Seattle Washington Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Named Insured’s Liability Found Irrelevant to Additional Insured’s Coverage Under a Landlords and Lessors Additional Insured Endorsement

November 16, 2020 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Truck Ins. Exchange v. AMCO Ins. Co. (No. B298798, filed 10/26/20), a California appeals court held that even though the named insured restaurant-lessee was found not liable for premises liability to injured restaurant patrons, the respective liability of the named and additional insured was irrelevant to the landlord-lessor’s coverage for injuries “arising out of” the lessee’s “use” of the premises under a landlords, managers or lessors of premises additional insured endorsement on the lessee’s general liability policy. In Truck v. AMCO, restaurant patrons were injured when a vehicle crashed into the restaurant while they were dining. The landlord was aware of a similar accident that happened several years before, but the current lessee operating the restaurant was not. The patrons sued the lessee, alleging negligence and premises liability for failing to take precautionary measures and safeguard the patrons. On learning of the prior incident, the patrons added the landlord, alleging that it should have protected the property from a recurrence by reinforcing the door and installing bollards by the street. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Fires, Hurricanes, Dangerous Heat: The US Is Reeling From a String of Disasters

August 22, 2023 — Will Wade & Brian K Sullivan - Bloomberg
From deadly wildfires to floods, the US is reeling from several natural disasters in quick succession — and more are likely on the way. Torrential rains from the remnants of Hurricane Hilary are inundating parts of California. Two tropical storms, one post-tropical cyclone and two potential storms are lined up in the Atlantic Ocean. Almost 100 wildfires are burning across 15 states as officials in Hawaii investigate the deadliest US blaze in more than a century. And record heat will test Midwest power grids this week. All of this, all at once, is a lot — and it’s not just bad luck. Climate change has triggered heat waves around the world, leading to ideal fire conditions in forests across the Northwest and Canada. It’s also boosting Atlantic water temperatures, which can intensify storms as the peak of hurricane season approaches. And unusually warm Pacific Ocean waters fueled Hilary, which in turn will contribute to scorching heat in the Midwest. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Hong Kong Property Tycoon Makes $533 Million Bet on Solar

April 02, 2014 — Ehren Goossens and Benjamin Haas - Bloomberg News
A Hong Kong real-estate tycoon has spent the past year accumulating stakes in failing solar companies, piecing together what may become the biggest collection of photovoltaic factories in the world. Zheng Jianming, also known in Cantonese as Cheng Kin Ming, has spent or pledged about $533 million to buy assets that at their peak were worth almost $20 billion, according to regulatory filings in the U.S. and Hong Kong, where he has a home and office. The transactions, if completed, would transform Zheng, a newcomer to the solar industry, into one of its most powerful leaders. Another Zheng solar investment in 2012, a 30 percent stake in Shunfeng Photovoltaic International Ltd. (1165), has surged more than 2,900 percent and is now worth more than $745 million. Mr. Goossens may be contacted at egoossens1@bloomberg.net; Mr. Haas may be contacted at bhaas7@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Ehren Goossens and Benjamin Haas, Bloomberg News

CA Supreme Court: Right to Repair Act (SB 800) is the Exclusive Remedy for Residential Construction Defect Claims – So Now What?

January 31, 2018 — Steven M. Cvitanovic & Omar Parra - Publications & Insights
A torrent of alerts have been flooding e-mail inboxes regarding the California Supreme Court’s decision in McMillin v. Superior Court, to reverse the Liberty Mutual Insurance Company v. Brookfield Crystal Cove LLC (2013) case, but with little discussion about the practical effects of the ruling. This alert will discuss how this ruling affects litigation of SB 800 Claims and Builders. Background on Liberty Mutual Case In 2002, the California Legislature enacted comprehensive construction defect litigation reform referred to as the Right to Repair Act (the “Act”). Among other things, the Act establishes standards for residential dwellings, and creates a prelitigation process that allows builders an opportunity to cure the construction defects before being sued. Since its enactment, however, the Act’s application has been up for debate. Most notably, in Liberty Mutual Insurance Company v. Brookfield Crystal Cove LLC (2013), the California Court of Appeal for the Fourth District held the Act was the exclusive remedy only in instances where the defects caused only economic loss, and that homeowners could pursue other remedies in situations where the defects caused actual property damage or personal injuries. Reprinted courtesy of Steve Cvitanovic, Haight Brown & Bonesteel LLP and Omar Parra, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com Mr. Parra may be contacted at oparra@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Climate Disasters Are an Affordable Housing Problem

October 01, 2024 — Juan Pablo Garnham & Arjuna Heim - Bloomberg
When Maui was devastated by wildfires in August 2023, some residents were initially fortunate. The neighborhood of Makawao, for example, was spared the worst effects of the fire that engulfed Lahaina, 35 miles to the west. Recently, though, we met a woman in that neighborhood who faces a different kind of threat: Her landlord has now demanded that she pay double her rent or face eviction. As housing advocates in the region, we’ve heard stories like this repeatedly, as residents report an acute fear of displacement and homelessness. A year after the fires killed more than 100 people, displaced 12,000 and disrupted the economy of the island, the disaster lingers for many in Maui and Hawai'i. Rents across the island have increased sharply, offering a cautionary tale for the rest of the US about how climate change, a housing crisis and the lack of adequate public policies can multiply the suffering of a community already in pain. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Want a Fair Chance at a Government Contract? Think Again

July 13, 2017 — Duane Craig - Construction Informer
If you’ve ever missed out on a government contract, part of the reason might have been because entrenched government contractors gained competitive advantages by under-paying their workers. The Fair Pay & Safe Workplaces executive order was nullified by Congress this year and much of the reporting by the business press presented just one side of the story. Here’s another perspective. When awarding federal contracts the government is supposed to consider each contractor’s compliance with labor laws related to pay, health and safety. But, there is a huge problem with enforcement on a government contract, according to Senator Elizabeth Warren and other observers.

Some federal contractors frequently underpay their workers violating wage and hour laws. More than 300,000 workers were cheated out of pay while working under federal contracts in the last decade. There were 12,000 companies working on federal contracts that were doing the cheating.
692 federal contractors significantly violated federal labor laws, and then repeated the behavior, over and over. The repeat offenders receive millions in taxpayer dollars as they violated safety and health standards. Those violations caused a wide range of physical harm to workers. Dozens of workers died, and countless numbers were exposed to chemicals that cause long term health problems.

Read the court decision
Read the full story...
Reprinted courtesy of Duane Craig, Construction Informer
Mr. Craig may be contacted at dtcraig@constructioninformer.com

Boston Catwalk Collapse Injures Three Workers

May 10, 2022 — Scott Van Voorhis - Engineering News-Record
The collapse of a catwalk in a defunct, 124-year-old power plant building in Boston on May 4 injured three workers in the latest in a spate of serious construction accidents in the city and its environs. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES