SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Indiana Court Enforces Contract Provisions rather than Construction Drawing Markings

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
Timothy J. Abeska, a vice-chair of Barnes & Thornburg LLP’s Construction Law Practice Group, analyzed Goodrich Quality Theaters, Inc. v. Fostcorp Heating and Cooling, Inc., 16 N.E.3d 426 (Ind. Ct. App. 2014), which “provides an example of a court enforcing contract provisions rather than markings on construction drawings that are inconsistent with contract requirements.” The case evolved from a dispute on a construction of an IMAX theater, when the general contractor did not understand the architect’s markings for non-standard joist girders, and ordered standard joist girders, per the contract. The error created delays and other problems, which led to payment disputes and mechanic’s liens against the project. Abeska stated that “[t]his case shows the importance of making sure all documents which comprise a construction contract are consistent with each other, as courts will enforce contracts negotiated by the parties. The case also demonstrates that litigation is not a quick process, as the Court of Appeals Opinion was issued more than seven years after the project was completed.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Bill to Include Coverage for Faulty Workmanship Introduced in New Jersey

December 04, 2013 — CDJ STAFF
On November 25, Gary S. Schaer, a Democrat from Bergen and Passic, introduced a bill into the New Jersey legislature that would require insurers to cover faulty workmanship. The bill would require commercial liability insurance policies to cover “property damage or bodily injury resulting from faulty workmanship.” Policies that do not provide this coverage could not be offered in the state of New Jersey should the measure pass and be enacted into law. Read the court decision
Read the full story...
Reprinted courtesy of

---

Loan Modifications Due to COVID-19 Pandemic: FDIC Answers CARES Act FAQs

May 11, 2020 — Nancy Sabol Frantz, Marissa Levy, Timothy E. Davis & Kristen E. Andreoli - White and Williams
In support of financial institutions and borrowers during the COVID-19 pandemic, the newly enacted Coronavirus Aid, Relief, and Economic Security Act (CARES Act) includes a number of provisions permitting lenders to suspend, during a covered period, requirements under U.S. Generally Accepted Accounting Principles (GAAP) with respect to categorizing certain loan modifications as a troubled debt restructuring (TDR) due to COVID-19. In light of the CARES Act, the Federal Deposit Insurance Corporation (FDIC) issued a series of answers to FAQs for financial institutions with respect to loan modifications. The FAQs help guide lenders as well as borrowers as they address pending defaults under existing credit facilities. The FAQs encourage financial institutions to work with borrowers who may be unable to meet their payment obligations due to COVID-19 in several ways: Payment Accommodations Short-term accommodations which modify, extend, suspend or defer repayment terms should be intended to facilitate the borrower’s ability to work through the immediate impact of the virus. According to the FAQs, all loan accommodation programs should ultimately be targeted towards repayment. To that end, the FDIC recommends that financial institutions address deferred or skipped payments by either extending the original maturity date or by making those payments due in a balloon payment at the maturity date of the loan. Reprinted courtesy of White and Williams attorneys Nancy Sabol Frantz, Marissa Levy, Timothy E. Davis and Kristen E. Andreoli Ms. Frantz may be contacted at frantzn@whiteandwilliams.com Ms. Levy may be contacted at levymp@whiteandwilliams.com Mr. Davis may be contacted at davist@whiteandwilliams.com Ms. Andreoli may be contacted at andreolik@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Traub Lieberman Attorneys Named 2019 Super Lawyers

November 04, 2019 — Traub Lieberman
Related Attorneys: Jonathan R. Harwood, Michael K. Kiernan, Michael S. Knippen, Meryl R. Lieberman, Christopher Russo, Scot E. Samis, Lisa L. Shrewsberry, Stephen D. Straus, Richard K. Traub, Cheryl P. Vollweiler, Brian C. Bassett, Jessica N. Kull, Jeremy S. Macklin, Dana A. Rice, Burks A. Smith, III, Jason Taylor Ten Traub Lieberman attorneys have been named 2019 Super Lawyers and seven named 2019 Rising Stars. The honored attorneys represent five of the firm's seven offices and nearly all of its service areas. Super Lawyers, a Thomson Reuters business, is a rating service of outstanding lawyers from more than 70 practice areas, who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. Read the court decision
Read the full story...
Reprinted courtesy of

---

The Irresistible Urge to Build Cities From Scratch

November 21, 2018 — Monte Reel - Bloomberg
Embedded in the cerebral folds of every city planner who’s ever lived, there’s a cluster of neurons that lights up like Las Vegas when confronted with the possibility of a blank slate. It started with Hippodamus, the man Aristotle claimed was the father of urban planning. When the Persians destroyed his hometown of Miletus, Hippodamus discovered a bright side to catastrophe: The attackers had erased all the regrettable improvisations that, over the centuries, had made a mess of the place. Tasked with rebuilding, he seized his chance to impose order upon chaos. And so the concept of the urban grid was born. Ever since, the dream of carte blanche has proved an all-but-irresistible seduction. Leonardo da Vinci drafted detailed sketches of an “ideal city” after the plague ravaged Milan, and a few hundred years later, Frank Lloyd Wright designed a metropolis that solved the problem of vehicular congestion via a network of helicopter taxis. Every so often, this urge in city planners breaks out into a full-scale epidemic, such as the one that spread throughout Europe and North America in the early 1900s. Known as the “garden city movement,” it aimed to counter the indignities of the Industrial Revolution by creating planned communities with plenty of green space. Read the court decision
Read the full story...
Reprinted courtesy of Monte Reel, Bloomberg

---

Coverage Denied for Insured's Defective Product

October 15, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court found there was no coverage obligations for the insured's defective product. Titanium Indus., Inc. v. Federal. Ins. Co., 2014 WL 4428324 (N.J. Super. Ct. App. Div. Sept. 10, 2014). The insured, Titanium Industries, supplied titanium bar materials to Biomet Manufacturing Corporation. Biomet manufactured orthopedic implants and devises. The titanium was used to manufacture screws to incorporate into Biomet's products. Biomet notified the insured of a potential defect in some of the titanium material, described as "alloy segregation," i.e., the failure of alloys in a metal to completely melt, causing the alloy to separate and undermine the strength of the finished product. The insured and Biomet negotiated a settlement, which included lost profits and the cost of returning the titanium. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Preparing For and Avoiding Residential Construction Disputes: For Homeowners and Contractors

September 18, 2023 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Construction Law Musings, we welcome a great friend. Scott Wolfe Jr. (@scottwolfejr)is a construction attorney in Louisiana, Washington and Oregon, and is the founding member of the construction practice Wolfe Law Group. He authors the Construction Law Monitor. He is also the founder of the mechanic lien and preliminary notice filing service, Zlien, and the author of its Construction Lien Blog. Residential construction disputes come in all shapes and sizes, but very typically have one thing in common: they can get very nasty. This is understandable, especially in today’s economy. The homeowner is spending hard-earned money on something very personal to them, their home. They want it done right. The contractor is working on really tight margins, and with a diligent client. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---