Fairfield Connecticut Building Expert Directory

“Based On”… What Exactly? NJ Appellate Division Examines Phrase and Estops Insurer From Disclaiming Coverage for 20-Month Delay

August 20, 2019 — Anthony L. Miscioscia and Timothy A. Carroll - White and Williams LLP
On May 28, 2019, the New Jersey Superior Court, Appellate Division examined the phrase “based on” in an assault-and-battery exclusion, finding that the phrase means “to make, form, or serve as the foundation of any claim, demand or suit.” C.M.S. Investment Ventures, Inc. v. American European Insurance Company, No. A-2056-17T3, 2019 N.J. Super. Unpub. LEXIS 1215, at *8-9 (N.J. Super. Ct. App. Div. May 28, 2019) (CMS). The CMS case is also notable because the Appellate Division held that a 20-month delay in disclaiming coverage was unreasonable and therefore warranted estoppel. In CMS, the insured was allegedly warned by its tenant about a faulty ground-floor window that failed to lock properly. Afterward, an intruder broke into the tenant’s apartment and sexually assaulted the tenant, who sued the insured on a premises liability claim. Before she filed suit, the tenant sought payment from the insured’s CGL insurer directly. The insurer denied coverage based on the assault-and-battery exclusion and closed the file, but never informed the insured. Later, the tenant sued the insured, which sought a defense and indemnity from its insurer, which again denied coverage based on the exclusion. The insured then sought a declaration of coverage on grounds that the exclusion was ambiguous, and the insurer “was estopped from denying coverage, because it waited [20] months to inform CMS of its coverage decision.” The trial court ruled in the insured’s favor which led to the appeal in CMS. Reprinted courtesy of Timothy Carroll, White and Williams LLP and Anthony Miscioscia, White and Williams LLP Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Mr. Carroll may be contacted at carrollt@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Payne & Fears LLP Recognized by U.S. News & World Report and Best Lawyers in 2023 “Best Law Firms” Rankings

November 28, 2022 — Payne & Fears LLP
Payne & Fears LLP is pleased to announce that the firm has been recognized by U.S. News & World Report and Best Lawyers 2023 “Best Law Firms” list. Firms included in the 2023 edition of U.S. News – Best Lawyers “Best Law Firms” are recognized for professional excellence with consistently impressive ratings from clients and peers. This includes the top 5% of private practicing lawyers in the United States. Payne & Fears LLP has been ranked in the following practice areas:

Commercial Litigation
Employment Law – Management
Insurance Law
Labor Law – Management
Litigation – Labor & Employment
Litigation – Real Estate
Litigation – Intellectual Property

Additionally, on August 15, 2022, 11 of our attorneys were selected for inclusion in The Best Lawyers in America® 2023. Collectively bringing decades of experience and dedication to their practice, Jeffrey K. Brown, Daniel F. Fears, Daniel M. Livingston, Thomas L. Vincent, Benjamin A. Nix, James L. Payne, Scott S. Thomas, and Kelby Van Patten received this respected achievement. Additionally, Leilani E. Jones, Sarah J. Odia, and Matthew C. Lewis were included in Best Lawyers: Ones to Watch 2023. Read the court decision
Read the full story...
Reprinted courtesy of Payne & Fears LLP

Seabold Construction Ties Demise to Dispute with Real Estate Developer

April 29, 2024 — Richard Korman - Engineering News-Record
When Harry W. Seabold, co-founder and CEO of Seabold Construction, died unexpectedly in January 2023 at age 69, the Beaverton, Ore.-based general contractor, which had been in business since 1984, kept chugging along for a year on two adjacent North Portland apartment projects. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

No Coverage for Negligent Misrepresentation without Allegations of “Bodily Injury” or “Property Damage”

February 10, 2012 — Tred R. Eyerly - Insurance Law Hawaii

Jeff City Industries was the general contractor for a sewer system improvement project in Branson, Missouri. Bituminous Cas. Corp. v. United HRB Gen. Contractors, Inc., 2011 U.S. Dist. LEXIS 145666 (W.D. Mo. Dec. 19, 2011). Branson sued Jeff City, alleging breach of the construction contract for the project. The claims included improperly bedded sewer piping, improper aligning portions of trenching for the sewer piping, improper service line connections to the sewer piping, etc.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

New Jersey Courts Speed Up Sandy Litigation

September 03, 2014 — Beverley BevenFlorez-CDJ STAFF
In order to deal with the thousand plus property damage cases related to Hurricane Sandy the “U.S. District Chief Judge Jerome Simandle of the District of New Jersey, who sits in Camden, N.J., issued a standing order dated Aug. 13 that, in effect, cuts in half the amount of time that arbitrators and mediators will have to hear disputes over coverage and issue rulings,” the New Jersey Law Journal reported. “John O’Brien, chief deputy of operations for New Jersey’s federal courts, said that, as of Wednesday, 1,240 Sandy-related lawsuits had been filed in New Jersey and that 1,051 of those cases are still pending,” according to the New Jersey Law Journal. “Sixty of those pending cases have been referred to mediation and another six have been sent to arbitration panels, according to O’Brien.” Read the court decision
Read the full story...
Reprinted courtesy of

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Planes, Trains and Prevailing Wages. Ok, No Planes, But Trains and Prevailing Wages Yes

October 25, 2021 — Garret Murai - California Construction Law Blog
The California Supreme Court doesn’t often delve into construction-related issues, but this year we’ve got two cases, both related to the payment of prevailing wages on California public works projects. The first, Mendoza v. Fonseca McElroy Grinding Co., Inc. (2021) 11 Cal.5th 1118 which we discussed in our last blog post, concerned whether mobilization work qualifies as a “public work” and in turn requires the payment of prevailing wages. On the same day that the Supreme Court issued its decision in Mendoza, it issued a decision in Busker v. Wabtec Corporation, et al. , Case No. S251135 (August 16, 2021). This is the equivalent of being struck by lightning twice. In Busker, the California Supreme Court considered whether on a public transportation project “field work” (e.g., building and outfitting radio towers on land adjacent to train tracks) and “onboard work” (e.g., installing electronic components on train cars and locomotives”) requires the payment of prevailing wage. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion

April 15, 2024 — Stu Richeson - The Dispute Resolver
This post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded. Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009). Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES