Fairfield Connecticut Building Expert Directory

Point Taken: The UK Supreme Court Finally Confirms the General Law of Liquidated Damages (LDs)

April 04, 2022 — Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2Gavel Construction & Real Estate Law Blog
In a long-awaited decision which overturned the Court of Appeal’s ruling in the Triple Point Technology vs PTT Public Company case, the UK Supreme Court confirmed the general law of LDs, which is that—absent clear words to the contrary—they accrue up to the date of termination of a contract regardless of whether the contractor completes the work; after that, general damages are recoverable. This approach was held to reflect “commercial reality and the accepted function of liquidated damages.” Although the contract in question was not a construction contract, the decision is equally relevant in the construction sphere. By way of reminder, Triple Point failed to complete the works under Phase 1 of a contract for the design, installation, maintenance and licencing of software. Despite agreeing a revised project plan, PTT gave notice to terminate. Reprinted courtesy of Vincent C. Zabielski, Pillsbury and Julia Kalinina Belcher, Pillsbury Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Attorneys Fees Under California’s Prompt Payment Statutes. Contractor’s “Win” Fails the Sniff Test

October 02, 2015 — Roger Hughes – California Construction Law Blog
This past month, the California Court of Appeals for the Third District, in James L. Harris Painting & Decorating, Inc. v. West Bay Builders, Inc., Case No. C072169 (August 27, 2015), handed down a decision in a construction contract battle that has raged since 2007. And, once again, the winner is . . . in the words of Justice Andrea Lynn Hoch who authored the opinion . . . . “no prevailing party in [the] case” and hence “no prevailing party attorney’s fees [ ] awarded.” Background In Harris, subcontractor James L. Harris Painting & Decorating, Inc. (“Harris”) sued general contractor West Bay Builders, Inc. (“West Bay”) for extra work performed on a school construction project in Stockton, California. Among its claims, Harris asserted that West Bay was liable under California’s prompt payment statutes for failure to timely pay Harris. Read the court decision
Read the full story...
Reprinted courtesy of Roger Hughes, Wendel Rosen Black & Dean LLP
Mr. Hughes may be contacted at rhughes@wendel.com

National Lobbying Firm Opens Colorado Office, Strengthening Construction Defect Efforts

January 05, 2017 — Beverley BevenFlorez-CDJ STAFF
Michael Best Strategies, a national law and lobbying firm, has recently opened an office in Colorado. According to the Denver Business Journal, the firm “has recruited several big-name associates — a move that could give business leaders even more clout with the Legislature on issues such as construction-defects reform.” One of the firm’s recruits, Jeff Thormodsgaard, the lead lobbyist in the recent movement to make it harder to sue condominium builders, told the Denver Business Journal, “The only change [in the construction-defects reform effort] is that we’re going to be adding more feet and more boots on the ground and more gravitas.” Read the court decision
Read the full story...
Reprinted courtesy of

Chinese Drywall Manufacturer Claims Product Was Not for American Market

October 22, 2013 — CDJ STAFF
Taishan Gypsum Co. Ltd. Claimed in a hearing at the Fifth Circuit Court of Appeals that when they sold about $8.5 million of contaminated drywall to Venture Supply Inc. of Virginia, that they had no awareness that the drywall would be sold in the United States. Joe Cyr, an attorney for Taisan told the court that “Venture Supply never said it was going to distribute the goods in Virginia.” One of the judges on the three-judge panel, Judge Jennifer Walker Elrod, was skeptical of Taishan’s claim, asking, “it was packed and labeled for the Virginia market, isn’t that correct?” When asked by a judge if Taishan was trying to avoid accountability, Cyr said that Tiashan “has not said that it doesn’t want to be accountable for its drywall.” Taishan holds the position that claims against it should be arbitrated in the People’s Republic of China. Read the court decision
Read the full story...
Reprinted courtesy of

Denial of Coverage For Bodily Injury After Policy Period Does Not Violate Public Policy

May 12, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Rhode Island Supreme Court agreed that the insurer had no coverage obligations for bodily injury occurring after the policy had been canceled. Hoesen v. Lloyd's of London, 2016 R.I. LEXIS 41 (R.I. March 24, 2016). The plaintiff, Mark Van Hoesen, was seriously injured on July 23, 2012, when he fell from a deck of his house. He sued his contractor, Brian Leonard, alleging that the deck had been negligently constructed. Lloyd's, Leonard's insurer, was later named as a defendant. Lloyd's admitted it issued the policy to Leonard, but it was cancelled on August 29, 2007. Even if it had not been canceled, the policy had expired long before the injuries alleged in plaintiff's complaint occurred. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Cal/OSHA’s Toolbox Has Significantly Expanded: A Look At Senate Bill 606

December 13, 2021 — Michael J. Studenka - Newmeyer Dillion
Governor Gavin Newsom recently signed into law Senate Bill 606, set to take effect on January 1, 2022. With proponents of the bill citing the need to hold large employers accountable for COVID-related workplace hazards, SB 606 creates two new categories of employer violations. First, SB 606 creates a rebuttable presumption that if a type of violation is discovered at one particular worksite, Cal/OSHA can extrapolate that the violation is an “enterprise-wide” violation at all of the other company worksites. Additionally, SB 606 adds a new category of “egregious violations” to Cal/OSHA’s arsenal, adding a penalty multiplier for such violations. Finally, SB 606 increases Cal/OSHA’s investigative capabilities by authorizing Cal/OSHA to issue a subpoena to employers should they fail to “promptly provide” information requested during an investigation. As further explained below, the consequences of violating Cal/OSHA regulations has become significantly greater and more expensive, particularly for larger employers with multiple worksites. ENTERPRISE-WIDE VIOLATIONS AND THE SEVERE REMEDIES THAT FOLLOW Under SB 606, employers with more than one worksite will now face a rebuttable presumption that a violation at one location is actually “enterprise-wide” if either of the following are true:

A written policy or procedure violates any Cal/OSHA standard, rule, order or regulation; OR
Cal/OSHA finds evidence of a “pattern or practice” of the same violation being committed by the employer at one or more of its worksites.

Read the court decision
Read the full story...
Reprinted courtesy of Michael J. Studenka, Newmeyer Dillion
Mr. Studenka may be contacted at michael.studenka@ndlf.com

Home Prices Up in Metro Regions

October 30, 2013 — CDJ STAFF
Housing prices in the largest metro regions beat expectations, rising 12.8% in August as compared to a year before. Analysts were expecting weaker increases; instead these have been the fastest increases in seven years. The metropolitan area with the largest increase was Las Vegas, where houses increased in price by 29.2%. Three California regions — San Francisco, Los Angeles, and San Diego — also saw increases of greater than 20%. Read the court decision
Read the full story...
Reprinted courtesy of

2018 Legislative Changes Affecting the Construction Industry

June 06, 2018 — Melinda S. Gentile - Peckar & Abramson
The 2018 Florida Legislative Session recently concluded and a number of important construction-related House Bills (HB) and Senate Bills (SB) were presented during the Session. Florida Governor Rick Scott has 15 days to act on the legislation once each Bill has passed the House and Senate. Bills signed by the Governor go into effect on July 1, 2018, unless indicated otherwise. These Bills may impact General Contractors and Construction Managers in a number of ways, not the least of which is the period of time that a cause of action may be initiated for the design, planning or construction of an improvement. Read the court decision
Read the full story...
Reprinted courtesy of Melinda Gentile, Peckar & Abramson
Ms. Gentile may be contacted at mgentile@pecklaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES