A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay
May 23, 2022 —
David Adelstein - Florida Construction Legal UpdatesDelay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing!
This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Repair of Fractured Girders Complete at Shuttered Salesforce Transit Center
July 22, 2019 —
Nadine M. Post - Engineering News-RecordThe repair of two fractured girders spanning Fremont Street and the reinforcement of twin girders spanning First Street are complete at the beleaguered Salesforce Transit Center in San Francisco.
Reprinted courtesy of
Nadine M. Post, Engineering News-Record
Ms. Post may be contacted at postn@enr.com
Read the court decisionRead the full story...Reprinted courtesy of
ETF Bulls Bet Spring Will Thaw the U.S. Housing Market
April 08, 2014 —
Corinne Gretler – BloombergBuild it and they will come, if it’s not too chilly.
Traders have turned bullish on a security that tracks home construction companies, appliance makers and furniture retailers as spring finally ends the harsh winter.
As the SPDR S&P Homebuilders ETF (XHB) heads for its first weekly gain since February, investors are buying options betting that the rebound will keep going. The cost of bullish contracts has risen to the highest versus bearish ones in 2 ½ years. The ETF has gained 2.2 percent this week.
The exchange-traded fund of companies such as Ryland Group Inc., Whirlpool Corp. and Home Depot Inc. has rebounded 8 percent after reaching its lowest level this year on Feb. 3 as investors attribute weakness in the housing market to winter weather. Between December and February, snow covered 1.42 million square miles of the continental U.S., the 10th-largest snow cover in records going back to 1966, according to the National Climatic Data Center.
Read the court decisionRead the full story...Reprinted courtesy of
Corinne Gretler, BloombergMs. Gretler may be contacted at
cgretler1@bloomberg.net
ASCE's Architectural Engineering Institute Announces Winners of 2021 AEI Professional Project Award
April 19, 2021 —
American Society of Civil EngineersRESTON, Va. – The
American Society of Civil Engineers' (ASCE) Architectural Engineering Institute (AEI) is pleased to announce the 100 Mount Street project by Skidmore, Owings & Merrill and Billie Jean King Main Library, also by Skidmore, Owings & Merrill as Best Overall Projects winners for AEI's Professional Project Awards. The 100 Mount Street project won the award Best Overall Project Over $100 Million, while the Billie Jean King Main Library won the award for Best Overall Project Under $100 Million. Traditionally, AEI announces project winners during its in-person annual Awards Banquet; however, ASCE held the banquet virtually this year to follow CDC guidelines which suggest avoiding large gatherings.
The AEI Professional Project Award recognizes outstanding achievements in design and construction by honoring the art and science of an integrated approach to architectural engineering. The program focuses on high performance buildings including structural, mechanical, electrical and lighting systems as well as construction management and architectural engineering integration. Projects are evaluated on originality and innovative character, integration and collaboration, sustainability, energy efficiency and economics, effective use of technology and constructability and site logistics.
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
About ASCE's Architectural Engineering Institute
Established in 1998, AEI is the premier organization for architectural engineering, promoting an integrated, multi-disciplinary approach to planning, design, construction and operation of buildings, by encouraging innovation, collaboration and excellence in practice, education and research of architectural engineering. For more information, visit www.asce.org/aei.
Read the court decisionRead the full story...Reprinted courtesy of
American Society of Civil Engineers
Does “Faulty Workmanship” Constitute An Occurrence Under Your CGL Policy?
January 08, 2024 —
David Adelstein - Florida Construction Legal UpdatesThere is nothing more scintillating than an insurance coverage dispute, right? Well, some folks would agree with this sentiment. Others would spit out their morning coffee in disagreement. Regardless of where you fall in the spectrum, they are always important because maintaining insurance is a NECESSARY part of business, particularly in the construction industry. The ideal is to have insurance that covers risks you are assuming in the performance of your work.
Sometimes, insurance coverage disputes provide valuable insight, even in disputes outside of Florida. Recently, the Western District of Kentucky in Westfield Insurance Co. v. Kentuckiana Commercial Concrete, LLC, 2023 WL 8650791 (W.D.KY 2023), involved such a dispute. While different than how Florida would treat the same issue, it’s still noteworthy because it sheds light into how other jurisdictions determine whether “faulty workmanship” constitutes an “occurrence” under a commercial general liability (CGL) policy.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Candis Jones Named “On the Rise” by Daily Report's Georgia Law Awards
September 29, 2021 —
Candis Jones - Lewis Brisbois NewsroomAtlanta Partner Candis Jones was named a lawyer “On the Rise” by the Daily Report (part of Law.com). Ms. Jones is one of 20 attorneys from Georgia to receive this distinction as part of the publication's 2021 Georgia Law Awards.
The Daily Report’s “On the Rise” category recognizes outstanding attorneys under the age of 40 who have made an impression on their colleagues, their clients, and the larger legal community of Georgia. Winners are selected by the publication’s editorial staff.
Ms. Jones is a member of Lewis Brisbois' General Liability Practice and has extensive experience with insurance defense, premises liability, personal injury, and medical malpractice cases. Her clients include Fortune 500 companies, numerous insurance carriers, and a major metropolitan transit authority. Outside her legal practice, Ms. Jones is an active member of her legal community and was recently installed as President of the Gate City Bar Association, the oldest African-American bar association in the State of Georgia.
Read the court decisionRead the full story...Reprinted courtesy of
Candis Jones, Lewis BrisboisMs. Jones may be contacted at
Candis.Jones@lewisbrisbois.com
Shimmick Gets Nod for Second Pilot Pile at Settling Millennium Tower
December 13, 2021 —
Nadine M. Post - Engineering News-RecordAfter the successful installation of a 24-in.-dia permanent pilot pile at the troubled foundation upgrade of the settling Millennium Tower in San Francisco, the Dept. of Building Inspection (DBI) has given Shimmick Construction Co. permission to install a second pilot pile, beginning Dec. 1.
Reprinted courtesy of
Nadine M. Post, Engineering News-Record
Ms. Post may be contacted at postn@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Utility Contractor Held Responsible for Damaged Underground Electrical Line
October 11, 2017 —
Brett M. Hill - Ahlers & Cressman, PLLCThe Washington State Court of Appeals recently addressed an excavation contractor’s responsibilities under the Underground Utilities Damage Prevention Act (UUDPA), RCW 19.122. That statute was enacted in 2011 and imposed certain statutory duties on parties involved with projects requiring excavation.
In this case, Titan Earthworks, LLC contracted with the City of Federal Way to perform certain street improvements including installation of a new traffic signal. During the process of excavating for the traffic signal, Titan drilled into an energized underground Puget Sound Energy power line. PSE sought damages from Titan and Titan sued the City of Federal Way.
Read the court decisionRead the full story...Reprinted courtesy of
Brett M. Hill, Ahlers & Cressman, PLLCMr. Hill may be contacted at
bhill@ac-lawyers.com