Fairfield Connecticut Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Idaho District Court Affirms Its Role as the Gatekeeper of Expert Testimony

March 15, 2021 — Melissa Kenney - The Subrogation Specialist
Many subrogation claims involving fire losses rely heavily on expert testimony. Expert testimony is admissible under Federal Rule of Evidence 702 if it is both relevant and reliable. In Daubert v. Merrell Dow Pharmaceuticals, Inc., 509 U.S. 579 (1993), whose standard has been incorporated into Federal Rule of Evidence 702, the Supreme Court instructed federal trial courts to act as a “gatekeeper” of expert testimony, giving them the power to exclude expert testimony that is not supported by sufficient evidence. In Maria Fernanda Elosu and Robert Luis Brace v. Middlefork Ranch Incorporated, Civil Case No. 1:19-cv-00267-DCN, 2021 U.S. Dist. LEXIS 14449 (D. Idaho Jan. 22, 2021) (Brace), the United States District Court for the District of Idaho exercised its gatekeeper role when it granted in part and denied in part the defendant’s motion to exclude expert testimony pursuant to Daubert and Federal Rule of Evidence 702. Brace, involved a fire at a vacation cabin in McCall, Idaho. The cabin, owned by Maria Elosu (Elosu) and Robert Brace (Brace and collectively with Elosu, Plaintiffs) was part of a homeowner’s association called Middlefork Ranch, Incorporated (MFR). The cabin had a “wrap around” deck with a propane-fired refrigerator on the north side. On the day before the fire, Brace stained the deck using an oil-based stain. That night, Elosu smoked cigarettes on the deck. The next morning, Plaintiffs used rags to clean up excess oil from the deck and an MFR employee changed the propane on the refrigerator and relit the pilot light. At 4:00 p.m., a fire started in or around the cabin while no one was home. The fire was discovered by a group of contractors who testified that the fire was isolated to the east side of the cabin when they first arrived. Importantly, one witness testified that there was no fire and no flames around the propane-fired refrigerator. The fire destroyed the cabin and the contents within. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Kenney, White and Williams LLP
Ms. Kenney may be contacted at kenneyme@whiteandwilliams.com

UK Construction Output Rises Unexpectedly to Strongest Since May

March 27, 2023 — Lucy White - Bloomberg
UK construction industry output grew for the first time in two months in February, boosting hopes that the economy may avoid a prolonged recession. A rebound in commercial and civil engineering work helped to compensate for continued gloom in the housing market, where buying activity has been depressed by higher mortgage rates and the cost-of-living crisis. The closely-watched Construction Purchasing Managers’ Index from S&P Global and the Chartered Institute of Procurement and Supply jumped to 54.6 in February, up from 48.4 a month earlier and the highest since May 2022. It was the first time in three months that activity was above the crucial no-change level of 50. Economists had expected a decline. Read the court decision
Read the full story...
Reprinted courtesy of Lucy White, Bloomberg

Unlicensed Contractors Nabbed in Sting Operation

September 09, 2011 — CDJ STAFF

The California State License Board charged sixteen people in the Fresno area with accepting contracting jobs without licenses. The Statewide Investigative Fraud Team of the CSLB set up a sting operation at a home in Clovis, California seeking bids on tree service, painting, and general contracting services. Those who bid for jobs at more than $500 are required under California law to be licensed. Unlicensed contractors can only work on jobs with a cost to the homeowner of less than $500 and must inform the homeowner that they are not licensed.

In addition to citing contractors for not possessing appropriate licenses, the CSLB also cited contractors for failure to carry workers compensation insurance and illegal advertising. Further, California law limits down payments to the lesser of ten percent or $1,000. Two contractors were cited for requesting excessive down payments.

One contractor, an unlicensed tree service contractor, had been cited previously in a sting operation. He failed to show up for his court date.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Homeowner’s Claims Defeated Because “Gravamen” of Complaint was Fraud, not Breach of Contract

September 29, 2021 — Garret Murai - California Construction Law Blog
Be careful what you wish for or, as in the next case, what you plead. In Vera v. REL-BC, LLC, Case Nos. A155807, A156823, and A159141 (June 30, 2021) 1st District Court of Appeal, a the buyer of a remodeled home who asserted breach of contract and fraud claims against a developer discovered that her claims, including her breach of written contract claim, was subject to a shorter 3 year statute of limitations because the “gravamen” of her complaint was fraud. The REL-BC Case Homeowner Adriana Vera purchased a remodeled home in Oakland, California from developers REL-BC, LLC and SNL Real Estate Solutions, LLC. The developers had purchased the home in July 2011, remodeled it, and sold it to Vera in November 2011. As is typical in such transactions, the purchase agreement for the house required that the sellers disclose known material facts and defects affecting the property. In their disclosure, the sellers stated that they were not aware of any significant defects or malfunctions with respect to the property. The disclosure also stated that the sellers were not aware of any water intrusion issues with respect to the property. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

New Jersey Supreme Court Hears Arguments on Coverage Gap Dispute

October 26, 2017 — Austin D. Moody - Saxe Doernberger & Vita, P.C.
On Tuesday, October 24, the New Jersey Supreme Court heard arguments in a 17-year-old battle over whether Honeywell International Inc. (Honeywell) will have to help cover the costs of asbestos-related injury suits that were filed against it after insurers began to universally exclude coverage for asbestos-related liabilities. The Court considered the arguments made by two excess insurers, St. Paul Fire and Marine Insurance Co. (St. Paul) and parent Travelers Casualty and Surety Co. (Travelers), that the Court should overturn a state appellate court’s ruling that Honeywell does not have to contribute to these costs. During the course of this case, Honeywell has sought coverage under more than 300 different policies, ultimately settling with all insurers except St. Paul and Travelers, who had issued a total of 10 excess policies to Honeywell’s predecessor, Bendix Corp. (Bendix) between 1968 and 1983. Honeywell has only sought coverage for claims made by individuals who allege that they were first exposed to asbestos prior to 1987. Read the court decision
Read the full story...
Reprinted courtesy of Austin D. Moody, Saxe Doernberger & Vita, P.C.
Mr. Moody may be contacted at adm@sdvlaw.com

Wilke Fleury Attorneys Featured in 2021 Best Lawyers in America and Best Lawyers: Ones To Watch!

August 16, 2021 — Wilke Fleury LLP
Wilke Fleury congratulates attorneys David Frenznick, Adriana Cervantes and Dan Egan on their inclusion in the 2021 Edition of Best Lawyers in America! Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 108,000 industry leading lawyers are eligible to vote (from around the world), and they have received over 13 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. For the 2021 Edition of The Best Lawyers in America©, 9.4 million votes were analyzed.

Daniel L. Egan

First year recognized in Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law: 2021

David A. Frenznick

First year recognized in Litigation – Real Estate: 2016

Adriana C. Cervantes

First year recognized in Medical Malpractice Law – Defendants: 2021

Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Fatal Boston Garage Demolition Leaves Long Road to Recovery

April 04, 2022 — Scott Van Voorhis - Engineering News-Record
Massachusetts' officials are bracing for a lengthy recovery process following the March 26 fatal collapse during demolition of a section of a hulking Brutalist-era parking garage in Boston. JDC Demolition was razing the Government Center structure to make way for a 410,000-sq-ft life-sciences complex, when a multistory portion near the top failed, killing 51-year-old operating engineer Peter Monsini. Reprinted courtesy of Scott Van Voorhis, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES