Fairfield Connecticut Building Expert Directory

Carolinas Storm Damage Tally Impeded by Lingering Floods

October 09, 2018 — Jim Parsons & Tom Sawyer - Engineering News-Record
As October rolls in, slow-moving flood crests and sluggish drainage persisting weeks after the passage of Hurricane Florence are leaving large eastern areas in the affected states too inundated for accurate damage assessments. The extent of damage is still largely uncalculated. In some cases, it’s believed to be worsening. Reprinted courtesy of Jim Parsons, Engineering News-Record and Tom Sawyer, Engineering News-Record Mr. Parsons may be contacted at sawyert@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

Zombie Foreclosures Plaguing Various Cities in the U.S.

July 16, 2014 — Beverley BevenFlorez-CDJ STAFF
Many homeowners are simply abandoning their homes before banks have completed the foreclosure process, according to USA Today. Banks are not always in a hurry to take ownership of property, and often will wait until they are ready to dispose of it before doing so: “There are two primary things that can factor into their decision," Eric Eckardt, vice president and general manager of Hubzu.com, told the Mail Tribune. "One, they may have a surplus of REO properties they're trying to move off the balance sheet. The second is, costs associated with foreclosure may be greater than the value. At the end of the day, it's really a case-by-case matter.” USA Today reported that “[t]he length of the entire foreclosure process is a major contributor to vacancy rates because homeowners are more likely to give up on their homes the longer they have to wait for a resolution.” These abandoned homes may have a negative impact on sales of neighboring homes, according to the Mail Tribune. Gary Poulos, a retired Harry & David systems engineer, lives next door to a ‘zombie foreclosure,’ and spent a year trying to get maintenance work completed on the neighboring property so that he could be in a position to sell his own. He created a blog about his experience (myneighborchasebank.blogspot.com). Big Builder analyzed May 2014 data from CoreLogic, and identified the five states with the highest foreclosure inventory: New Jersey, Florida, New York, Hawaii, and Maine. While the five states with the lowest foreclosure inventory were Alaska, Nebraska, North Dakota, Wyoming, and Minnesota. Read the full story, USA Today... Read the full story, Big Builder... Read the full story, Mail Tribune... Read the court decision
Read the full story...
Reprinted courtesy of

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Sales of New Homes in U.S. Increased 5.4% in July to 507,000

August 26, 2015 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. rebounded in July, bolstering signs the real-estate market is picking up. Sales climbed 5.4 percent, the biggest gain this year, to a 507,000 annualized pace from a 481,000 rate in the prior month, a Commerce Department report showed Tuesday in Washington. The median forecast of 75 economists surveyed by Bloomberg called for 510,000. Demand had declined 7.7 percent in June. Demand for new properties is likely to keep expanding amid strong employment, low borrowing costs and a lack of available existing homes from which to choose. The improving outlook may spur more residential construction, contributing to the economic expansion in the second half of the year. Read the court decision
Read the full story...
Reprinted courtesy of

Nomos LLP Partner Garret Murai Recognized by Best Lawyers®

September 18, 2023 — Garret Murai - California Construction Law Blog
Nomos LLP Partner Garret Murai has been recognized by Best Lawyers® in its 30th edition of The Best Lawyers in America® in the area of Construction Law for 2024. This is the the first year Garret has been recognized by Best Lawyers®. Reprinted courtesy of Garret Murai, Nomos LLP Mr. Murai may be contacted at gmurai@nomosllp.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Breaking the Impasse by Understanding Blame

January 13, 2020 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday (on a Thursday) here at Construction Law Musings, Victoria Pynchon (@vickiepynchon) joins us for the 4th time. Victoria is an attorney-mediator with ADR Services, Inc. in Century City; an arbitrator with the American Arbitration Association in Los Angeles, California; and, a negotiation consultant and trainer world-wide. Victoria co-founded She Negotiates Training and Consulting in 2010 and writes for ForbesWoman at its She Negotiates blog. She is the author of one of my favorite books on conflict resolution, A is for A*@!#, the Grownups’ ABC’s of Conflict Resolution reviewed at Musings here. First Let’s Talk About Anger Please raise your hand if your clients — corporate clients — are angry about the burdens of litigation. Irritated with the document “demands” and interrogatories. Frustrated about the e-discovery. Ticked off at the way opposing counsel asks them questions as if they’re lying. Hot under the collar about the mounting attorneys’ fees and the distance between the day suit was filed and the probable day on which a trial might eventually be scheduled. Simmering about the time the litigation consumes, time they’d prefer to be spending doing their actual jobs — planning for and implementing business strategies for a profitable future instead of fighting about the unprofitable past. And we’re not even talking about your clients’ anger at the defendant who has stolen their intellectual property or stopped worked at the construction site or refused to release the remaining funds in the construction loan account. And if you believe that powerful people in highly successful and profitable businesses do not fear that litigation might hurt their careers, think again. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

CA Court of Appeal Reinstates Class Action Construction Defect Claims Against Homebuilder

September 03, 2015 — Beverley BevenFlorez-CDJ STAFF
Laurence R. Phillips, Andrew S. Azarmi, and Stefani Warren of Dentons reported that “on August 19, the California Court of Appeal, Fourth District, reinstated a class action asserting construction defect claims against a nationwide homebuilder.” According to the article, the decision is significant because “it effectively opens the door to class claims against homebuilders (and potentially other service providers employed in the homebuilding industry) arising out of alleged construction defects on California residential development and construction projects.” The decision is unpublished, but “could signal a troubling trend for companies involved in the homebuilding industry in California. It is not yet clear whether the decision will be appealed to the California Supreme Court.” Read the court decision
Read the full story...
Reprinted courtesy of

TLSS Partner Burks Smith and Associate Katie Keller Win Summary Judgment on Late Reported Water Seepage Case in South Florida

November 18, 2019 — Burks A. Smith, III & Kathryn Keller - Traub Lieberman
On July 9, 2019, Traub Lieberman Straus & Shrewsberry LLP Partner, Burks A. Smith, III and Associate, Kathryn A. Keller, secured Summary Judgment on behalf of a major homeowners’ insurer in a breach of contract action in the United States District Court for the Southern District of Florida. See Lehrfield v. Liberty Mutual Fire Insurance Company, 2019 WL2994270 (S.D. Fla. 2019). The underlying claim involved a water loss at the Plaintiffs’ residence allegedly resulting in $91,147.32 worth of damage to their home. The claim was reported eight (8) months after the alleged date of loss, and during the inspection, the adjuster observed rot, decay, mold, and warping wood, prompting the carrier to deny the claim based on the Seepage Endorsement. The Plaintiffs filed a breach of contract action alleging that the insurer breached the Policy by denying the claim. Mr. Smith and Ms. Keller argued that Plaintiffs’ Policy with the insurer imposes a duty on the Plaintiffs to comply with the Duties After Loss conditions of the Policy, including the requirement to provide prompt notice of the loss and show the damaged property. As mentioned above, the Plaintiffs provided notice of the claim eight (8) months late, and performed various repairs prior to notifying the insurer of the claim. After the close of discovery, Mr. Smith and Ms. Keller filed a Motion for Summary Judgment on behalf of the insurer based on the late reporting, and further argued that the Plaintiffs had the burden of proving direct physical loss to property within the first 13 days of the loss, given the recent decision of Hicks v. American Integrity Insurance Company of Florida, 241 So.3d 925 (Fla. 3d DCA 1018). In Florida, when an insured fails to comply with their Duties After Loss, a presumption of prejudice to the insurer arises. Bankers Ins. Co. v. Macias, 475 So. 2d 1216, 1218 (Fla. 1985)). In order to recover, the Plaintiffs bear the burden of overcoming the presumption, and must prove that no prejudice existed. Id. Mr. Smith and Ms. Keller’s comprehensive arguments successfully proved to the Court that the Plaintiffs’ failure to timely report the claim prejudiced the insurer by prohibiting the insurer from being able to independently validate the loss, or distinguish between multiple causes of loss. Mr. Smith and Ms. Keller further argued that Plaintiffs did not meet their burden to prove that the insurer was not prejudiced by the Plaintiffs’ failure to comply with the Duties After Loss provision of the Policy. The Motion cited numerous cases and extensive analysis supporting the insurer’s position. Reprinted courtesy of Burks A. Smith, III, Traub Lieberman and Kathryn Keller, Traub Lieberman Mr. Smith, may be contacted at bsmith@tlsslaw.com Ms. Keller may be contacted at kkeller@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES