Cambridge Massachusetts Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Unrelated Claims Against Architects Amount to Two Different Claims

July 30, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Second Circuit found that two claims arising from the same project were unrelated, creating two separate payments by the insurer for the two separate claims. Dormitory Auth. of New York v. Continental Cas. Co., 2014 U.S. App. 12088 (2nd Cir. June 23, 2014). In 1995, the State agency contracted with the insured architectural firm to design and oversee the construction of a new dormitory at City University of New York. Plans drawn by the architects erred in their estimate of the steel requirement. To recover losses from the resulting delay and expense, the agency sent a demand letter in May 2002 to the architects detailing the Steel Girt Tolerance issue. After the project was finished in 2001, another problem was discovered: excess accumulations of snow and ice were sliding off the building onto sidewalks a considerable distance away. The Ice Control Issue was studied during the winter of 2003-04. The conclusion was that the design of the facade failed to account for temperature variations appropriate for a building in New York. The problem could not be resolved by adding canopies, which would have been a cheaper fix. Study of the problem continued into 2005. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Mexico's Richest Man Carlos Slim to Rebuild Collapsed Subway Line

November 01, 2021 — The Associated Press - Bloomberg
Mexico City (AP) -- Mexico’s richest man reached an agreement with Mexico City authorities Wednesday to rebuild or reinforce an elevated subway line that collapsed in May, killing 26 people. Telecom and construction magnate Carlos Slim said his Grupo Carso’s construction subsidiary would pay the cost of rebuilding the span that collapsed, and reinforcing other parts of the elevated line to meet higher standards in a city plagued with severe earthquakes. Grupo Carso said in a statement to the country’s stock market that the outlay did not constitute any admission of responsibility for the collapse, and would not “materially affect” the company’s business. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Illinois Supreme Court Holds That the Implied Warranty of Habitability Does Not Extend to Subcontractors

March 04, 2019 — Michael J. Ciamaichelo - The Subrogation Strategist
The implied warranty of habitability allows a homeowner to recover damages for latent defects that interfere with the intended use of a home. In Sienna Court Condo. Ass’n v. Champion Aluminum Corp., 2018 IL 122022, 2018 Ill. LEXIS 1244 (2018), the Supreme Court of Illinois held that buyers of new homes cannot assert claims for breach of the implied warranty of habitability against subcontractors involved in the construction of the homes because the subcontractors have no contractual relationship with the homeowners and the damages are purely economic. As the court explained, the implied warranty of habitability is a creature of contract (not tort) and, therefore, only exists when there is contractual privity between the defendants and the homeowners. In Sienna, a group of condominium unit owners alleged that their new homes contained latent construction defects and asserted claims against the various parties involved in the construction and sale of the homes, including claims against the defendant subcontractors for breach of the implied warranty of habitability. The plaintiffs contracted with the property developer to purchase the homes, but the plaintiffs had no contractual relationship with the subcontractors involved in the construction of the homes. The Sienna court, overturning the decisions of the trial court and the appellate court, granted the subcontractors’ joint motion to dismiss the plaintiff’s claims for the implied warranty of habitability because the plaintiffs had no contractual relationship with the subcontractors and the damages were purely economic. Read the court decision
Read the full story...
Reprinted courtesy of Michael J. Ciamaichelo, White and Williams LLP
Mr. Ciamaichelo may be contacted at ciamaichelom@whiteandwilliams.com

Lost Rental Income not a Construction Defect

November 27, 2013 — CDJ STAFF
A judge in Colorado has ruled that although the homeowner’s policy excluded construction defects from coverage, lost rental income and the cost of deck repair involved in fixing a defective drainage system were. Read the court decision
Read the full story...
Reprinted courtesy of

Justin Clark Joins Newmeyer & Dillion’s Walnut Creek Branch as its Newest Associate

May 03, 2017 — Newmeyer & Dillion LLP
WALNUT CREEK, Calif. – APR. 28, 2017 – Up and coming associate and insurance attorney Justin Clark is the newest associate to join the ever-growing litigation practice at Newmeyer & Dillion LLP’s Walnut Creek office. Clark brings experience in the areas of insurance litigation, construction defect litigation, and business transactions. Walnut Creek’s managing partner Brian Morrow explained why he is so excited by the addition of Clark: “We are thrilled to have Clark on board, as his emphasis on insurance coverage will assist in a key area for our clients, and further expand our capabilities in our northern California office.” Clark has a background in a variety of practice areas, including insurance coverage, products liability, and asbestos litigation. He advocates for manufacturers, suppliers, distributers, and contractors in all phases of litigation. Clark represents developers, builders, and general contractors in construction and insurance disputes. He also helps small business clients draft commercial contracts to better serve their growing business needs. Clark can be reached at justin.clark@ndlf.com or 925-988-3263. About Newmeyer & Dillion For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com. Read the court decision
Read the full story...
Reprinted courtesy of

Texas Federal Court Delivers Another Big Win for Policyholders on CGL Coverage for Construction-Defect Claims and “Rip-and-Tear” Damages

March 14, 2022 — Blake A. Dillion, Jared De Jong & Scott S. Thomas - Payne & Fears
Insurers regularly argue that commercial general liability (“CGL”) policies are not performance bonds and therefore there is no coverage for claims seeking damages for defective or faulty workmanship. Insurers also argue there is no coverage for so-called “tear-out” or “rip-and-tear” damages, where fixing property damage requires replacing defective work that has not itself been damaged. Fortunately, in a newly decided case, a Texas federal district court rejected both arguments by an insurer. Amerisure Mutual Insurance Company v. McMillin Texas Homes, LLC, No. SA-20-CV-01332-XR, 2022 WL 686727 (W.D. Tex. Mar. 8, 2022). As with most construction-defect claims, this case involved homeowner claims against a residential developer, McMillin Texas Homes (“McMillin”). After the homes were completed, homeowners complained about defects in the artificial stucco exterior finish and filed suit. McMillin tendered to its insurer, Amerisure Mutual Insurance Company (“Amerisure”). Amerisure then sued McMillin for declaratory relief, arguing that it had no duty to defend or indemnify the homeowner claims. McMillin filed a counterclaim alleging Amerisure breached its policies by refusing to defend or indemnify McMillin. Reprinted courtesy of Blake A. Dillion, Payne & Fears, Jared De Jong, Payne & Fears and Scott S. Thomas, Payne & Fears Mr. Dillion may be contacted at bad@paynefears.com Mr. De Jong may be contacted at jdj@paynefears.com Mr. Thomas may be contacted at sst@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

More Hensel Phelps Ripples in the Statute of Limitations Pond?

February 03, 2020 — Christopher G. Hill - Construction Law Musings
As is always the case when I attend the Virginia State Bar’s annual construction law seminar, I come away from it with a few posts on recent cases and their implications. The first of these is not a construction case, but has implications relating to the state project related statute of limitations and indemnification issues for construction contracts brought out in stark relief in the now infamous Hensel Phelps case. In Radiance Capital Receivables Fourteen, LLC v. Foster the Court considered a waiver of the statute of limitations found in a loan contract. The operative facts are that the waiver was found in a Continuing Guaranty contract and that the default happened more than 5 years prior to the date that Radiance filed suit to enforce its rights. When the defendants filed a plea in bar stating that the statute of limitations had run and therefore the claim was barred, Radiance of course argued that the defendants had waived their right to bring such a defense. The defendants responded that the waiver was invalid in that it violated the terms of Va. Code 8.01-232 that states among other things:

an unwritten promise not to plead the statute shall be void, and a written promise not to plead such statute shall be valid when (i) it is made to avoid or defer litigation pending settlement of any case, (ii) it is not made contemporaneously with any other contract, and (iii) it is made for an additional term not longer than the applicable limitations period.

The Circuit Court and ultimately the Supreme Court agreed with the defendants. In doing so, the Virginia Supreme Court rejected arguments of estoppel and an argument that a “waiver” is not a “promise not to plead.” Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES