Fairfield Connecticut Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Zoning Hearing Notice Addressed by Georgia Appeals Court

April 20, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
The Georgia Court of Appeals recently addressed the requisite notice of zoning proceedings that ultimately requested in a zoning decision. The key question was whether, after a properly noticed planning meeting, additional notice was required before the board’s formal vote that occurred three months later. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Appeals Court Overruled Insured as Additional Insured on Subcontractor’s Commercial General Liability Policy

April 02, 2014 — Beverley BevenFlorez-CDJ STAFF
Scott R. Murphy and Clifford J. Shapiro of Barnes & Thornburg LLP in the publication National Law Review analyzed the findings of the Mississippi case Carl E. Woodward, LLC v. Acceptance Indemnity Insurance: “the U.S. Court of Appeals for the Fifth Circuit overruled the district court’s determination that a general contractor was insured as an additional insured on its subcontractor’s commercial general liability (CGL) policy for claims arising out of the allegedly defective work performed by the subcontractor.” “This case underscores the fact that many standard policy forms do not include completed operations coverage for additional insureds,” Murphy and Shapiro declared. “Owners and contractors that desire to have such coverage therefore need to check their contracts to be make sure the contract language requires completed operations coverage for additional insureds, and they also need to obtain and review the actual additional insured endorsement contained in their subcontractors’ insurance policies before work commences to make sure that the required completed operations insurance coverage is provided.” Read the court decision
Read the full story...
Reprinted courtesy of

Unjust Enrichment and Express Contract Don’t Mix

August 23, 2021 — Christopher G. Hill - Construction Law Musings
I am a huge fan of clearly written construction contracts. Virginia state and federal courts will interpret contract provisions as written and will seek to enforce all of those terms where possible. Where the contract is ambiguous, we construction attorneys make money and the courts are forced to make decisions that the parties may not like. A recent case out of the Eastern District of Virginia federal court highlights the ways in which a clear contract affects the claims that can be brought and limits the scope of possible litigation. In First Call Environmental LLC v. Murphy Oil USA LLC, the Court looked at a relatively typical Owner, Contractor, Subcontractor set of agreements. In this matter, Murphy Oil entered a contract with National Rapid Response, Inc. (“NRR”) whereby NRR would provide emergency and environmental management and waste disposal services to Murphy Oil. NRR then subcontracted with the Plaintiff First Call to perform the services for Murphy Oil. First Call filed suit against Murphy Oil alleging two counts: breach of contract (based on a third-party beneficiary theory), and unjust enrichment. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Residential Contractors, Be Sure to Have these Clauses in Your Contracts

May 16, 2018 — Christopher G. Hill - Construction Law Musings
I have often “mused” on the need to have a good solid construction contract at the beginning of a project. While this is always true, it is particularly true in residential contracting where a homeowner may or may not know the construction process or have experience with large scale construction. Often you, as a construction general contractor, are providing the first large scale construction that the homeowner has experienced. For this reason, through meetings and the construction contract, setting expectations early and often is key. As a side note to this need to set expectations, the Virginia Department of Professional and Occupational Regulation (DPOR) and the Virginia General Assembly require certain clauses to be in every residential construction contract. DPOR strictly enforces these contractual items and failure to put them in your contracts can lead to fines, penalties and possibly even revocation of a contractor’s license. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Subcontractor Strength Will Drive Industry’s Ability to Meet Demand, Overcome Challenges

October 10, 2022 — Anwar Ghauche - Construction Executive
Owners, developers and general contractors get a lot of notoriety for construction projects, especially in these infrastructure-focused times. However, the subcontractor is truly the one under the microscope, as this group requires the most care and attention to ensure the owners and operators are able to meet accelerating demand and public expectations. The challenges in the current environment are many. Inflation and supply chain disruptions are highly detrimental to specialty trades in the mechanical, electrical, plumbing, drywall and other areas. Reports show that the construction industry, in particular, has seen an increase of over 20% in the cost of supplies and building materials in the last year alone and, in some cases, over 90% since the start of the pandemic. While these costs are passed along to the owner, the subcontractor still retains significant cash flow risk. This truth is amplified in a volatile market. As if the cost was not enough, equipment and material shortages coupled with rising interest rates only compound the problem—and tenfold for small businesses. Subcontractors are likely to feel the greatest pressure from supply-related issues. Inflation combined with supply chain shortages require subcontractors to prepare earlier for projects and, when possible, purchase materials upfront. However, the consequence of this preliminary preparation equates to further strains on cash flow. In an effort to remain aligned on schedules and budgets, subcontractors frequently buy all of a project’s materials as soon as a contract is signed—if not before. Reprinted courtesy of Anwar Ghauche, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Defects not Creating Problems for Bay Bridge

July 31, 2013 — CDJ STAFF
There might have been a number of problems with San Francisco’s new Bay Bridge, but despite all that, the Contra-Costa Times says that the experts say that there is no reason for panic. And although the chair of the Senate Transportation Committee, Mark DeSaulnier, has been a critic of the bridge, he says that he is “convinced the old bridge is unsafe.” Although DeSaulnier wants an independent review, construction of the bridge has been investigated by what the Times refers to as “dozens of internationally renowned bridge engineers and other experts.” According to the experts, the problems with the bridge fall in to three categories, ranging from the fixable, through the fixed, to those that were never actual problems. Of the last category, the Oakland Tribune reported in 2005 that construction workers claimed they were told to “conceal shoddy welds to speed up construction,” but the Federal Highway Administration outside experts found no evidence of bad welds. In another case, bad welds were discovered at the factory where a span was being constructed. The process was changed and the bad welds repaired. Caltrans has delayed the opening of the Bay Bridge to December 10. Earlier plans were to open the bridge in September. Read the court decision
Read the full story...
Reprinted courtesy of

Florida SB 2022-736: Construction Defect Claims

February 07, 2022 — Kelly A. Johnson - Saxe Doernberger & Vita, P.C.
*Special thank you to SDV Law Clerk Iliriana Fteja for contributing to this article. A new bill (SB 2022-736) was recently introduced to the Florida Senate. The proposed amendments to the statutes of limitations and repose could significantly impact construction defect claims by effectively creating additional exposure to contractors and insurance carriers. The proposed bill requires all actions founded on the design, planning, or construction of an improvement to real property to be commenced within four years after the time to commence an action begins. Under the proposed amendment, the time to commence an action runs from the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion of the contract or termination of the contract between the professional engineer, registered architect, or licensed contractor and their employer. This provision would effectively alter the time to commence an action to whichever triggering event is earliest instead of the latest triggering event per the previous statute. Read the court decision
Read the full story...
Reprinted courtesy of Kelly A. Johnson, Saxe Doernberger & Vita, P.C.
Ms. Johnson may be contacted at KJohnson@sdvlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES