New York Federal Court Enforces Construction Exclusion, Rejects Reimbursement Claim
August 03, 2020 —
Eric D. Suben - Traub LiebermanIn Crescent Beach Club, LLC v. Indian Harbor Insurance Company, 2020 WL 3414697 (E.D.N.Y. June 22, 2020), the district court considered application of a CGL policy issued to a property owner containing the following exclusion:
"This policy does not apply to any ‘bodily injury’, ‘property damage’, ‘personal and advertising injury’, or any other loss, cost, defense fee, expense, injury, damage, claim, dispute or ‘suit’ either arising out of, or related to, any construction, renovation, rehabilitation, demolition, erection, excavation or remedition [sic] of any building and includes planning, site preparation, surveying or other other [sic] construction or development of real property. This exclusion, however, shall not apply to routine maintenance activities."
Plaintiff in the underlying action alleged injury while engaged in construction work at the insured’s premises. The information the insurer received was conflicting as to whether plaintiff was demolishing a pergola (excluded) or merely removing vines (not excluded). The insurer reserved its rights accordingly.
At his deposition in the underlying action, the plaintiff testified he was in a manlift performing demolition at the time he was injured. The insured’s property manager also testified that the pergola was being demolished. Approximately one month after the depositions, the insurer denied coverage based on the exclusion.
Read the court decisionRead the full story...Reprinted courtesy of
Eric D. Suben, Traub LiebermanMr. Suben may be contacted at
esuben@tlsslaw.com
OSHA’s Multi-Employer Citation Policy: What Employers on Construction Sites Need to Know
September 09, 2019 —
Phillip C. Bauknight - Construction ExecutiveMulti-employer worksites are a frequent occurrence in the construction industry as employees from various companies often occupy the same site while a project is being completed. While the need for employees from different companies may be necessary to perform the various tasks required by a project, the presence of multiple employers, and their employees, on the same worksite can result in an increased risk of safety hazards.
Companies performing construction work should be, and generally are, aware of OSHA’s ability to issue citations for workplace safety violations. What many companies may not know, however, is that OSHA’s ability to cite employers is not limited to workplace conditions that are unsafe only to that employer’s direct employees. Rather, OSHA also has the ability to cite an employer, and often does issue such citations, for conditions that could result in injury or death to another company’s employees.
The policy which provides OSHA with this citation ability is CPL 02-00-124 and is called the Multi-Employer Citation Policy (the “Policy”). Under the language of the Policy, OSHA has the ability to cite multiple employers for violations of the Occupational Safety and Health Act for the same hazardous workplace condition. Critically, responsibilities under the Policy do not depend on the employer’s job title but are determined by the employer’s role.
Reprinted courtesy of
Phillip C. Bauknight, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Bauknight may be contacted at
pbauknight@fisherphillips.com
Contractors: Revisit your Force Majeure Provisions to Account for Hurricanes
September 14, 2017 —
David Adelstein - Florida Construction Legal UpdatesWe now know and can appreciate the threat of hurricanes. Not that we did not appreciate the reality of hurricanes–of course we did–but Hurricane Harvey and Hurricane Irma created the type of actual devastation we fear because they hit close to home. The fear came to life, creating panic, anxiety, and uncertainty. It is hard to plan for a force majeure event such as a hurricane because of the capriciousness of Mother Nature. But, we need to do so from this point forward. No exception! And, I mean no exception!!
A force majeure event is an uncontrollable event that cannot be anticipated with any degree of definitiveness. The force majeure event will excusably delay or hinder performance obligations under a contract. One type of force majeure event is a hurricane—an uncontrollable and unforeseen act of Mother Nature.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Contractor’s Burden When It Comes to Delay
October 26, 2020 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:
When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.
Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Fifth Circuit -- Damage to Property Beyond Insured’s Product/Work Not Precluded By ‘Your Product/Your Work Exclusion’
January 24, 2022 —
Anthony L. Miscioscia & Marianne Bradley - White and Williams LLPOn January 11, 2022, the United States Court of Appeals for the Fifth Circuit issued its decision in Siplast, Incorporated v. Employers Mutual Casualty Company, 2022 U.S. App. LEXIS 795 (5th Cir. Jan. 11, 2022), finding that an insurer had a duty to defend its insured in a construction defect case where the underlying complaint alleged damage to property beyond the product and work of the insured.
Siplast, Inc. (Siplast) had contracted with the Archdiocese of New York (the Archdiocese) to install a roof membrane system at a high school in the Bronx, New York. Id. at *1. As part of the contract, Siplast guaranteed that the roof membrane system would remain in a watertight condition for at least twenty years. Id. at *2. If it did not, Siplast would repair the roof membrane system at its own expense. Id.
Several years after the installation, the Archdiocese observed water damage in the ceiling tiles at the high school. Id. The Archdiocese contacted Siplast, who attempted to repair the damage and prevent further leaks; however, leaks and resultant damage continued to occur. Id. Siplast subsequently refused to make any more improvements to the roof. Id.
Reprinted courtesy of
Anthony L. Miscioscia, White and Williams LLP and
Marianne Bradley, White and Williams LLP
Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com
Ms. Bradley may be contacted at bradleym@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Amada Family Limited Partnership v. Pomeroy: Colorado Court of Appeals Expressly Affirms the Continuing Viability of the Common-Law After-Acquired Title Doctrine and Expressly Recognizes Utility Easements by Necessity
June 28, 2021 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn May 27, 2021, a division of the Colorado Court of Appeals issued its opinion in Amada Family Limited Partnership v. Pomeroy, 2021 COA 73. In that case, the court decided two significant issues that apparently had never been expressly ruled on by a Colorado appellate court before: (1) that Colorado’s common-law after-acquired title doctrine was not abrogated by adoption of the after-acquired interest statute; and (2) that utility easements may be implied by necessity.
As is often the case in matters involving access and implied property rights, the facts and history underlying Amada are complicated, but the case’s two most significant rulings are not. Instead, the basic legal principles established (or confirmed) in Amada appear to be broadly applicable, and real property practitioners should take note of these significant developments (or clarifications) in the law.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Judge Rejects Extrapolation, Harmon Tower to Remain Standing
November 07, 2012 —
CDJ STAFFCityCenter has filed an emergency motion asking the Nevada Supreme Court to intervene in Judge Elizabeth Gonzalez’ order that the building’s defects cannot be extrapolated from those tested. CityCenter’s structural engineering expert “evaluated 397 of the Harmon’s critical structural elements and found all but one defective,” according to the article on Vegas.Inc. Judge Gonzalez would not permit this to be extrapolated to the untested 1,072, as the locations tested were not random.
Judge Gonzalez also ruled that if CityCenter does additional testing, they may not appeal her order that ruled the extrapolation inadmissible. CityCenter argued to the Nevada Supreme Court that “the notion that CityCenter should be forced to incur additional millions of dollars in testing costs and sanctions – on the condition that it waive its right to appeal this ruling – just to be permitted to present its own damages evidence, shocks the conscience.”
Gonzalez gave the okay to CityCenter to demolish the building, but its demolition would make any further testing impossible. Under Gonzalez’ ruling, the untested structural elements cannot b assumed to be defective.
Read the court decisionRead the full story...Reprinted courtesy of
CGL Policy Covering Attorney’s Fees in Property Damage Claims
December 11, 2018 —
David Adelstein - Florida Construction Legal UpdatesDoes a CGL policy cover attorney’s fees and costs in property damages claims, to the extent there is a contractual or statutory basis to recover attorney’s fees? Naturally, you need to review the policies and this is not a clear-cut issue, but there is law to argue under.
A case I have argued in support of CGL policies providing for coverage for attorney’s fees as a component of property damage claims when there is a contractual or statutory basis is Assurance Co. of America v. Lucas Waterproofing Co., Inc., 581 F.Supp.2d 1201 (S.D.Fla. 2008). In this case, the following applied:
- The policy provided coverage for “those sums that the insured becomes legally obligated to pay as damages of… ‘property damage’….
- Property damage was defined as “physical injury to tangible property, including all resulting loss of use of that property.”
- The term damage, in of itself, was not defined in the policy.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
