Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion
April 15, 2024 —
Stu Richeson - The Dispute ResolverThis post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded.
Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009).
Read the court decisionRead the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
Fraud and Construction Contracts- Like Oil and Water?
December 31, 2014 —
Christopher G. Hill – Construction Law MusingsWe have discussed the interaction of fraud and breach of contract actions on occasion here at Construction Law Musings. In most cases the two do not mix. Between the economic loss rule and the general desire of Virginia courts to keep contract actions and tort actions separate, most of the time it is impossible to make a fraud action relating to a contract stick in a construction context.
The Virginia Supreme Court recently confirmed this fraud/contract distinction. As discussed in the Virginia Real Estate Land Use & Construction Law blog (Thanks Heidi!), Station No. 2, LLC v. Lynch, et. al. strongly re-states the Virginia courts’ strong reluctance to allow a breach of contract turn into a claim for fraud. Without re-iterating the great discussion of the facts of the case found in the post by Heidi Meizner, suffice it to say that certain contractual promises between and among the parties were not fulfilled much to Station 2, LLC’s detriment.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Quick Note: Attorney’s Fees and the Significant Issues Test
November 03, 2016 —
David Adelstein – Florida Construction Legal UpdatesAttorney’s fees become a component of damages that parties seek to recover whenever there is a contractual or statutory basis for them to recover their fees. Parties want to be able to recover all or substantially most of the attorney’s fees they incurred in pursuing their claim. (In my experience, recovering all of the fees incurred is very challenging.) But, to be entitled to attorney’s fees, a party has to be deemed the
prevailing party. There is the sentiment that as long as you recover a positive net judgment (even if it is for $100 when your claim was for $50,000) then you will be able to recover your attorney’s fees which will likely exceed the amount that was ever in dispute.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.Mr. Adelstein may be contacted at
dma@katzbarron.com
Angelo Mozilo Speaks: No Regrets at Countrywide
September 03, 2014 —
Max Abelson – BloombergSix years after he lost control of the largest mortgage lender in the U.S., and days after news that the U.S. Attorney’s Office in Los Angeles plans to sue him, the Countrywide Financial Corp. founder is baffled by a new effort to punish him, proud of past triumphs and incensed by criticism.
“You’ll have to ask those people, ‘What do you have against Mozilo, what did he do?’” he said in a 30-minute call with Bloomberg News before Labor Day, one of his few interviews since the firm’s downfall. “Countrywide didn’t change. I didn’t change. The world changed.”
Interviews with Mozilo, 75, and three friends show what retirement looks like for a chief executive officer linked to the worst financial crisis since the Great Depression. Remaining out of public view like Lehman Brothers Holdings Inc.’s Richard Fuld or Jimmy Cayne of Bear Stearns Cos., Mozilo has submitted plans for Old West-style offices in California, taught students in Italy about finance, invested in a building in the Arizona desert that houses a Taco Bell and written about his life so that his grandchildren will “know the truth.”
Read the court decisionRead the full story...Reprinted courtesy of
Max Abelson, BloombergMr. Abelson may be contacted at
mabelson@bloomberg.net
2017 Legislative Changes Affecting the Construction Industry
November 21, 2017 —
Melinda S. Gentile – Peckar & Abramson, P.C.Originally published by CDJ on July 13, 2017
The 2017 Florida Legislative Session recently concluded, and a number of important construction-related House Bills (HB) and Senate Bills (SB) were presented during the Session, most notably SB 204/HB 377. These Bills may impact General Contractors and Construction Managers in a number of ways, not the least of which is the period of time that a cause of action may be initiated for the design, planning or construction of an improvement.
The following construction-related Bills passed in both the House and Senate and will become law if approved by the Governor.
Senate Bill (SB) 204/House Bill (HB) 377: Relating to the Statute of Repose for causes of action based on design, planning or construction of an improvement to real property. This bill passed both the House and the Senate and was approved by the Governor on June 14, 2017. This bill becomes effective on July 1, 2017.
Read the court decisionRead the full story...Reprinted courtesy of
Melinda S. Gentile, Peckar & Abramson, P.C.Ms. Gentile may be contacted at
mgentile@pecklaw.com
Checking the Status of your Contractor License During Contract Work is a Necessity: The Expanded “Substantial Compliance” under B&P 7031 is Here
June 05, 2017 —
Ivo G. Daniele – Newmeyer & Dillion LLP News AlertIt is paramount that a contractor diligently maintains its license prior to and during the performance of any contract work. Failure to do so could result in barring a contractor from receiving payment and/or disgorgement of profits received under the construction contract.
California Business and Professions Code section 7031 is part of the Contractors State License Law (Business & Prof. section 700 et seq.), and is both feared and loathed by all contractors performing work in the state of California. This draconian statute is known as the “Shield” and was enacted over 70 years ago for the singular purpose to bar all actions by contractors seeking compensation for unlicensed contract work – even precluding a contractor from enforcing his or her mechanic’s lien rights. However, a contractor could potentially avoid the harshness of B&P 7031 by establishing that he or she had substantially complied with the appropriate licensing requirements.
SUBSTANTIAL COMPLIANCE WITH LICENSE REQUIREMENTS PRIOR TO 2017 AMENDMENT
The substantial compliance exception is found in section B&P 7031(e), which authorizes the court to determine that there has been substantial compliance with licensure requirements, if the contractor has shown at an evidentiary hearing that he or she engaged in the unlicensed work had:
- Been duly licensed as a contractor in this state prior to the performance of the act or contract;
- Acted reasonably and in good faith to maintain the license;
- Did not know or reasonably should not have known that he or she was not licensed when he or she performed the work; and
- Acted promptly and in good faith to reinstate the license once it learned the license had lapsed.
Although not impossible, satisfying all four requirements of the exception was challenging for the contractor, specifically, requirement # (3) – the lack of knowledge that he or she was unlicensed during performance of work.
SUBSTANTIAL COMPLIANCE POST 2017
Fortunately, Governor Brown heard the collective cry for relief and signed Assembly Bill 1793 (“AB 1793”) into law. The new bill revises the criteria for the court to determine if a contractor is in substantial compliance with the licensing requirements by deleting requirement # (3) in its entirety and modestly amending requirement # (4) to require the contractor to act promptly and in good faith to remedy the failure to comply with the licensure requirements upon learning of the failure.
As a result, the substantial compliance exception under B&P 7031(e) reads as follows:
(e) The judicial doctrine of substantial compliance shall not apply under this section where the person who engaged in the business or acted in the capacity of a contractor has never been a duly licensed contractor in this state. However, notwithstanding subdivision (b) of Section 143, the court may determine that there has been substantial compliance with licensure requirements under this section if it is shown at an evidentiary hearing that the person who engaged in the business or acted in the capacity of a contractor
(1) had been duly licensed as a contractor in this state prior to the performance of the act or contract, (2) acted reasonably and in good faith to maintain proper licensure, and (3) acted promptly and in good faith to remedy the failure to comply with the licensure requirements upon learning of the failure.
This new legislation has tempered the burden of proof born by the contractor in establishing substantial compliance, although be it minor in its modification, the fact of the matter remains the same – be diligent in maintaining your license during all phases of contract work.
Ivo Daniele is a seasoned associate in the Walnut Creek office focusing his practice on commercial transactions and business and construction litigation. For questions regarding California Business and Professions Code section 7031, please feel free to contact Ivo Daniele at (925) 988-3222 or ivo.daniele@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Missouri Asbestos Litigation Reform: New Bill Seeks to Establish Robust Disclosure Obligations
March 15, 2021 —
Jennifer B. Pigeon - Lewis BrisboisMissouri State Senator Eric Burlison is reviving attempts to reform asbestos litigation in the State of Missouri through the introduction of SB 331. This bill was pre-filed on December 29, 2020 and first read on January 6, 2021. The bill establishes disclosure procedures for claimants in asbestos-related lawsuits. Specifically, the bill, if passed, would require claimants in civil asbestos-related lawsuits to file a sworn information form within 30 days of filing an asbestos-related lawsuit.
The required disclosures under SB 331 include, but are not limited to (1) each asbestos-containing product to which the exposed person was exposed and each physical location at which the exposure occurred; (2) the identity of the manufacturer or distributor of specific asbestos-containing products for each named exposure; (3) the specific location and manner of each exposure; (4) the beginning and end dates of each exposure, the frequency and length of each exposure, and the proximity of the asbestos-containing product or its use to the exposed person; and (5) a certification that any claim that can be made with a bankruptcy trust concerning any asbestos injury to the exposed person has been filed.
Read the court decisionRead the full story...Reprinted courtesy of
Jennifer B. Pigeon, Lewis BrisboisMs. Pigeon may be contacted at
Jenna.Pigeon@lewisbrisbois.com
Real Estate & Construction News Roundup (8/21/24) – REITs Show Their Strength, Energy Prices Increase Construction Costs and CRE Struggles to Keep Pace
October 01, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, UBS to liquidate $2 billion real estate fund, hotel workers in San Francisco vote to strike, housing market to change after blockbuster settlement, and more!
- When it comes to buying and selling homes, new rules are about to be put in play, five months after the National Association of Realtors agreed to a settlement over how its 1.5 million agents across the U.S. are paid commissions. (Kate Gibson, CBS)
- Project abandonments tumbled in July in one of the largest monthly declines ever due to the anticipated interest rate cut. (Sebastian Obando, Construction Dive)
- Increases in energy prices drove most of the total rise in construction input costs over the past month. (Sebastian Obando, Construction Dive)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
