Shifting the Risk of Delay by Having Float Go Your Way
July 05, 2021 —
Christopher J. Brasco & Matthew D. Baker - ConsensusDocsCritical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects.
Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency.
Reprinted courtesy of
Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and
Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP
Mr. Brasco may be contacted at cbrasco@watttieder.com
Mr. Baker may be contacted at mbaker@watttieder.com
Read the court decisionRead the full story...Reprinted courtesy of
Follow Up on Continental Western v. Shay Construction
March 28, 2012 —
Brady Iandiorio, Higgins, Hopkins, McLain & Roswell, LLCWriting in Construction Law Colorado, Brady Iandiorio revisits the case Continental Western v. Shay Construction. He promises to continue to follow cases dealing with Colorado HB 10-1394.
Recently the Court ruled on two Motions to Reconsider filed by Defendants Milender White and Shay Construction.
Procedurally, the Motions to Reconsider were ruled on by the Honorable William J. Martinez, because the day after the motions were filed the action was reassigned to Judge Martinez. In the short analysis of the Motion to Reconsider, the court leaned on Judge Walker D. Miller’s ruling on the summary judgment and his analysis of the (j)(5) and (j)(6) exclusions.
As a quick refresher regarding the grant of summary judgment, Judge Miller agreed with Continental Western’s argument that the asserted claims were excluded under the “damage to property” exclusion. The policy’s exclusions state: “(j) Damage to Property . . . (5) that particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the ‘property damage’ arises out of those operations; or (6) that particular part of any property that must be restored, repaired or replaced because ‘your work’ was incorrectly performed on it.” Judge Miller found that both exclusions (j)(5) and (6) applied to both Shay’s allegedly defective work.
Read the full story…
Reprinted courtesy of Brady Iandiorio of Higgins, Hopkins, McClain & Roswell, LLC. Mr. Iandiorio can be contacted at iandiorio@hhmrlaw.com.
Read the court decisionRead the full story...Reprinted courtesy of
Courts Favor Arbitration in Two Recent Construction Dispute Cases
November 21, 2018 —
Jason Plaza - The Subrogation StrategistRecent court decisions have signaled the courts’ proclivity to prefer arbitration over full-fledged litigation when provisions in construction contracts are called into question. While the courts recognize a party’s constitutional right to a jury trial, the courts also lean strongly towards resolving disputes via arbitration as a matter of public policy, especially if a construction contract carves out arbitration as an alternative to litigation.
In Avr Davis Raleigh v. Triangle Constr. Co., 818 S.E.2d 184 (N.C. App. 2018), the North Carolina Appeals Court reviewed the issue of whether the contracting parties selected binding arbitration as an alternative to litigation. The contract at issue was an AIA A201-2007 form document. Under the terms of the contract, the parties elected to arbitrate claims under $500,000 but to litigate claims over this amount. However, if there were several claims under $500,000 but the aggregate of all claims exceeded $500,000, then the contract implied that all claims would be arbitrated. Since the claims involved were an amalgamation of the two, the contracting parties disagreed about whether the arbitration provision would apply. The plaintiff interpreted this provision to mean litigation was mandatory when at least one claim exceeded $500,000 and that arbitration was mandatory when no single claim exceeded this amount. In contrast, the defendant interpreted this provision as meaning that when there were several claims worth less than $500,000 individually, but more than $500,000 aggregately, then all claims must be arbitrated. The trial court agreed with the plaintiff’s interpretation.
Read the court decisionRead the full story...Reprinted courtesy of
Jason Plaza, White & Williams LLP
U.S. Home Prices Rose More Than Estimated in February
May 07, 2015 —
Kathleen M. Howley – BloombergU.S. house prices rose more than economists estimated in February as the strongest labor market in seven years gives Americans the confidence to bid on property.
Prices climbed 0.7 percent on a seasonally adjusted basis from January, the Federal Housing Finance Agency said in a report Wednesday. The average economist estimate was for a 0.5 percent increase, according to data compiled by Bloomberg.
Housing demand is climbing as consumer confidence hovers close to an eight-year high. Sales of existing homes rose in March by the most in four years, the National Association of Realtors reported today. The number of U.S. households jumped by almost 2 million in 2014, according to data compiled by Bloomberg.
Read the court decisionRead the full story...Reprinted courtesy of
Kathleen M. Howley, BloombergMs. Howley may be contacted at
kmhowley@bloomberg.net
American Arbitration Association Revises Construction Industry Rules and Mediation Procedures
April 08, 2024 —
Dennis Cavanaugh & Larry Grijalva - Construction Law ZoneThe American Arbitration Association (AAA), one of the longest-standing and experienced alternative dispute resolution (ADR) administrators, has unveiled a significant update to its Construction Industry Rules and Mediation procedures. This update, last revised in 2015, became effective March 1, 2024. Changes to the AAA Construction Industry Rules are significant as these rules are incorporated by default in American Institute of Architects standard construction forms, which are widely used in the industry.
Advancements in remote access technology drive a substantial number of new changes. Others are designed to streamline the arbitrator appointment process and certain prehearing procedures and to make arbitration more cost-efficient by enhancing the arbitrator’s case management authority. Some of the more notable changes are:
Fast Track
F-1: The limit for cases eligible for AAA’s Fast Track Procedures has been increased from $100,000 to $150,000 so long as no claim or counterclaim exceeds that amount.
Reprinted courtesy of
Dennis Cavanaugh, Robinson & Cole and
Larry Grijalva, Robinson & Cole
Mr. Cavanaugh may be contacted at dcavanaugh@rc.com
Mr. Grijalva may be contacted at lgrijalva@rc.com
Read the court decisionRead the full story...Reprinted courtesy of
Housing-Related Spending Made Up Significant Portion of GDP in Fourth Quarter 2013
March 31, 2014 —
Beverley BevenFlorez-CDJ STAFFOn the Insights Blog of CoreLogic, Molly Boesel reported that “housing-related spending made up 17.4 percent of GDP in [the] fourth quarter [of] 2013,” according to the latest release by the Bureau of Economic Analysis.
The numbers published by the Bureau of Economic Analysis demonstrated “upward revisions in overall GDP and housing-related expenditures from the second estimate released in February 2014.”
Boesel explained how they determined the housing-related spending number: “To calculate the portion of domestic spending that is related to housing, we look at three expenditures from the release: residential investment (the construction of new single- and multi-family houses), spending on housing services (rent, owner’s equivalent rent and utilities) and spending on furnishings and durable goods. Together, these expenditures made up 17.4 percent of total real GDP in the fourth quarter of 2013, the same as this time a year ago and down from the high of 20.6 percent in the third quarter of 2005.”
Read the court decisionRead the full story...Reprinted courtesy of
Unlicensed Contractor Shoots for the Stars . . . Sputters on Takeoff
September 20, 2017 —
Garret Murai - California Construction Law BlogElon Musk . . .
Eccentric engineer.
Technology billionaire.
And, now, litigation bad ass.
Frequent readers of the California Construction Law Blog know that we’ve talked about the importance of being properly licensed when doing construction work and the risks to you if you don’t.
One California contractor recently found this out the hard way.
In Phoenix Mechanical Pipeline, Inc. v. Space Exploration Technologies Corp., California Court of Appeals for the Second District, Case No. B269186 (June 13, 2017), contractor Phoenix Mechanical Pipeline, Inc. (Phoenix) lost its boosters . . . err britches . . when it sued Elon Musk’s Space Exploration Technologies Corp. (Space X) due to its failure to have a California contractor’s license.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
PA Superior Court Provides Clarification on Definition of CGL “Occurrence” When Property Damage Is Caused by Faulty Building Conditions
September 30, 2019 —
Anthony L. Miscioscia & Konrad R. Krebs - White and Williams LLPThe standard for an “occurrence” under a commercial general liability (CGL) insurance policy has been addressed on several occasions by Pennsylvania courts when an insured has allegedly performed faulty workmanship on a construction project. Specifically, in Pennsylvania, a claim for damages arising from an insured’s performance of faulty workmanship pursuant to a construction contract, where the only damage is to property supplied by the insured or worked on by the insured, does not constitute an “occurrence” under the standard commercial general liability insurance policy definition. But what about the circumstance when the insured has failed to perform contractual duties where the claim is for property damage to property not supplied by the insured or unrelated to the service the insured contracted to provide? The Pennsylvania Superior Court recently addressed this question in Pennsylvania Manufacturers Indemnity Co. v. Pottstown Industrial Complex LP, No. 3489 EDA 2018, 2019 Pa. Super. 223, 2019 Pa. Super. LEXIS 729* (Pa. Super. 2019).
Pottstown Industrial Complex arose out of an underlying dispute between a landlord and a commercial tenant who had leased space to store its product inventory. The tenant alleged that the landlord was responsible under the lease for keeping the roof “in serviceable condition in repair.” Notwithstanding this responsibility, the tenant alleged that the landlord failed to properly maintain and repair the roof, resulting in leaks and flooding during four separate rainstorms, destroying over $700,000 in inventory. The tenant specifically alleged that the floods were caused by poor caulking of the roof, gaps and separations in the roofing membrane, undersized drain openings, and accumulated debris and clogged drains.
The insurer filed a declaratory judgment action, seeking a determination that there was no coverage under a commercial general liability policy issued to the landlord. Following a motion for judgment on the pleadings, the trial court entered an order in favor of the insurer, holding that allegations of inadequate roof repairs were claims for faulty workmanship and were not covered under Kvaerner Metals Division of Kvaerner U.S., Inc. v. Commercial Union Insurance Co., 908 A.2d 888 (Pa. 2006) and Millers Capital Insurance Co. v. Gambone Brothers Development Co., 941 A.2d 706 (Pa. Super. 2007).
Reprinted courtesy of
Anthony Miscioscia, White and Williams LLP and
Konrad Krebs, White and Williams LLP
Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com
Mr. Krebs may be contacted at krebsk@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
