Fairfield Connecticut Building Expert Directory

Challenging Enforceability of Liquidated Damages (In Federal Construction Context)

March 11, 2024 — David Adelstein - Florida Construction Legal Updates
A recent summary judgment opinion from the Armed Services Board of Contract Appeals (ASBCA), Appeals Of – BCI Construction USA, Inc.,ASBCA No. 6257, 2024 WL 773324 (2024), contains a worthy discussion regarding a contractor’s challenge to the government’s assessment of liquidated damages, specifically the enforceability of the liquidated damages rate. Although this challenge is in the federal context, this discussion would be more expansive and apply outside of the federal context. When dealing with the enforceability of a liquidated damages, the ASBCA “examines whether the liquidated damages amount ‘is extravagant, or disproportionate to the amount of property loss, as to show that compensation was not the object aimed at or as to imply fraud, mistake, circumvention or oppression.” Appeals of – BCI Construction USA, Inc. (citation omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer Must Indemnify Additional Insured After Settlement

October 21, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that Target was an additional insured under its supplier's policy and the insurer had a duty to indemnify Target after it settled the underlying suit. Selective Ins. Co. v. Target Corp., 2015 U.S. Dist. LEXIS 123230 (E.D. Ill. Sept. 15, 2015). Angela Brown sued Target when she was allegedly injured by a door to a fitting room that came unhinged and fell on her head. Harbor Industries, Inc. supplied Target with its fitting rooms. Pursuant to the "Supplier Qualification Agreement" (SQA), Harbor named Target as an additional insured under its policy with Selective Insurance Company. The SQA became effective and was to remain in effect until terminated by either party. A second agreement, the "Program Agreement," set forth the terms under which Harbor sold the fitting rooms to Target. The Program Agreement went into effect on April 23, 2009, and expired on July 1, 2010. Brown's injury occurred on December 17, 2011, while the SQA and the policy were in effect, but after the Program Agreement expired. After Brown's injury, Target tendered to Selective, who denied coverage, contending Target was not an additional insured. The policy's endorsement expanded insureds to any additional insured whom Harbor agreed in a written contract to add as an additional insured. Selective filed suit and the parties filed cross-motions for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Unlocking the Potential of AI and Chat GBT in Construction Management

September 11, 2023 — Matthew DeVries - Best Practices Construction Law
The construction industry is one of the most complex and challenging sectors. Projects can be highly demanding and require a significant amount of planning and coordination to complete successfully. However, with advancements in technology, specifically the use of artificial intelligence (AI) and chat GBT, the construction industry can experience a transformation in how it operates. One of the significant challenges in construction projects is the management of data. Information is collected from various sources and needs to be organized and analyzed to make informed decisions. AI can play a significant role in data analysis by providing real-time insights into the project’s progress. This can help in predicting potential delays, identifying areas where cost savings can be made, and even improve safety measures. Chat GBT, a natural language processing tool, can assist in project management by acting as a virtual assistant to construction managers. The software can be programmed to answer questions about the project, provide updates on the progress, and even suggest solutions to potential problems. This can help in reducing the workload of the project manager and allow them to focus on other critical tasks. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Burr & Forman LLP
Mr. DeVries may be contacted at mdevries@burr.com

A Word to the Wise: The AIA Revised Contract Documents Could Lead to New and Unanticipated Risks - Part II

October 16, 2018 — George Talarico - Construction Executive
Part I addressed general conditions, revised insurance terms, revisions that affect owner’s required insurance and revisions that affect contractor’s required insurance. REVISIONS THAT AFFECT DISPUTE RESOLUTION A seemingly minor but noteworthy change is to the definition of “Claim.” Under Section 15.1 a “Claim” is defined to:

include a request for a modification of contract time; and
exclude any requirement that an owner must file a claim to impose liquidated damages.

Notably, any request relating to contract time must be brought within the specified time period for Notice of Claim and in the prescribed manner. There are at least two traps for the unwary. First, even though email is regularly used for communications among the parties, the revised contract documents do not recognize email as an acceptable form of delivery of a Notice of Claim. Second, an unwary contractor may wrongly assume that an owner’s failure to assert a claim for LDs means that LDs will not be imposed. This may lull the contractor into failing to timely assert its own claim for a time extension and thereby waiving its ability to do so. Reprinted courtesy of George Talarico, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Talarico may be contacted at gtalarico@sillscummis.com

Landlords Challenge U.S. Eviction Ban and Continue to Oust Renters

October 25, 2020 — Kriston Capps - Bloomberg
In September, the Trump administration announced a national moratorium on evictions, via an order by the Centers for Disease Control and Prevention aimed at reducing the spread of coronavirus. The four-month temporary suspension applies to any tenant who can’t make rent due to economic conditions and who presents a written declaration about their circumstances to their landlord. But the CDC ban now faces legal challenges on multiple fronts, even as landlords continue to routinely file evictions for nonpayment of rent — the very outcome that the order was designed to prevent. On Oct. 20, the U.S. District Court for the Northern District of Georgia heard the first case against the moratorium, Richard Lee Brown, et al. v. Secretary Alex Azar, et al.. That challenge, brought by a nonprofit called the New Civil Liberties Alliance, has been joined by the National Apartment Association, which represents some 85,000 landlords responsible for 10 million rental units. Lawyers and scholars working on behalf of plaintiffs in the cases say that the CDC lacks the constitutional authority to enact a policy affecting rents. Read the court decision
Read the full story...
Reprinted courtesy of Kriston Capps, Bloomberg

Insurer Incorrectly Relies Upon "Your Work" Exclusion to Deny Coverage

June 10, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Eleventh Circuit reversed the district court's determination that there was no coverage based upon the policy's "your work" exclusion. Southern-Owners Ins. Co. v. Mac Contractors of Fla, LLC, 2019 U.S. App. LEXIS 10689 (11th Cir. April 11, 2019). Mac Contractors contracted with the homeowners to custom build their home. After construction began, Mac left the site before completing the project and before the issuance of a certificate of occupancy. The homeowners sued, alleged damage to wood floors and the metal roof. Southern-Owners originally agreed to defend under the CGL policy, but later withdrew the defense and filed this action for declaratory relief. The parties cross-filed motions for summary judgment. Southern-Owners argued that the "your work" exclusion applied to bar coverage. The "your work" exclusion barred coverage for "'property damage' to 'your work' arising out of it or any part of it and included in the 'products' completed operations hazard.'" The "products' completed operations hazard" included all "'property damage' occurring away from premises you own or rent and arising out of . . . 'your work' except . . . (1) products that are still in your physical possession; or (2) work that has not yet been completed or abandoned." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Rainwater Collecting on Rooftop is not Subject to Policy's Flood Sublimits

October 15, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Responding to a certified question from the First Circuit, the Supreme Judicial Court of Massachusetts determined that rainwater collecting on the insureds' rooftop and causing interior damage was not "flood" as defined in the policy and subject to sublimits. Zurich Am. Ins. Co. v. Medical Properties Trust, Inc., 2024 Mass. LEXIS ___ (Mass. July 23, 2024). A severe thunderstorm caused heavy rain and strong winds which damaged a hospital. The hospital was owned by Medical Properties Trust, Inc. (MPT) and leased to Steward Health Care System LLC (Steward). Ground water accumulated and flooded the basement. Rainwater also accumulated on the hospital's parapet roofs and on the second-story courtyard, and eventually seeped through the parapet roofs and courtyard to the hospital's upper floors, causing damage to the building and property within. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Congratulations to BWB&O’s 2023 Super Lawyers Rising Stars!

June 26, 2023 — Bremer Whyte Brown & O'Meara LLP
BWB&O is excited to announce Partner Courtney Serrato and Associates Andrew Arakelian, Pamchal Deylami, and Brian Taylor have been selected in the 2023 Southern California Super Lawyers list as Rising Stars for their work in Family Law and Civil Litigation. To read Super Lawyers’ digital publication, please click here. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The objective of Super Lawyers’ patented multiphase selection process is to create a credible, comprehensive, and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. Please join us in congratulating Courtney, Andrew, Pamchal, and Brian on achieving this level of recognition! Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES