How the Cumulative Impact Theory has been Defined
November 30, 2020 —
David Adelstein - Florida Construction Legal UpdatesLargely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”).
To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
“To Indemnify, or Not to Indemnify, that is the Question: California Court of Appeal Addresses Active Negligence in Indemnity Provisions”
April 05, 2017 —
Steven M. Cvitanovic & Omar Parra – Haight Brown & Bonesteel LLPIn California, it is well-established that the extent of a party’s obligation under an indemnity agreement is an issue of contractual interpretation, and it is therefore the intent of the parties that should control. What is the parties’ intent, then, when a subcontractor (indemnitor) agrees to indemnify the general contractor (indemnitee) “except to the extent the claims arise out of the general contractor’s active negligence or willful misconduct”? Does this mean the general contractor is barred entirely from recovering any indemnity if its active negligence contributed to the injury? Not according to the First Appellate District of the California Court of Appeal, which recently held that an actively negligent general contractor may still recover indemnity for the portion of liability attributable to the fault of others. Oltmans Construction Co. v. Bayside Interiors, Inc., No. A147313, 2017 WL 1179391, at *1 (Cal. Ct. App. Mar. 30, 2017).
In Oltmans Construction, an employee of O’Donnell Plastering, Inc. (“O’Donnell”), a sub-subcontractor of Bayside Interiors, Inc. (“Bayside”), which was a subcontractor to Oltmans Construction Company (“Oltmans”), sustained injuries when he fell through a skylight opening in the roof of a building under construction. The employee filed suit against Bayside, Oltmans, and the building’s owner, arguing Oltmans negligently cut and left unsecured the skylight opening. Oltmans subsequently filed a Cross-Complaint against Bayside and O’Donnell, contending it was entitled to indemnification under the governing agreements.
Reprinted courtesy of
Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and
Omar Parra, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com
Mr. Parra may be contacted at oparra@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Update: Lawyers Can Be Bound to Confidentiality Provision in Settlement Agreement
January 13, 2020 —
Danielle Ward, Esq. - Balestreri Potocki & HolmesIn July 2019, the California Supreme Court ruled that an attorney’s signature under the often-used phrase “approved as to form and content” does not preclude a finding that the attorney could be bound to the terms of a settlement agreement. (Monster Energy Co. v. Schechter (2019) 7 Cal.5th 781.) This decision marks a reversal of the Fourth District Court of Appeal’s 2018 ruling that approval of a contract is not tantamount to an agreement to be bound by that contract.
The underlying action stemmed out of a wrongful death suit by Wendy Crossland and Richard Fournier, parents of the decedent, against Monster Energy Company. The parties negotiated a settlement, a critical of element of which was a confidentiality provision aimed at keeping the the settlement secret.
The confidentiality provision prohibited plaintiffs and their counsel of record from disclosing both the existence of the settlement, or the terms thereof, to any person, entity, or publication, including the legal website Lawyers & Settlements. The attorneys signed the agreement under the phrase “approved as to form and content.”
Shortly after the settlement agreement was executed, the Plaintiffs’ attorney Bruce Schechter disclosed his clients’ settlement with Monster in an interview with Lawyers & Settlements. Monster filed suit against Mr. Schechter for breach of contract, among other causes of action. Mr. Schechter challenged the lawsuit with a SLAPP motion, essentially arguing that the lawsuit was meritless and merely an attempt to thwart freedom of speech.
The trial court denied Mr. Schechter’s motion as to the breach of contract cause of action finding that the settlement clearly contemplated that the attorneys were subjected to the terms of the agreement, and Schechter’s claim that he was not a party because he merely approved as to form and content was “beyond reason.”
The Fourth District Court of Appeal reversed, concluding that Mr. Schechter was not a party to the agreement by virtue of his signature approving the form and content, and the Plaintiffs had no authority to bind their attorney to the terms of the agreement. The Court of Appeal found that by affixing his signature to the agreement Mr. Schechter was merely manifesting his “professional thumbs up” in line with legal industry’s customary understanding.
In its reversal, the California Supreme Court did not disturb the legal community’s understanding of the phrase “approved as to form and content.” Rather, the Court concluded that an attorney’s signature under that often-used phrase does not preclude as a matter of law that the attorney intended to be bound by the agreement. The entire agreement, including the substantive provisions, need to be examined to determine the attorney’s intent in affixing his/her signature to the agreement.
Turning to the Crossland/Fournier Monster settlement agreement, the Court was unpersuaded by Mr. Schechter’s argument that he was not bound to the agreement because counsel was not included in the definition of “party”. The Court stated that it’s the substance of the agreement that determines whether counsel is a party to the contract, as opposed to a party to the lawsuit.
The Court was persuaded, in part, by the important role that confidentiality plays in brokering settlements. It noted that public disclosure of private settlements would serve to “chill” parties’ ability to resolve matters short of trial, and there was little doubt that confidentiality was an important term of the Crossland/Fournier Monster settlement. In concluding that Monster had met its burden to defeat an anti-SLAPP motion, the Court pointed to the numerous references to counsel in the substantive provisions of the agreement which a trier of fact could conclude bound Mr. Schechter to the confidentiality terms.
Danielle Ward has concentrated her law practice on defending developer, general contractor, and subcontractor clients in a variety of construction matters. She has been an attorney with Balestreri Potocki & Holmes since 2010 and can be reached at dward@bph-law.com.
Read the court decisionRead the full story...Reprinted courtesy of
Contractor Sues Golden Gate Bridge District Over Suicide Net Project
December 18, 2022 —
James Leggate - Engineering News-RecordThe project to install a suicide-deterrence net and perform other upgrades on the Golden Gate Bridge in San Francisco now is expected to complete five years late and cost more than double the original contract price, its contractors say. The joint venture leading the project filed a breach-of-contract complaint against the agency that manages the bridge seeking $195 million in damages, while the agency counters that delays were caused by changes in the contractor’s ownership.
Reprinted courtesy of
James Leggate, Engineering News-Record
Mr. Leggate may be contacted at leggatej@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Court Bars Licensed Contractor From Seeking Compensation for Work Performed by Unlicensed Sub
June 06, 2022 —
Garret Murai - California Construction Law BlogIt all started with a tree.
A eucalyptus tree to be exact.
What followed is one of the more important cases to be decided under Business and Professions Code section 7031 in recent years. Yes, that Section 7031. The statute variously described by the state’s courts as “harsh[ ],” draconian” and “unjust,” but, importantly, nevertheless valid.
Under Section 7031, an unlicensed contractor is barred from seeking compensation for work requiring a contractor’s license. This has been called the “shield.” However, in addition to the “shield,” project owners can also employ Section 7031’s “sword,” and seek disgorgement of all monies paid to an unlicensed contractor. Section 7031’s “shield” and “sword” applies even if the project owner knew that the contractor was unlicensed. They also apply even if the unlicensed contractor’s work was flawless. And they also apply even if a contractor was unlicensed during a portion of its work. This is because, as courts have stated, Section 7031 is a consumer protection statute intended to protect the public from unlicensed contractors and applies irrespective of the equities.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Sales of Existing U.S. Homes Unexpectedly Fell in January
February 22, 2018 —
Sho Chandra – BloombergSales of previously owned U.S. homes unexpectedly fell in January to a four-month low, indicating a shortage of available properties is increasingly hindering the real-estate industry, a National Association of Realtors report showed Wednesday.
Sales growth is limited by an acute shortage of inventory, which is pushing up home prices faster than wage growth. The group noted that property prices have jumped 41 percent over the past five years, while wages have gained 12 percent.
If the current pace of sales continues -- which NAR doesn’t anticipate -- purchases would be lower than in 2017. At the same time, steady hiring and elevated confidence to make large purchases, as well as tax cuts that are boosting Americans’ take-home pay, are expected to sustain demand for housing in much of the nation.
Read the court decisionRead the full story...Reprinted courtesy of
Sho Chandra, Bloomberg
Structural Failure of Precast-Concrete Span Sets Back Sydney Metro Job
January 04, 2018 —
Chris Webb - Engineering News-RecordOriginally Published by CDJ on February 23, 2017
A key component of Australia’s biggest public transport infrastructure project—Sydney’s $6.3-billion Metro North West—is the subject of a critical and detailed technical report describing how an elevated viaduct span failed at a stitch joint between two precast segments during construction last September. Project officials say the affected span, which did not suffer a progressive collapse, has since been removed and its replacement fast-tracked to avoid further delays. Little additional detail was provided.
Read the court decisionRead the full story...Reprinted courtesy of
Chris Webb, ENR
What ‘The Curse’ Gets Wrong About Passive House Architecture
April 02, 2024 —
Teresa Xie - BloombergIn the fifth episode of Showtime’s The Curse, two potential buyers are touring a boutique house in Española, a soon-to-be gentrified Santa Fe neighborhood when one of them makes a remark about the temperature. “Sorry, can I get a water? It’s just really hot in here,” he says, airing out his sweat-stained shirt. The quirky home’s architect-slash-developer, played by Emma Stone, says, “Sure!” and without skipping a beat, continues to explain the virtues of her passive house design: The home functions like a thermos, with no need for air conditioning — unless any air escapes the house. Then it takes five to seven hours for the room to recover.
Owning a passive house sounds like a nightmare, right? If you’re buying a one-of-a-kind, mirror-clad spec house from Stone and co-star Nathan Fielder, it may well be. On The Curse, the two play a do-gooder couple attempting to make an HGTV series (with Benny Safdie) about turning regular houses into carbon-neutral passive homes.
Odd things happen to Stone and Fielder over the show’s first season: trouble with the laws of gravity, the trials of a failing marriage and a literal curse from a small child. But the weirdest might be the show’s portrayal of passive house design, an energy-efficient design standard that has been around since the 1970s. Passive building, which has its origins in Europe, relies on advanced construction methods to seal a structure in an airtight envelope, thereby reducing energy consumption for heating and cooling by as much as 75%.
Read the court decisionRead the full story...Reprinted courtesy of
Teresa Xie, Bloomberg
