Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor
September 09, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project.
In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Rebuilding the West: Construction Considerations After the Smoke Clears
December 21, 2020 —
Richard Glucksman & Ravi Mehta – Chapman Glucksman Dean & RoebWildfires have always been a part of life in the western United States, but, in recent years, the frequency and size of wildfires have become staggering. Oregon, Washington, and—in particular—California face drier conditions, making wildfire season longer and more intense.
In these states, among others, prescribed burns (designed to reduce wildfire ignition sources and spreading potential) have been limited or cancelled altogether as the air pollution emitted by these burns may worsen the impact of COVID-19, a respiratory illness in its essence, as noted recently by
Science magazine. These circumstances, further compounded by the severe shortage of housing, have created a “perfect storm” in California, which has seen new and denser construction deeper within wildfire-prone areas, prompting a number of key legislative proposals that will impact the rebuilding process after the smoke clears.
The infamous 2018 Camp Fire in northern California made international headlines for decimating the town of Paradise. While the cause of the Camp Fire was determined to be faulty electrical transmission equipment, unusually dry conditions allowed the fire to spread to just over 150,000 acres, and the fire took 17 days to contain.
Then, five of the 20 largest wildfires in California history occurred during the 2020 wildfire season, according to the California Department of Forestry and Fire Protection (Cal Fire). The Camp Fire was eclipsed by the August 2020 Complex Fire, which is the largest wildfire ever recorded in the state, growing to just over one million acres in size until it was finally contained on Nov. 15.
Legislative Response
The Camp Fire and other 2018 wildfires displaced hundreds of thousands of people from their homes throughout California. The unprecedented scale of both the 2018 and the 2020 wildfire seasons in California has spurred legislators in Sacramento to draft a number of important bills that will undoubtedly impact rebuilding efforts.
California AB 38 was prompted by the 2018 California wildfire season and was signed into law by Gov. Gavin Newsom in October 2019. It requires the state fire marshal, the Office of Emergency Services, and Cal Fire to work together to develop and administer a comprehensive wildfire mitigation program, including "cost-effective structure hardening and retrofitting to create fire-resistant homes, businesses, and public buildings."
Unfortunately, the well-intentioned program has yet to be funded, and may be relying on federal hazard funds from the Federal Emergency Management Agency at a future date. In light of the crippling economic impact of the COVID-19 pandemic, federal funding is likely the only viable source for this important item of legislation.
California SB 182 would enact new building regulations in high fire-risk areas (as determined by the state fire marshal), including new standards for fire-resistive construction, evacuation routes, defensible space, and available water and firefighting resources. It would also prohibit municipalities from approving new construction in high fire-risk areas unless wildfire reduction standards are satisfied. In effect, the bill would discourage new construction in high fire-risk areas.
After passing through both legislative houses, Newsom vetoed the bill, citing its negative impact on the state's strained supply of affordable housing. However, the bill is likely to be revisited in the 2020-2021 legislative session.
California AB 1516 is a comprehensive bill that would:
- Create new defensible-space requirements for both new and existing construction in high fire-risk areas.
- Create a grant-assistance program for fire-prevention education, inspections, and technical assistance.
- Direct Cal Fire to develop vegetation management recommendations to minimize flammability.
Additionally, the bill would allow insurers providing course of construction coverage for a project to request, from the owner, municipal certification that the structure to be built complies with existing and new building standards. Newsom vetoed this bill, cautioning that a "one size fits all" approach to wildfire management may not be appropriate, given that each individual community's needs differ.
California AB 2380 focuses on the development of standards and regulations for a relatively new and growing phenomenon: the rising use of private firefighting personnel, particularly by wealthy homeowners. Several prominent and well-known carriers offer homeowners-insurance policies that provide for private firefighting personnel, as well as preventative services (wildfire hazard inspections and clearing defensible space), and expected post-incident services (clean up and removal of fire retardant and similar substances).
AB 2380 was signed into law by Newsom at the tail end of the 2018 wildfire season, and it now requires Cal Fire, the governor's Office of Emergency Services, and the board of directors of the FIRESCOPE Program (designed to coordinate firefighting resources among different agencies) to develop standards and regulations for privately contracted fire fighters.
Housing Shortage and New Construction
These legislative efforts are underscored by the worsening housing crisis, which has both strained existing supply and increasingly pushed new construction into areas known as the Wildland Urban Interface (WUI).
WUI areas are designated as either "interface" or "intermix:” Interface WUI areas have little to no wildland vegetation, but are near large wildlands. By contrast, in intermix WUI areas, structures are mixed with wildland vegetation.
A recent study by the U.S. Forest Service found that, as expected, WUI areas are the hardest hit by wildfires. However, the study also found that, contrary to popular belief, wildfires cause greater damage in interface WUI areas than intermix WUI areas- in other words, wildfire damage is greatest where there is little to no wildland vegetation. The study concludes that wildfires in WUI areas are fueled more by human-made fuels as opposed to natural vegetation. These human-made fuels include building materials and landscaping.
It may not come as a surprise that a growing body of scientific literature has ascribed more severe and frequent wildfires to climate change. However, what may be less appreciated is the profound impact of building in the WUI. By 2050, an estimated one million new homes are projected to be built in California WUI areas.
In light of this, as well as the recognition that wildfire risk is determined, in large part, by construction standards and the fire resistivity of materials as opposed to natural vegetation, California has developed a special building code for WUI areas: Chapter 7A of the California Building Code- Materials and Construction Methods for Exterior Wildfire Exposure. California is one of the few states to have a unique building code for WUI areas, and, in light of the recent wildfires, California officials are developing stricter WUI building standards.
The constituents of State Sen. Bill Dodd in Napa County and surrounding areas have faced some of the state's most devastating wildfires. Dodd is at the forefront of significant fire-related legislation, and was responsible for the passage of the Insurance Adjuster Act of 2019, which sets regulations for insurance-claim adjusting in emergencies.
Dodd also spearheaded the passage of SB 190, which was enacted in late 2019. The law requires, among other things, the state fire marshal to develop suitable materials and products for building in WUI areas with respect to exterior wall siding and sheathing, exterior windows, doors and skylights, vents, decking, treated lumber and ignition-resistant materials, and roofing materials. The state fire marshal's office found that roofing material is among the most important factors in a structure's fire resistivity, and slate, metal, and tile roofs have the highest fire resistance rating of "A:”
As of July 1, 2021, wood-shake roofs will no longer be allowed by the California Fire Code. The state fire marshal also cites non-combustible siding as an important building element.
Wildfire-Resistant Construction
A recent study prepared by Headwaters Economics and commissioned by the U.S. Forest Service, WR Foundation, and Insurance Institute for Business & Home Safety analyzed cost differentials between traditional construction and wildfire-resistive construction as they relate to the four most fire-critical assemblies of a structure: roofs, exterior walls (including windows and doors), decks, and landscaping. Wildfire-resistant roofing, vents, fascia, and gutters were estimated to cost about 27 percent more than traditional components. However, the wildfire-resistant roofing materials feature lower maintenance requirements and longer lifespans.
Wildfire-resistant exterior walls were estimated to cost 25 percent less than traditional components, due in large part to the substitution of true wood siding with fiber cement siding.
Wildfire-resistant decking involves the use of composite boards, foil-faced bitumen tape on support joists, and the creation of non-combustible space beneath decking. This type of construction was estimated to cost approximately 19 percent more than traditional decking construction. Wildfire-resistant landscaping has the most significant cost difference as compared to traditional landscaping construction, with the former costing about double the latter. Landscaping fabric can minimize the growth of weeds and thus reduce fire hazard, as does the use of rocks instead of mulch.
While certain components of fire-resistant construction may have increased costs, the benefits far outweigh these increases: longer life cycles and less maintenance of the components, and, most importantly, greatly increased fire resistivity of the structure itself and thus its life cycle.
As construction in WUI areas is expected to grow substantially in the coming years, so too are fire-resistive construction standards and material requirements. These standards and requirements are part and parcel of a more comprehensive and deliberate set of land use planning, vegetation management, and emergency-response regulations and policies that California will develop by necessity to meet the growing demand for housing in WUI areas, and also to rein in the staggering costs of wildfire suppression. Thus, construction in WUI areas, and, to a lesser degree, in non WUI areas, will be subject to more exacting standards in the years to come.
As the science of wildfire prevention and suppression advances, so too will the technological innovations that will allow for safer, longer-lasting and ecologically sensitive construction. As in many other fields, California is expected to emerge as a leader in wildfire resistant building and material requirements, and will undoubtedly play a key role in shaping fire policy throughout the United States.
Richard Glucksman is a partner, and Ravi Mehta is senior counsel, at Chapman Glucksman Dean & Roeb. rglucksman@cgdrlaw.com; rmehta@cgdrlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Exploring the Future of Robotic Construction with Dr. Thomas Bock
November 06, 2023 —
Aarni Heiskanen - AEC BusinessIn
this episode of the AEC Business podcast, host Aarni Heiskanen interviews Dr. Thomas Bock, a renowned expert in construction robotics. With 45 years of experience in the field and multiple books on the topic, Thomas shares his insights and expertise.
Tune in to learn more about his professional journey and the advancements in construction robotics.
An unconventional professional journey
Thomas’s journey in construction robotics began when he built his own house as a student. The labor-intensive process led him to explore the potential of robotics in construction. He studied civil engineering and architecture simultaneously, gaining a multidisciplinary understanding of the field. His interest in robotics grew when he saw the first welding robot at a Daimler-Benz factory in Stuttgart. This encounter sparked his curiosity and led him to question why robots couldn’t be used for assembling walls and buildings.
The Illinois Institute of Technology (IIT) in Chicago was one of Thomas’s destinations during his journey. There he studied under professors who had worked on iconic architectural projects. He also learned about Japanese companies like Toyota and Sekisui, which were producing houses using innovative methods. Intrigued by these advancements, Thomas secured a scholarship to study in Japan, where he discovered that the country was ahead of what he had known in the United States.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Construction Contracts Need Amending Post COVID-19 Shutdowns
October 19, 2020 —
Richard P. Higgins - Construction ExecutiveNo one could have expected the coronavirus pandemic in the beginning of 2020. True, there were rumblings about a sickness in China that was highly contagious and infecting many people. Death tolls began rising as the world watched in disbelieve. After all, this is 2020. This is not supposed to happen. We should have been able to control the spread of the virus, but we could not. COVID-19 quickly spread throughout the world causing havoc and economic despair.
While some sectors of the construction industry are not as impacted as others, contractors industry-wide need to consider how COVID-19 will impact their contractual obligations. Depending on what happens and what the government decides to do to stop the spread of the coronavirus, project delays, supply chain distributions, lost productivity and work stoppages may continue for months. All of this will impact the contracts that contractors have with owners. Contractors may not be able to preform according to the terms of the contract through no fault of their own. Owners may no longer qualify for the financing needed to pay for the project.
FORCE MAJEURE
According to Investopedia, “force majeure refers to a clause that is included in contracts to remove liability for natural and unavoidable catastrophes that interrupt the expected course of events and prevent participants from fulfilling obligations.”
Reprinted courtesy of
Richard P. Higgins, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Higgins may be contacted at
Richard.Higgins@MCC-CPAs.com
Lenders and Post-Foreclosure Purchasers Have Standing to Make Construction Defect Claims for After-Discovered Conditions
October 10, 2013 —
W. Berkeley Mann, Jr. — Higgins, Hopkins, McLain & Roswell, LLCThe Colorado Court of Appeals has decided a case which answers a question long in need of an answer: do banks/lenders have standing to assert construction defect claims when they receive title to a newly-constructed home following a foreclosure sale or deed-in-lieu of foreclosure? The decision was released on August 1, 2013, in the case of Mid Valley Real Estate Solutions V, LLC v. Hepworth-Pawlack Geotechnical, Inc., Steve Pawlak, Daniel Hadin, and S K Peightal Engineers, Ltd. (Colorado Court of Appeals No. 13CA0519).
The background facts of the case are typical of a Colorado residential construction defect case generally. A developer contracted for an analytical soil engineering report from a geotechnical engineering firm (H-P) which made a foundation recommendation. The developer’s general contractor then retained an engineering firm (SPKE) to provide engineering services, including a foundation design. The general contractor built the foundation in accordance with the H-P and SPKE criteria and plans.
The house was not sold by the developer and went into default on the construction loan. These events resulted in a deed-in-lieu of foreclosure to a bank-controlled entity which purchased the house for re-sale. Shortly after receiving the developer’s deed, the bank-related entity discovered defects in the foundation that resulted in a construction defect suit against the two design firms and related individuals.
Read the court decisionRead the full story...Reprinted courtesy of
W. Berkeley Mann, Jr.W. Berkeley Mann, Jr. can be contacted at
mann@hhmrlaw.com
Just Because You Record a Mechanic’s Lien Doesn’t Mean You Get Notice of Foreclosure
September 15, 2016 —
Christopher G. Hill – Construction Law MusingsAs longtime (or new readers for that matter) know, mechanic’s liens are near and dear to my heart here at Construction Law Musings. These powerful tools to collect for your hard work on a construction project are great when prepared and recorded in the very specific fashion required by the Virginia legislature and courts. In most situations, if done properly, a mechanic’s lien gives you some security and priority for your construction claim that you would not have with a simple judgment lien.
Despite the power of a properly perfected and enforced mechanic’s lien (and the fact that the end result of a full mechanic’s lien suit that remains unsettled is in fact a foreclosure), a recent case in the Eastern District of Virginia, Weinberg v. J.P. Morgan Chase, et. al., (thanks for the head’s up on this case to the folks at the Construction Payment Blog) held that under Virginia statute mechanic’s lien holders are not entitled to notice of foreclosure. In the Weinberg case, the plaintiff, a pro se lien claimant that recorded two different liens, one pre-foreclosure and one post-foreclosure, and who had not received notice of the intervening foreclosure, argued, among other things, that he should have been given notice of the foreclosure on the deed of trust on the property by J. P. Morgan Chase.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
How the Science of Infection Can Make Cities Stronger
November 13, 2023 —
Carlo Ratti & Michael Baick - BloombergEarlier this year, a group of European researchers published a study with a scorching conclusion: As climate change makes heat waves more prevalent across the continent, the city most vulnerable to excess heat deaths is not a warm southern metropolis, but the relatively cool city of Paris.
Why? In part, the reason is that historically hotter cities have developed adaptations for dealing with extreme heat, from the shady architecture of Palermo to the siestas of Madrid. That leaves Paris at the bottom of a deadly learning curve.
This is just one urgent example of why cities need to talk. The world has an incredible stockpile of effective urban policies, but the best ideas are not being adopted quickly or widely enough. Covid-19 taught us all how to slow the spread of viruses: wear masks, avoid large gatherings and take vaccines. To speed the spread of good ideas, we need to take the opposite tack by making urban solutions go viral.
Reprinted courtesy of
Carlo Ratti, Bloomberg and
Michael Baick, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Defining Construction Defects
February 04, 2013 —
CDJ STAFFJoseph M. Junfola has started a series at PropertyCasualty360.com on construction defect, and as is appropriate with an in-depth look, he starts by defining the central terms. What is a construction defect? What is a construction defect claim?
Junfola notes that "there is no one uniform definition in all jurisdictions," and so he looks at the commonalities to "fashion at least a working definition." Nevada says that a construction defect "includes a defect in the design, construction, manufacture, repair or landscaping of a new residence, of an alteration of or an addition to an existing residence, or of an appurtenance." According to Florida it is "a deficiency in, or a deficiency arising of, the design, specifications, surveying, planning, supervision, observation of construction, or construction, repair, alteration, or remodeling of real property."
He continues that a construction defect claim is "a claim for damages, i.e. money, arising out of a defect in construction, including defective design, faulty workmanship, and defective materials," but he notes that this is typically pursuant to the discovery of the problem within a given time.
Read the court decisionRead the full story...Reprinted courtesy of
