Fairfield Connecticut Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

A Race to the Finish on Oroville Dam Spillway Fix

October 09, 2018 — Scott Blair - Engineering News-Record
The Lake Oroville spillway’s 400-acre construction site is an intense flurry of activity. In one corner, an excavator driver uses an old tire as a squeegee to clean away loose rock and prep a foundation. In the steeply sloping spillway chute, a crane operator flies in a rebar cage to workers who tie it into neighboring chute wall segments. Everywhere, dump trucks buzz around the circuitous roadways while rock crushers and batch plants keep pace with dozens of dozers and excavators. Drones hover in the sky photographing and surveying the site, while inspectors pour over every detail of the finished assets. Read the court decision
Read the full story...
Reprinted courtesy of Scott Blair, ENR
Mr. Blair may be contacted at blairs@enr.com

Cost of Materials Holding Back Housing Industry

June 28, 2013 — CDJ STAFF
As home building makes its recovery, there’s another hurdle to overcome: the cost of building materials. The Toledo Blade reports that the rise in the costs of materials makes homes built this year several thousands of dollars more expensive than those built last year. One builder, James Moline, said that he “ended up eating some of the lumber prices on a deal this spring because lumber prices went up so much.” The cost of framing lumber has increased by about two-thirds, while the cost of strand board has more than doubled. Happily, material costs seem to have hit their high and in recent months have started to lower. The rise, according to Robert Denk, a senior economist at the National Association of Home Builders, is due to suppliers cutting back on capacity when demand dwindled, and despite the increase in building starts, suppliers have yet to bring that capacity back. Read the court decision
Read the full story...
Reprinted courtesy of

Denver Airport's Renovator Uncovers Potential Snag

March 04, 2019 — Nadine M. Post - Engineering News-Record
The renovation of the Great Hall of Denver International Airport’s iconic Jeppesen Terminal, roofed by a series of peaked tensile tents that echo the nearby mountains, has hit a bump. Routine but limited concrete testing of the nearly quarter-century-old terminal’s elevated floor slab, to determine whether the floor could support crane loads, shows the compressive strength of the concrete in certain sections is lower than was specified for the original project, more than 25 years ago. Read the court decision
Read the full story...
Reprinted courtesy of Nadine M. Post, ENR
Ms. Post may be contacted at postn@enr.com

Voluntary Payments Affirmative Defense Does Not Apply in Contract Cases

July 16, 2023 — David Adelstein - Florida Construction Legal Updates
In certain matters, there is an affirmative defense referred to as the “voluntary payments” defense. This defense states, “where one makes a payment of any sum under a claim of right with knowledge of the facts such a payment is voluntary and cannot be recovered.” Avatar Properties, Inc. v. Gundel, 48 Fla.L.Weekly D1272c (Fla. 6th DCA 2023) quoting City of Miami v. Keton, 115 So.2d 547, 551 (Fla. 1959). This voluntary payments defense could be construed as a “gotcha” defense, right? Unfair! You voluntarily made the payment with knowledge of the facts; therefore, you are s**t out of luck when it comes to recovering the potentially wrongful payment. Well, guess what? This voluntary payments affirmative defense does NOT apply in contract disputes. This is codified by Florida Statute s. 725.04 which states: “When a suit is instituted by a party to a contract to recover a payment made pursuant to the contract and by the terms of the contract there was no enforceable obligation to make the payment or the making of the payment was excused, the defense of voluntary payment may not be interposed by the person receiving payment to defeat recovery of the payment.” Fla.Stat. s. 725.04. See also Avatar Properties, supra (explaining voluntary payment defense does not apply in contract cases and even in non-contract cases it doesn’t apply if payment made under coercion or compulsion). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Contract Language and Insurance Coverage Must Be Consistent

July 30, 2015 — Craig Martin – Construction Contract Advisor
How often do you review both the additional insured language in the contract and the insurance policy provided by a subcontractor? My guess is, unless the project has gone off the rails, NEVER. Well, perhaps you should to make absolutely sure the extent of the subcontractor’s insurance obligations and whether those obligations are being fulfilled. This point was recently addressed in a recent DRI article analyzing the Deepwater Horizon/BP lawsuit. My partner, Anne Marie O’Brien, also blogged on this a few months ago. As you will recall, Transocean’s Deepwater Horizon oil-drilling rig exploded, killing 11 workers, and polluted the Gulf of Mexico. BP demanded that Transocean’s insurer pay for the loss. Transocean’s insurer said no, and the litigation ensued, in state court, federal court, and the Texas Supreme Court. It was quite an odyssey of litigation. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Colorado Passes Construction Defect Reform Bill

June 05, 2017 — David Suggs – Bert L. Howe & Associates, Inc.
According to Daniel E. Evans of Gordon & Rees Scully Mansukhani, Colorado’s state legislature recently passed a bill “designed to reduce litigation risk associated with building condos by requiring a majority of actual condo unit owners, as opposed to a majority of the HOA board members, to approve the filing of a lawsuit over construction defects.” Evans stated that this “legislation cannot be viewed as sweeping reform” and that “future legislative sessions will undoubtedly see additional efforts to reform construction defect litigation.” Perhaps the most significant aspect of HB 1279 is the requirement for a majority of condo owners in a development to approve a lawsuit, Evans reported. Furthermore, HB 1279 “requires the HOA board to notify all condo unit owners and builders about plans to pursue a construction lawsuit. It further requires the HOA board to hold a meeting to allow the board and the developer to present facts and arguments to the individual condo unit owners, including arguments of the potential benefits and detriments of filing a lawsuit.” Unlike its failed predecessors, HB 1279 does not require arbitration. Read the court decision
Read the full story...
Reprinted courtesy of

Washington Supreme Court Finds Agent’s Representations in Certificate of Insurance Bind Insurance Company to Additional Insured Coverage

February 03, 2020 — Jason Taylor - Traub Lieberman
In T-Mobile USA Inc. v. Selective Ins. Co. of Am., 450 P.3d 150 (Wash. 2019) the Washington Supreme Court addressed whether an insurance company is bound by its agent’s written representation—made in a certificate of insurance—that a particular corporation is an additional insured under a given policy. The question arose in a case where: (1) the Ninth Circuit had already ruled that the agent acted with apparent authority, but (2) the agent’s representation turned out to be inconsistent with the policy and (3) the certificate of insurance included additional text broadly disclaiming the certificate’s ability to “amend, extend or alter the coverage afforded by” the policy. According to the Court, under Washington law the answer is yes: an insurance company is bound by the representation of its agent in those circumstances. Otherwise, the Court reasoned, an insurance company’s representations would be meaningless and it could mislead without consequence. At the heart of this case were two T-Mobiles entities: T-Mobile USA and T-Mobile Northeast (“T-Mobile NE”), which were distinct legal entities. T-Mobile NE engaged a contractor to construct a cell phone tower on a rooftop in New York City. The contract between T-Mobile NE and the contractor required the contractor to obtain a general liability insurance policy, to annually provide T-Mobile NE “with certificates of insurance evidencing [that policy’s] coverage,” and to name T-Mobile NE as an additional insured under the policy. T-Mobile USA was not a party to the contract, but was nonetheless aware of it and approved the contract as to form. The contractor obtained the required insurance policy from Selective. The policy provided that a third party would automatically become an “additional insured” under the policy if the contractor and the third party entered into their own contract that required the contractor to add the third party to its insurance policy as an additional insured. Because T-Mobile USA did not have a contract with the contractor, it did not automatically become an additional insured under the policy. Nevertheless, over the course of several years, Selective’s agent issued a series of certificates of insurance to “T-Mobile USA Inc., its Subsidiaries and Affiliates” that stated that those entities were “included as an additional insured [under the policy] with respect to” certain areas of coverage. The agent signed those certificates as Selective’s “Authorized Representative.” Read the court decision
Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES