Cambridge Massachusetts Building Expert Directory

Quick Note: Expert Testimony – Back to the Frye Test in Florida

December 19, 2018 — David Adelstein - Florida Construction Legal Updates
Expert testimony (opinions) – very important testimony in construction disputes. Whether it is a delay claim, an inefficiency claim, a defect claim, etc., expert testimony plays an invaluable role in construction disputes. Construction attorneys work closely with expert witnesses to ensure that an expert helps render an opinion to support their client’s burden of proof (including damages) or an affirmative defense. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Transition Study a Condo Board’s First Defense against Construction Defects

December 04, 2013 — CDJ STAFF
According to the advice provided by T. Allen Mott and Nicholas D. Cowie, condominium boards would be well advised to “hire an engineer or architect to perform a transition study,” since it would be preferable to repair any problems while warranties are still in effect. They also caution that the board must “determine whether the developer-created budget and reserve fund are adequate to cover the cost of maintaining the condominium’s construction over time.” They note that discovered in time, some problems are easy to fix, but left unrepaired, they can result in “extensive, hidden property damage requiring associations to borrow money and assess unit owners to cover the entire cost of repairing the developer’s construction defects and resulting property damage. The goal, as they point out, is “an amicable repair resolution.” Read the court decision
Read the full story...
Reprinted courtesy of

The Architecture of Tomorrow Mimics Nature to Cool the Planet

January 31, 2022 — Damian Shepherd - Bloomberg
There’s a new climate push in the building industry: regenerative architecture. The sector has been trying for years to cut its sizeable carbon footprint, which was responsible for 38% of the world’s energy-related greenhouse gases in 2019. But developers need to go beyond preventing pollution if they want to help avoid catastrophic climate change, according to Sarah Ichioka and Michael Pawlyn, co-authors of a new book titled Flourish: Design Paradigms for Our Planetary Emergency. They argue that buildings should be designed in a regenerative way — a process that mimics nature by restoring its own materials and sources of energy. It goes further than sustainable design, which seeks to reduce harm to the environment and use only essential materials. “More than half of humanity’s total historic greenhouse-gas emissions have occurred since the concept of ‘sustainability’ entered the mainstream,” Ichioka and Pawlyn write. “It is now time to embrace a new regenerative approach to design and development.” Read the court decision
Read the full story...
Reprinted courtesy of Damian Shepherd, Bloomberg

New Survey Reveals Present-Day Risks of Asbestos Exposure in America - 38% in High-Risk Jobs, 47% Vulnerable through Second-Hand Exposure

April 08, 2024 — The Law Offices of Justinian C. Lane, Esq. - PLLC
AUSTIN, April 04, 2024 (GLOBE NEWSWIRE) -- A recent nationwide survey conducted on the risks of asbestos in America revealed that 38% of respondents have worked in high-risk industries where asbestos was present, while 47% have experienced indirect exposure through family members employed in these high-risk environments. The survey results reflect the fact that, despite the EPA's recent ban on ongoing uses of chrysotile asbestos, the threat of exposure still looms large in the US, underscoring the urgent need for continued vigilance and action to safeguard public health. Compounding the concern is the revelation that only 8% of Americans undergo regular testing. These findings, released today, underscore the urgent necessity for Asbestos Cancer Risk Awareness and routine testing. They emphasize the crucial importance of proactive measures to mitigate the pervasive risks associated with asbestos exposure in the United States. The study was conducted by Researchscape on behalf of The Law Offices of Justinian C. Lane, Esq. - PLLC, a leading firm advocating for testing and compensation for individuals exposed to asbestos on the job and their families who are at risk due to second-hand exposure. According to the survey, 86% of respondents have never undergone any testing for asbestos exposure, while a mere 8% are tested regularly. The lack of testing is particularly concerning among the Gen X demographic who could be at risk due to secondhand exposure from a family member who worked with asbestos when it was still prevalent, with 92% reporting no testing, highlighting the potential risks associated with secondhand exposure. Read the court decision
Read the full story...
Reprinted courtesy of

First Circuit: No Coverage, No Duty to Investigate Alleged Loss Prior to Policy Period

May 18, 2020 — Eric B. Hermanson & Austin D. Moody - White and Williams
On April 1, 2020, the First Circuit, applying Massachusetts law, issued a potentially useful decision addressing the Montrose “known loss” language in ISO Form CGL policies. In Clarendon National Insurance Company v. Philadelphia Indemnity Insurance Company,[1] the court applied this language to allow denial of defense for claims of recurring water infiltration that began before the insurer’s policy period, and it found an insurer had no duty to investigate whether the course of property damage might have been interrupted, or whether other property damage might have occurred during the policy period, so as to trigger coverage during a later policy. In the underlying dispute, a condominium owner (Doherty) asserted negligence claims against her association’s property management company (Lundgren) stemming from alleged water infiltration into her condominium. The complaint said leaks developed in 2004 in the roof above Doherty’s unit, and repairs were not made in a timely or appropriate manner. The following year, the complaint said, a Lundgren employee notified Doherty that the threshold leading to her condominium's deck was rotting. In February 2006, Doherty discovered a mushroom and water infiltration on the threshold and notified Lundgren. At that time, Lundgren asked its maintenance and repair contractor (CBD) to replace the rotting threshold. According to the complaint, CBD did not do this repair in a timely manner and left debris exposed in Doherty’s bedroom. In March 2006, the complaint said, a mold testing company hired by Lundgren found hazardous mold in Doherty's unit, caused by water intrusions and chronic dampness. Lundgren’s attempts at remediation were ineffectual. In September 2008, Doherty's doctor ordered her to leave the condominium and not to return until the leaks were repaired and mold was eliminated. Reprinted courtesy of Eric B. Hermanson, White and Williams and Austin D. Moody, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Alarm Cries Wolf in California Case Involving Privette Doctrine

May 06, 2019 — Garret Murai - California Construction Law Blog
It’s one of the most quoted phrases in legal history: “Shouting fire in a [crowded] theater.” It comes from the U.S. Supreme Court’s landmark 1919 decision in Schenck v. U.S. and has come to stand for the proposition that not all speech, in particular dangerous speech, is protected by the First Amendment. The next case also involves a false alarm. But not of the First Amendment kind. In Johnson v. The Raytheon Company, Inc., California Court of Appeal for the Second District, Case No. B281411 (March 8, 2019), a false alarm investigated by maintenance engineering staff led to a Privette Doctrine claim against a property owner when a ladder on which the maintenance staff was standing slipped on wet flooring. Johnson v. Raytheon Lawrence Johnson worked as a maintenance engineer for ABM Facilities Services, Inc. ABM was hired by Raytheon Company, Inc. to staff the control room at one of Raytheon’s facilities in Southern California. Among other things, control room staff monitored water cooling towers owned by Raytheon to ensure that the water in the cooling towers were maintained at minimum levels. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

April Rise in Construction Spending Not That Much

June 28, 2013 — CDJ STAFF
April saw an increase in construction spending that didn’t even break a half of a percent with just a 0.4% increase, although that’s better than March’s slight decrease of 0.8%, Both government and residential construction spending dropped, although government spending dropped only 1.2% and residential a miniscule 0.1%. This was slightly more than offset by the modest 2.2% increase in residential spending. Although the April gains were modest, they come after the first year to increase after five years of decline. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES