Ready, Fire, Aim: The Importance of Targeting Your Delay Notices
November 08, 2021 —
Bradley Sands, Jones Walker LLP - ConsensusDocsProviding written notice of delay to subcontractors when a project is behind schedule is a regular part of good project documentation practices. A properly targeted delay notice is an important, project correspondence that is an appropriate response to a subcontractor’s specific delay or ongoing delays. However, when a project falls behind schedule and the project management team is in the fog of war, it could seem like a good idea to start firing off project delay notices to any and every subcontractor. While these delay notices may provide a short term burst of productivity, you could find that those same notices are aimed back at you in a future litigation.
This article identifies two potential unintended consequences of sending delay notices that a contractor should keep in its sights and then provides recommendations for properly calibrating future delay notices in light of these potential consequences.
Acceleration: You Might Get What You Ask For
A delay notice to a subcontractor could be interpreted as—or expressly state—direction to the subcontractor to accelerate its work. When a subcontractor is directed to accelerate its work, it may incur additional costs for premium, extended, or overtime labor, additional crews, increased supervision costs, increased overhead costs, and losses due to productivity impacts from the acceleration (e.g., stacking of trades and fatigue). A subcontractor may be entitled to recover these increased costs that are caused by a direction to accelerate.
Read the court decisionRead the full story...Reprinted courtesy of
Bradley Sands, Jones Walker LLPMr. Sands may be contacted at
bsands@joneswalker.com
Real Estate & Construction News Round-Up (01/18/23) – Construction Inventory, 3D Printing, and Metaverse Replicas
February 06, 2023 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThis week’s round-up dives into projections on construction inventory in the housing market, the first 3D-printed house, a replica of South Korea’s Seoul in the Metaverse, and more.
- Shifts that occurred last year and at the peak of pandemic have transformed the real estate industry, with 2023 emerging as something of a barometer in the manifestations of those changes. (Tony Cantu, Mortgage Professional America (MPA))
- Total new construction of homes across the country is expected to drop by 200,000 dwellings per year until 2026 as skill shortages and supply issues continue to bite. (Sowaibah Hanifie, 7 News)
- Almost all economists and contractors expect some sort of an economic slowdown this year. (Sebastian Obando, Construction Dive)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Wisconsin Supreme Court Holds that Subrogation Waiver Does Not Violate Statute Prohibiting Limitation on Tort Liability in Construction Contracts
October 21, 2019 —
Gus Sara - The Subrogation StrategistIn Rural Mut. Ins. Co. v. Lester Bldgs., LLC 2019 WI 70, 2019 Wisc. LEXIS 272, the Supreme Court of Wisconsin considered whether a subrogation waiver clause in a construction contract between the defendant and the plaintiff’s insured violated Wisconsin statute § 895.447, which prohibits limitations of tort liability in construction contracts. The Supreme Court affirmed the lower court’s decision that the waiver clause did not violate the statute because it merely shifted the responsibility for the payment of damages to the defendant’s insurance company. The waiver clause did not limit or eliminate the defendant’s tort liability. This case establishes that while
§ 895.447 prohibits construction contracts from limiting tort liability, a subrogation waiver clause that merely shifts responsibility for the payment of damages from a tortfeasor to an insurer does not violate the statute and, thus, is enforceable.
In Rural Mutual, the plaintiff’s insured, Jim Herman, Inc. (Herman), entered into a contract with Lester Buildings, LLC (Lester) to design and construct a barn on Herman’s property. The contract included a provision that stated the following:
Both parties waive all rights against each other and any of their respective contractors, subcontractors and suppliers of any tier and any design professional engaged with respect to the Project, for recovery of any damages caused by casualty of other perils to the extent covered by property insurance applicable to the Work or the Project, except such rights as they have to the proceeds of such property insurance and to the extent necessary to recover amounts relating to deductibles of self-insured retentions applicable to insured losses. . . . This waiver of subrogation shall be effective notwithstanding allegations of fault, negligence, or indemnity obligation of any party seeking the benefit or production [sic] of such waiver.
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Court Rules on a Long List of Motions in Illinois National Insurance Co v Nordic PCL
May 10, 2012 —
CDJ STAFFThe case Illinois National Insurance Co. v Nordic PCL, et al. “involves a dispute about whether insurance benefits are available to a general contractor who built structures that allegedly have construction defects. Plaintiffs Illinois National Insurance Company (‘Illinois National’) and National Union Fire Insurance Company of Pittsburgh, PA (‘National Union’) (collectively, the ‘Insurers’), commenced this action for declaratory relief against Defendant Nordic PCL Construction, Inc., f/k/a Nordic Construction, Ltd. ("Nordic"), on August 23, 2011.”
The court was asked to rule on a long list of motions: “Counterclaim Defendants’ Request for Judicial Notice in Support of Their (1) Motion to Dismiss the Counterclaim and (2) Motion to Strike Portions of the Counterclaim, ECF No. 16 (‘Request for Judicial Notice’); Counterclaim Defendants’ Motion to Dismiss Counterclaim Filed October 24, 2011, ECF No. 14 (‘Motion to Dismiss Counterclaim’); Counterclaim Defendants’ Motion to Strike Portions of the Counterclaim Filed October 24, 2011, ECF No. 15 (‘Motion to Strike’); Third-Party Defendant Marsh USA, Inc.’s Motion to Dismiss or, in the Alternative, Stay Proceedings in Favor of Pending State Action, ECF No. 33 (‘Marsh’s Motion To Dismiss Or Stay’); Defendant and Third-Party Plaintiff Nordic PCL Construction, Inc., f/k/a Nordic Construction Ltd.’s Substantive Joinder to Third-Party Defendant Marsh USA Inc.’s Motion to Dismiss or, in the Alternative, Stay Proceedings in Favor of Pending State Action, ECF No. 36 (‘Nordic’s Joinder’); and Third-Party Defendant Marsh USA, Inc.’s Motion for Judgment on the Pleadings on Counts V and VI of Defendant/Third-Party Plaintiff Nordic PCL Construction, Inc.’s Third-Party Complaint, ECF No. 29 (‘Marsh’s Motion for Judgment on the Pleadings’).”
In result, the court reached the following decisions: “The court GRANTS IN RELEVANT PART the Insurers’ Request for Judicial Notice to the extent it covers matters relevant to these motions; GRANTS IN PART the Insurers’ Motion to Dismiss Counterclaim, but gives Nordic leave to amend the Counterclaim in certain respects; DENIES the Insurers’ Motion to Strike; DENIES Marsh’s Motion To Dismiss Or Stay and Nordic’s Joinder; and GRANTS Marsh’s Motion for Judgment on the Pleadings.”
The court provides a bit of background on the case: “This action arises out of alleged construction defects involving two projects on which Nordic acted as the general contractor. Nordic is a defendant in a pending state court action with respect to one of the projects and says it spent more than $400,000 on repairs with respect to the other project. Nordic tendered the defense of the pending state court action to the Insurers and sought reimbursement of the cost of repairs already performed. The Insurers responded by filing this action to determine their rights under the insurance policies issued to Nordic.”
Furthermore, the court presented a brief procedural history: “The Insurers commenced this declaratory action in this court on August 23, 2011. The Complaint asserts two claims, one seeking a declaration that the Insurers have no duty to provide a defense or indemnification regarding the Safeway Action, the other seeking such a declaration regarding the Moanalua Claims. Along with its Answer, Nordic filed a Counterclaim against the Insurers. The Counterclaim asserts breach of contract, breach of the covenant of good faith and fair dealing, misrepresentations and omissions of material fact, and bad faith, and seeks declaratory relief against the Insurers.”
The procedural history continues: “Nordic also filed a Third-Party Complaint against Marsh, the broker that had procured the Policies from the Insurers for Nordic. Nordic alleges that it reasonably believed that the Policies would provide completed operations insurance coverage for the types of construction defects alleged in the Safeway Action and Moanalua Claims. The Third-Party Complaint asserts breach of contract, negligence, promissory estoppel, breach of fiduciary duties, implied indemnity, and contribution and equitable subrogation.”
In conclusion, “The court GRANTS IN RELEVANT PART the Insurers’ Request for Judicial Notice. With regard to the Insurers’ Motion to Dismiss Counterclaim, the court GRANTS the motion as to Count I (breach of contract), Count II (duty of good faith and fair dealing), Count III (fraudulent and negligent misrepresentation), the portion of Count IV (bad faith) premised on fraud, and Count IV (declaratory relief). The court DENIES the motion as to Count IV (bad faith) that is not premised on fraud. Except with respect to the "occurrence" issue, which the court disposes of here on the merits, and Count V, which concerns only a form of relief, Nordic is given leave to amend its Counterclaim within three weeks of the date of this order. The court DENIES the Insurers’ Motion to Strike, DENIES Marsh’s Motion to Dismiss or Stay and Nordic’s Joinder, and GRANTS Marsh’s Motion for Judgment on the Pleadings with respect to Counts V and VI of the Third-Party Complaint.”
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
General Contractor Supporting a Subcontractor’s Change Order Only for Owner to Reject the Change
December 09, 2019 —
David Adelstein - Florida Construction Legal UpdatesThe opinion in Westchester Fire Ins. Co, LLC v. Kesoki Painting, LLC, 260 So.3d 546 (Fla. 3d DCA 2018) leads to a worthy discussion because it involves a common scope of work occurrence on construction projects involving a general contractor and subcontractor. The contractor submits a subcontractor’s change order request to the owner and the owner rejects the change order. What happens next is a scope of work payment dispute between the general contractor and subcontractor. Yep, a common occurrence.
In this case, a general contractor hired a subcontractor to perform waterproofing and painting. A scope of work issue arose because the specifications did not address how the window gaskets should be cut and then sealed. The owner wanted the window gaskets cut at a 45-degree angle and the subcontractor claimed this resulted in increased extra work. The general contractor agreed and submitted a change order to the owner to cover these costs. The owner rejected the change order claiming it was part of the general contractor’s scope of work even though the cutting of window gaskets at a 45-degree angle was not detailed in the specifications.
After the subcontractor filed a suit against the general contractor’s payment bond surety, the project architect further rejected the change order because gasket cutting was part of the specification requirements. (Duh! What else was the architect going to say? It was not going to concede there was an omission that resulted in a change order to the owner, right?)
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Illinois Joins the Pack on Defective Construction as an Occurrence
December 16, 2023 —
Anna M. Perry - Saxe Doernberger & Vita, P.C.Illinois joins the majority of states finding “property damage that results inadvertently from faulty work can be caused by an ‘accident’ and therefore constitute an ‘occurrence’.”
The Illinois Supreme Court’s ruling in Acuity v. M/I Homes of Chicago, LLC1 (“Acuity v. M/I Homes”) is the first high court ruling in Illinois on this critical coverage issue for contractors. M/I Homes of Chicago, LLC (“M/I Homes”) constructed a townhome development. After completion, water entered the townhomes resulting in interior water damage. The townhome owners’ association filed suit against M/I Homes alleging it, or its subcontractors, caused the damage because it used defective materials, conducted faulty workmanship, and failed to comply with applicable building codes (the “Underlying Action”).
Read the court decisionRead the full story...Reprinted courtesy of
Anna M. Perry, Saxe Doernberger & Vita, P.C.Ms. Perry may be contacted at
APerry@sdvlaw.com
Jury Could Have Found That Scissor Lift Manufacturer Should Have Included “Better” Safety Features
January 02, 2024 —
Garret Murai - California Construction Law BlogA few years ago I listened to an NPR segment called “
What Can Kids Learn by Doing Dangerous Things?” It was about a summer program called the Tinkering School where kids can learn to build things, using tools of course, including power tools.
The founder of the program, Gever Tulley, also wrote a book entitled
50 Dangerous Things (You Should Let Your Children Do), in which he argued that while well-intentioned, children today are overly protected, and that giving children exposure to “slightly” dangerous things can help foster independence, responsibility, and problem-solving as well as a healthy dose of caution.
The plaintiff in the next case might have benefitted from that program.
In
Camacho v. JLG Industries Inc., 93 Cal.App.5th 809 (2023), the Court of Appeals examined whether the manufacturer of a scissor lift should have incorporated “better” safety features when a construction worker fell from the lift.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
CDC Issues Moratorium on Residential Evictions Through 2020
October 05, 2020 —
Steven E. Ostrow, C. Jason Kim, & Marissa Levy - White and Williams LLPOn September 1, 2020, the Centers for Disease Control and Prevention (CDC) announced that it was issuing an order (CDC Order) to temporarily halt residential evictions to prevent the further spread of COVID-19. The CDC Order became effective on September 4, 2020 and will remain in effect through December 31, 2020.
The purpose of the CDC Order is to keep tenants in their residences to reduce crowding in shelters or other shared housing and to reduce the number of unsheltered homeless, as those conditions have been shown to increase the spread of COVID-19.
APPLICABILITY & PROTECTIONS
The CDC Order is broader than the previous eviction moratorium under the Coronavirus Relief and Economic Security Act (CARES Act), which applied only to federally-funded housing and expired on July 24, 2020. Eligible renters include those who qualified for a stimulus check under the CARES Act and individuals who expect to make less than $99,000 this year or a joint-filing couple that expects to make less than $198,000.
Reprinted courtesy of
Steven E. Ostrow, White and Williams LLP,
C. Jason Kim, White and Williams LLP, and
Marissa Levy, White and Williams LLP
Mr. Ostrow may be contacted at ostrows@whiteandwilliams.com
Mr. Kim may be contacted at kimcj@whiteandwilliams.com
Ms. Levy may be contacted at levymp@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
