lead to confusion, faulty memories, and more money paid to construction counsel than you would like as we lawyers play around in the grey areas. One other area where the written versus unwritten distinction makes a difference is in the calculation of the statute of limitations. In Virginia, a 5 year statute of limitations applies to written contracts while a 3 year statute of limitations applies to unwritten contracts. This distinction came into stark relief in the case of M&C Hauling & Constr. Inc. v. Wilbur Hale in the Fairfax, Virginia Circuit Court. In M&C Hauling, M&C provided hauling services to the defendant through a subcontract with Hauling Unlimited in 2014, the last of which was in July. M&C provided over 2000 hours of hauling and provided time tickets (that were passed to Mr. Hale on Hauling Unlimited letterhead and signed by Mr. Hale or his agent) and an invoice stating the price term of $75.00 per hour. No separate written contract between M&C and Hauling Unlimited or Mr. Hale existed. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES