Fairfield Connecticut Building Expert Directory

Beyond Inverse Condemnation in Wildfire Litigation: An Oregon Jury Finds Utility Liable for Negligence, Trespass and Nuisance

July 10, 2023 — Marisa Miller, John Yacovelle & Kazim Naqvi - Sheppard Mullin
On June 10, 2023, a jury in Portland, Oregon found PacifiCorp and Pacific Power (collectively, “PacifiCorp”) liable for negligence, trespass, and nuisance based on a series of four wildfires that occurred during Labor Day weekend in 2020. PacifiCorp prevailed against the plaintiffs on the claim of inverse condemnation. With respect to the tort-based claims, the jury awarded approximately $72 million in compensatory damages to 17 plaintiffs. The jury later found PacifiCorp liable for $18 million in punitive damages, or one quarter of the compensatory damages that the jury awarded to the 17 plaintiffs. The jury’s liability findings apply to a broader class of owners, whose damages will need to be individually proven in a yet-to-be defined second phase of proceedings. Post-verdict motion practice and appeals may affect the jury’s findings. Reprinted courtesy of Marisa Miller, Sheppard Mullin, John Yacovelle, Sheppard Mullin and Kazim Naqvi, Sheppard Mullin Ms. Miller may be contacted at mmiller@sheppardmullin.com Mr. Yacovelle may be contacted at jyacovelle@sheppardmullin.com Mr. Naqvi may be contacted at knaqvi@sheppardmullin.com Read the court decision
Read the full story...
Reprinted courtesy of

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Suit Limitation Provisions in New York

January 28, 2025 — Bill Wilson - Construction Law Zone
New York law generally enforces a contractual suit limitation that specifies a “reasonable” period of time (usually shorter than the applicable statute of limitations) within which an action must be commenced. The contractual suit limitation needs to be fair and reasonable, given the circumstances of each particular case. The New York Court of Appeals recently examined this precedent in the context of an insurance policy enforcing an insurance contract’s two-year suit limitation period in Farage v. Associated Insurance Management Corp., 2024 N.Y. Slip Op. 05875 (Nov. 26, 2024). In Farage, a Staten Island multi-unit apartment building was damaged in a fire. The plaintiff owner filed its full repair claim for damages with its insurer six years after the fire and four years after the expiration of the contractual limitation period. The insurer denied the claim. The plaintiff filed suit for breach of contract and breach of the covenant of good faith fair dealing. The insurer moved to dismiss the action based on the two-year limitation provision in the insurance contract. Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Investigators Eye Fiber Optic Work in Deadly Wisconsin Explosion

July 18, 2018 — Jeff Yoders – Engineering News-Record
A hole punched into a 4-in.-dia gas pipeline during fiber-optic line laying is blamed for an explosion that killed a 34-year-old fire captain and injured nine other people, including four firefighters, in downtown Sun Prairie, Wis., on July 10. The injured were treated at nearby hospitals and have since been released. Read the court decision
Read the full story...
Reprinted courtesy of Jeff Yoders, ENR
Mr. Yoders may be contacted at yodersj@enr.com

The Top 10 Changes to the AIA A201: What You Need to Know

May 24, 2018 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome back Melissa Dewey Brumback. Melissa is a construction law attorney with Ragsdale Liggett in Raleigh, North Carolina. Aside from the fact that she is a UNC grad and fan, she’s okay! In 2017, as it does every ten years, the American Institute of Architects (AIA) updated most of its standard form contract documents, including the A201 General Conditions. This cycle, the contract changes are evolutionary in nature, not revolutionary. Even so, it is crucial to know the changes to avoid making a fatal mistake that could cost you money on a construction project. In reverse order, the top 10 changes you need to know include: # 10: Differing Site Conditions Prior editions of the A201 provided that upon encountering differing site conditions, the Contractor was to promptly provide notice to the Owner and Architect, before the conditions are disturbed, and in no event later than 21 days after the conditions were first observed. A201–2017 shortens the time for notice from 21 to 14 days. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Ohio Supreme Court Holds No Occurence Arises from Subcontractor's Faulty Workmanship

January 09, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Ohio Supreme Court bucked the modern trend by finding that there was no coverage under CGL policy's the subcontractor's exception for faulty workmanship claimed against the insured. Ohio N. Univ. v. Charles Constr. Servs. 2018 Ohio LEXIS 2375 (Ohio Oct. 9, 2018). The University contracted with Charles Construction Services, Inc. to build a new luxury hotel and conference center on campus. After work was completed, the University discovered extensive water damage from hidden leaks that it believed were caused by the defective work of Charles Construction and its subcontractors. Repairs were made at the cost of $6 million. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Contractors Struggle with Cash & Difficult Payment Terms, Could Benefit From Legal Advice, According to New Survey

December 30, 2019 — Christopher G. Hill - Construction Law Musings
Guest Post Friday is back with a post from my pal Scott Wolfe. Scott is the founder and CEO of Levelset, which is used by thousands of contractors to make payments fast and easy. Scott, previously a construction attorney himself, founded Levelset to even the $1 trillion construction playing field, and is on a mission to make payments less stressful for contractors and suppliers across the globe. Getting paid in construction is slow, hard, and stressful, according to a survey conducted by Levelset & TSheets by Quickbooks that polled over 500 construction professionals. Half of the contractors surveyed complained that they did not get paid on time, which caused serious cash flow issues that negatively impacted their customer relationships and frequently forced them to dip into personal savings and lines of credit to keep their business afloat. View the 2019 Construction Payment Report here. Unfortunately, since the construction industry’s slow payment problems are well-documented, this sad reality isn’t too surprising. The findings, though, do demonstrate a massive cash crunch for the 1.5 million+ contractors in the United States, and underscores the importance of having legal help and counsel from a construction lawyer before, during, and after jobs. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Death, Taxes and Attorneys’ Fees in Construction Disputes

July 18, 2022 — Garret Murai - California Construction Law Blog
According to Benjamin Franklin there are two certainties in this world: Death and taxes. Let me humbly add a third if you’re ever involved in non-contingency civil litigation: Attorneys’ fees. As such, when it comes to legal disputes, sophisticated parties know that it’s not just about winning but the cost of winning. While winning is never certain – remember Poor Richard’s proverb above – what is certain is that it will most likely cost you to find out whether you’ve won or lost. That’s why the ability to recover (or at least threaten the recovery of attorneys’ fees – that’s a separate discussion altogether) in litigation and arbitration is so important. A few facts:

According to the National Center for State Courts (NCSC) in their 2013 report, Measuring the Cost of Civil Litigation: Findings From a Survey of Trial Lawyers, the median cost of litigation (i.e., attorneys’ fees) for contract disputes, of which most construction disputes would fall under, was $90,575 from case initiation through post-trial disposition.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES