FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Another Colorado District Court Refuses to Apply HB 10-1394 Retroactively

October 28, 2011 —

In Martinez v. Mike Wells Construction Company, 09CV227, Teller County District Court Judge Edward S. Colt refused to apply C.R.S. § 13-20-808 retroactively to provide coverage for the underlying construction defect allegations. According to the recitation of facts in Judge Colt’s March 2011 order, Martinez contracted with Mike Wells Construction to serve as the general contractor for the construction of a home. At that time, Mike Wells Construction was insured through ProBuilders Specialty Insurance Company, RRG. Disputes arose between Martinez and Mike Wells Construction, resulting in Martinez ordering it off of the project in mid-November 2007 and terminating its right to work there by letter dated November 28, 2007.

Mike Wells, the owner of the corporation, subsequently died. Martinez sued Mike Wells Construction in July 2009 for breach of contract and various claims relating to alleged defecting workmanship. Martinez provided notice of the suit to the special administrator of the probate estate. No answer having been filed, the court entered a default judgment against Mike Wells Construction and Martinez sought to garnish Mike Wells Construction’s ProBuilders insurance policy.

Read the full story...

Reprinted courtesy of Higgins, Hopkins, McLain & Roswell, LLC. Mr. McClain can be contacted at mclain@hhmrlaw.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Mortgagors Seek Coverage Under Mortgagee's Policy

July 19, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The mortgagor homeowners survived a motion to dismiss their claim for coverageunder the lender's property policy after their home suffered hurricane damage. Gary v. Am. Sec. Ins. Co., 2021 U.S. Dist. LEXIS 100010 (W.D. La. May 26, 2021). Plaintiffs' home was mortgaged by Pennymac Loan Services, LLC. Pennymac held a property policy with American Security to insure its interest in the home. Plaintiffs were not named as insureds or additional insureds under the policy. Plaintiffs were identified as the borrowers under the policy on the Declarations page. After hurricane damage to their home, plaintiffs sued American Security for coverage for the losses. American Security moved to dismiss, arguing plaintiffs were neither additional insureds nor third party beneficiaries. Lender-placed policies were designed to insure the lender's collateral whenever the borrower failed to maintain adequate insurance. The Loss Payment provisions in the policy stated that "Loss will be made payable to the named insured [Pennymac]. No coverage will be available to any mortgagee other than that shown as the named insured on the Declarations." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Lessons from the Sept. 19 Mexico Earthquake

October 19, 2017 — Nadine M. Post - Engineering News-Record
On the 32nd anniversary of the magnitude-8.1 earthquake that devastated Mexico City on Sept. 19, 1985, 41 U.S. seismic experts were in a workshop near Los Angeles, polishing a new tool to identify “killer” buildings: non-ductile concrete structures that often perform poorly in quakes. Suddenly, the attendees started getting pager alerts from the U.S. Geological Survey: A magnitude-7.1 quake had struck about 120 kilometers from Mexico City. Read the court decision
Read the full story...
Reprinted courtesy of Nadine M. Post, ENR
Ms. Post may be contacted at postn@enr.com

---

BWB&O Partner Jack Briscoe and Associate Anoushe Marandjian Win Summary Judgment Motion on Behalf of Homeowner Client!

March 13, 2023 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is excited to share that Partner, Jack Briscoe and Associate, Anoushe Marandjian obtained an order for summary judgment in a multi-theory liability action in Los Angeles Superior Court. Plaintiff suffered severe injuries when he fell off a ladder while performing finish carpentry work at the home of BWB&O’s client. Plaintiff alleged various theories of liability against our client, the homeowner, including that: our client supplied a dangerous and defective ladder that, among other things, was unstable and not tall enough for the job; that the floor was covered with a slippery plastic sheeting hidden underneath construction paper which constituted a dangerous condition; that our client was his “employer” under the Labor Code; and that our client was civilly liable on the basis that he had directly hired Plaintiff, who was an unlicensed contractor. Alternatively, Plaintiff alleged that our client was vicariously liable for the conduct of his general contractor, who failed to maintain worker’s compensation insurance covering Plaintiff. After several rounds of written discovery, which required extensive attempts to “meet and confer” over Plaintiff’s deficient responses, as well as the parties’ depositions, Mr. Briscoe and Ms. Marandjian filed a Motion for Summary Judgment on behalf of our client on various grounds, including that the Privette Doctrine precluded Plaintiff from recovery against our client and that our client was not negligent (there was no dangerous condition and if there was, our client did not create it or that it existed for a long enough time for our client to have discovered it and remedied it). Plaintiff’s Opposition to our Motion for Summary Judgment included a Declaration from an expert witness alleging various grounds upon which our client was liable. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

David Uchida Joins Kahana Feld’s Los Angeles Office as Partner

December 31, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce that David M. Uchida recently joined the firm as a partner in the firm’s Los Angeles Office. He is a member of the firm’s General Liability group. A client-focused and seasoned litigator, David has defended product manufacturers and suppliers in complex toxic tort and environmental litigation. David also has extensive experience defending clients in alleged asbestos, benzene, and silica exposure claims. Read the court decision
Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

---

Workers Hurt in Casino Floor Collapse

February 10, 2012 — CDJ STAFF

More than a dozen construction workers fell about thirty feet when a floor collapsed in a Cincinnati casino. The workers were pouring cement on the second-floor level when the accident happened. The area in question will be the gaming area in the completed casino. Scott Allen, OSHA’s regional spokesperson, said their investigation of the accident would probably take about a month to complete.



The cause of the collapse is still undetermined. Although the weather has been wet in the area, experts thought it unlikely to be the cause. A construction forensics professor at Ohio State University said that “concrete pouring is very common” and that “you cannot go wrong unless something happens with the connection.” Engineering experts said it was more likely an issue with the metal decking.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Loss Caused by Subcontractor's Faulty Work Covered in Georgia

January 17, 2013 — Tred Eyerly, Insurance Law Hawaii

The Georgia Court of Appeals found a subcontractor was covered under a CGL policy for loss caused by alleged faulty workmanship. Maxum Indem. Co. v. Jimenez, 2012 Ga. App. LEXIS 970 (Ga. Ct. App. Nov. 20, 2012).

 

Jimenez was hired as a subcontractor to install pipes for a dormitory construction project at Georgia Southern University. Subsequent to the construction, a pipe burst occurred at the dormitory, causing damage to several units. After a jury trial, Jimenez was found liable for $191,382 in damages that arose from his negligent pipe work. 

 

Jimenez was insured under a CGL policy issued by Maxum. Maxum filed a suit for a declaratory judgment, seeking a declaration that the claim against Jimenez was not covered.

Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---