California Expands on Scope of Coverage for Soft Cost Claims
February 14, 2023 —
Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage.
The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project.
As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.Ms. Rabiyan may be contacted at
CRabiyan@sdvlaw.com
Liquidated Damages Clause Not Enforced
October 02, 2023 —
David R. Cook Jr. - Autry, Hall & Cook, LLPA liquidated-damages clause was not enforced in a recent case before the Georgia Court of Appeals. The clause did not contain standard provisions that would normally allow a trial court to enforce the clause as written. As a result, the trial court looked beyond the contract to determine whether the City satisfied the requirements for enforcement of the liquidated-damages clause. Below are the relevant excerpts.
City of Brookhaven v. Multiplex, LLC, A23A0843, 2023 WL 4779591 (Ga. Ct. App. July 27, 2023)
Here, the Contract provides for “Liquidated Damages at the rate of $1,000.00 per calendar day” in the last paragraph of the Scope of Work addendum. The Contract lacks, however, any language indicating that the liquidated damages were not intended to be a penalty. See Fuqua Const. Co. v. Pillar Dev., Inc., 293 Ga. App. 462, 466, 667 S.E.2d 633 (2008) (rejecting use of parol evidence where the parties “explicitly agreed” in “unambiguous contract language” that the liquidated damages were not a penalty). Absent such language, the court can look to parol evidence in the record to determine the effect the provision was intended to have. See J.P. Carey Enterprises, 361 Ga. App. at 391-392 (1) (b), 864 S.E.2d 588 (looking to “extrinsic evidence” such as emails, documents, and deposition testimony to determine whether the damages provision at issue was a penalty); see also Gwinnett Clinic, Ltd. v. Boaten, 340 Ga. App. 598, 602-603, 798 S.E.2d 110 (2017) (“Shah’s testimony also suggested that one purpose of the liquidated damages provision was to deter employees from breaching the agreement”).
Read the court decisionRead the full story...Reprinted courtesy of
David R. Cook Jr., Autry, Hall & Cook, LLPMr. Cook may be contacted at
cook@ahclaw.com
New Jersey Supreme Court Ruled Condo Association Can’t Reset Clock on Construction Defect Claim
September 20, 2017 —
David Suggs – Bert L. Howe & Associates, Inc.The New Jersey Law Journal reported that New Jersey Supreme Court “justices reversed an Appellate Division ruling that found three suits filed against contractors by the Palisades at Fort Lee Condominium Association on various dates in March and April 2009 and September 2010 were within the six-year limit because the association received notice of construction defects in the building in an engineer's report issued in June 2007.”
The justices stated that the statute of limitations is not reset when property changes hands: "An owner of a building cannot convey greater property rights to a purchaser than the owner possessed. If the building's owner knew or reasonably should have known of construction defects at the time of the sale of the property, the purchaser takes title subject to the original owner's right—and any limitation on that right—to file a claim against the architect and contractors."
Read the court decisionRead the full story...Reprinted courtesy of
ASCE Statement on House Passage of the Water Resources Development Act of 2024
August 05, 2024 —
Marsia Geldert-Murphey, P.E., President of the American Society of Civil EngineersWASHINGTON — The American Society of Civil Engineers (ASCE) commends the House of Representatives for passing H.R. 8812, the bipartisan Water Resources Development Act (WRDA) for 2024. The House WRDA 2024 bill will help improve America's ports and inland waterways, enhance flood risk management and storm risk reduction programs, and prioritize ecosystem restoration. While we urge the Senate to swiftly vote on its version of WRDA, we are encouraged that our nation's critical water resources infrastructure remains a congressional priority.
The House version of WRDA includes several key provisions to enhance the safety of America's dams and levees, which each received a 'D' on the 2021 Report Card for America's Infrastructure, as well as provisions to modernize the nation's inland waterways system, which received a 'D+' in the 2021 Report Card. This includes one of ASCE's top legislative priorities for this year, the reauthorization of the National Dam Safety Program through 2028. But beyond the reauthorization, this bill reduces restrictions on the amount of funds states can receive in National Dam Safety Program State Assistance Grants; improves access to the High Hazard Potential Dam Rehabilitation Grant Program; and requires the incorporation of low-head dams into the National Inventory of Dams. Each of these provisions are critical to ensuring the long-term safety of our nation's dams and ASCE applauds the House for their inclusion. Furthermore, ASCE was pleased to see that the House legislation extends the National Levee Safety Program through 2033, which will help support the establishment of state levee safety programs, develop and publish national guidelines for levee safety, and enhance flood protection nationwide.
While these measures are not included in the Senate version of WRDA, we encourage lawmakers to ensure they are included in a final conference version of the bill.
We thank the House of Representatives for moving forward WRDA 2024 and strongly encourage the Senate to pass its version so that Congress can keep this vital water resources legislation on a biennial schedule and ensure our nation's dams, levees, ports, and inland waterways can support the American economy and protect public safety.
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 160,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
Read the court decisionRead the full story...Reprinted courtesy of
Haight Welcomes Robert S. Rucci
August 26, 2015 —
Robert S. Rucci – Haight Brown & Bonesteel LLPHaight Brown & Bonesteel LLP welcomes new partner Robert S. Rucci. Mr. Rucci joins Haight’s San Diego office in the Construction Law, General Liability and Risk Management & Insurance Law Practice Groups. For 25 years, Mr. Rucci has specialized in defending design professionals, businesses and their employees in addition to representing clients against declaratory relief, breach of contract and bad faith litigation. During his career, he has tried 60 cases to defense verdict and successfully resolved countless matters via mediation, arbitration and settlement conference. His extensive litigation experience is invaluable to our clients.
Haight Brown & Bonesteel LLP
402 West Broadway
Suite 1850
San Diego, CA 92101
www.hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Robert S. Rucci, Haight Brown & Bonesteel LLPMr. Rucci may be contacted at
rrucci@hbblaw.com
Flint Water Crisis and America’s Clean Water Access Failings
June 28, 2021 —
Pam Radtke Russell - Engineering News-RecordGrowing up on a Navajo reservation in Arizona, Jay Yazzie, now a senior environmental engineer at Brown and Caldwell, did not have running water in his home. To get its water supply, the family would take a 55-gallon drum to a livestock well or to a distribution point to obtain potable water for everyday use. He was 10 when his family was finally hooked up to a reliable supply.
Reprinted courtesy of
Pam Radtke Russell, Engineering News-Record
Ms. Russell may be contacted at Russellp@bnpmedia.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Construction Law Alert: Builder’s Alternative Pre-litigation Procedures Upheld Over Strong Opposition
April 01, 2014 —
Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel, LLPLast week, the Court of Appeal, Fifth Appellate District, was tasked with evaluating the enforceability of provisions in home purchase contracts containing alternative pre-litigation procedures which differ from the standard Right to Repair Act procedures. The Court of Appeal, in McCaffrey v. Superior Court of Fresno, et al. ultimately upheld the contractual provisions, and in overturning the trial court's decision, preserved the rights of builders to contract around certain requirements set forth in the Right to Repair Act.
The McCaffrey Group, Inc. constructed single-family homes in a Fresno development. Plaintiffs consisted of 24 homeowners within the development who brought suit against McCaffrey for construction defects in their homes. The homeowners were comprised of three categories: (1) the original purchasers who bought their homes from McCaffrey before January 1, 2003 and had a 2001 version of McCaffrey's contract; (2) the original purchasers who bought their homes from McCaffrey on or after January 1, 2003 and signed a 2003 version of McCaffrey's contract; and (3) the subsequent purchasers who did not buy their homes directly from McCaffrey, but purchased their homes subject to either the 2001 or 2003 version of McCaffrey's home purchase agreement.
Reprinted courtesy of
Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and
Whitney L. Stefko, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Must Defend Where Possible Continuing Property Damage Occurred
January 13, 2017 —
Tred R. Eyerly - Insurance Law HawaiiThe California Court of Appeal overturned the trial court's issuance of summary judgment based upon the possibility of continuing property damage during the insurer's policy period. Tidwell Enters. v. Fin. Pac. Ins. Co., 2016 Cal. App. LEXIS 1038 (Cal. Ct. App. Nov. 29, 2016).
Financial Pacific insured Greg Tidwell, Tidwell Enterprises, Inc. and Tidwell Enterprises Fireplace Division (Tidwell) under CGL policies issued between March 2003 and March 2010. In 2006 or 2007, Tidwell installed a fireplace in a home. On November 11, 2011, 20 months after the end of the last policy period of Financial Pacific's coverage, the home owned by Kendall Fox, was damaged by fire. Fox was insured by State Farm. State Farm's attorney advised Tidwell of the fire, and Tidwell forwarded the information to Financial Pacific.
State Farm hired an investigator who reported that the fire was caused by the installation of an "unlisted shroud at the top of the chimney chase". This prevented the fireplace from drafting properly, resulting in overheating of the fireplace and heat transfer to the surround wood framing members. This resulted in the ignition of the framing members at the sides, top and bottom of the fireplace. State Farm sent the report to Financial Pacific.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
