FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Providing Notice of Claims Under Your Construction Contract

April 02, 2014 — Beverley BevenFlorez-CDJ STAFF
Craig Martin on his blog Construction Contractor Advisor explained the importance of knowing when to provide notice under your construction contract: “Time and time again, courts rule that contractors must follow notice requirements in order to submit a claim for additional time or compensation.” Martin cited the case JEM Contracting v. Morrison-Maierle, where the contractor provided verbal notice of a claim to the engineer, but failed to submit in writing until eighteen days later, which was past the notice requirement as stated in the contract. The judge denied the contractor’s claim and sided with the engineer and county. Read the court decision
Read the full story...
Reprinted courtesy of

---

Revised Federal Rule Regarding Class-Wide Settlements

May 13, 2019 — Edward M. Koch & Michael Jervis - White and Williams LLP
The United States Supreme Court recently approved and adopted amendments to Federal Rule of Civil Procedure 23 concerning class action practice as proposed by the Advisory Committee on Civil Rules. The amended rule went into effect on December 1, 2018. The amendments do not affect the core of the rule – the criteria for obtaining class certification. Instead, the changes are more subtle adjustments that update and modernize procedures and processes for notification to class members and obtaining approval of class settlements. Nonetheless, although the amendments are not breathtaking, there are important changes. The first set of amendments apply to Rule 23(e), governing the process of settlement of a class action. First, the amendment makes explicit that the subsection applies not just to already certified classes, but also “a class proposed to be certified for purposes of settlement.” The changes also add some discretion of the court concerning when notice of a proposed settlement and settlement class should be provided. As part of the settlement approval process, the parties now are expressly required to give the court “information sufficient to enable it to determine whether to give notice of the proposal to the class.” The giving of notice is justified only if that information is sufficient to allow the court to determine it is likely to approve the proposed settlement and certify the class. Once notice is approved, the new rule recognizes modern developments by allowing that notice may be by “United States mail, electronic means, or other appropriate means.” The rule thus recognizes that in many cases traditional mail notice may still be best; in others e-mail notification might be the best way to reach class members. Reprinted courtesy of Edward M. Koch, White and Williams LLP and Michael Jervis, White and Williams LLP Mr. Koch may be contacted at koche@whiteandwilliams.com Mr. Jervis may be contacted at jervism@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Pancakes Decision Survives Challenge Before Hawaii Appellate Court

March 12, 2015 — Tred R. Eyerly – Insurance Law Hawaii
In 1997, the Hawaii Intermediate Court of Appeals (ICA) decided Pancakes of Hawaii, Inc. v. Pomare Prop. Corp., 85 Haw. 286, 944 P.2d 83 (Haw. Ct. App. 1997). Although not an insurance coverage case, Pancakes addressed the duty to defend in terms of a contractual indemnity obligation. Under challenge in a recent appeal before the ICA, the Court reaffirmed the holding in Pancakes. Arthur v. State of Hawaii, Dept. of Hawaiian Home Lands, 2015 Haw. App. LEXIS 109 (Haw. Ct. App. Feb. 27, 2015). The decision is long with detailed facts complicated and many indemnities running in favor of various parties. This post focuses on the decision's discussion of Pancakes. A resident, Mona Arthur, of the Kalawahine Streamside Housing Development, was killed when she apparently slipped and fell from a hillside adjacent to the project. She was on the hillside tending to her garden there. At the bottom of the hill was a two foot fence in front of a drainage ditch, where Mona allegedly hit her head. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Washington Supreme Court Expands Contractor Notice Obligations

November 28, 2018 — Brett M. Hill - Ahlers Cressman & Sleight Blog
The Washington State Supreme Court dealt another blow to public works contractors in Washington State. In a case recently issued by the court, Nova Contracting, Inc. v. City of Olympia, [1] the court expanded contractors’ obligations when providing notice on public works construction projects. The Nova Contracting case was the subject of a previous blog. The case involved Nova Contracting and the City of Olympia. Nova was the low bidder on the contract. Nova alleged that the City of Olympia did not want Nova to win the job and intentionally hindered Nova’s ability to perform the job. The facts alleged by Nova, which were covered in the previous blog, involved the City’s improper and apparently punitive rejection of submittals on the job and the City’s eventual wrongful termination of Nova. Of significance in the case is that Nova never actually began work on the job. All that Nova had done at the time of termination was begin mobilizing its equipment on site. The Court of Appeals found that Nova had alleged sufficient facts to establish that the City violated the duty of good faith and fair dealing by improperly rejecting Nova’s submissions and had breached the contract with Nova by improperly terminating. Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers Cressman & Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com

---

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

---

Structural Problems May Cause Year-Long Delay Opening New Orleans School

January 29, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the Uptown Messenger, structural issues found at Audubon Charter School’s Broadway campus in New Orleans, Louisiana, will require “selective demolition” and “could delay students’ return by as much as a full year.” Late September of last year, “officials discovered that some of the steel supports around the stair towers were not level—some of the steel beams lean out several inches, so that the floors are not parallel.” Discovering the problem will require some demolition, according to Chris Young of Blitch Knevel architects as quoted in the Uptown Messenger: “…we’re going to have to tear down a lot of this construction to expose that steel frame to make sure that every steel beam is straight and true and not deformed.” Read the court decision
Read the full story...
Reprinted courtesy of

---

EPA and the Corps of Engineers Repeal the 2015 “Waters of the United States” Rule

January 13, 2020 — Anthony B. Cavender - Gravel2Gavel
The pre-publication version of the final rule to be promulgated by EPA and the U.S. Army Corps of Engineers (ACOE) to repeal the 2015 redefinition of the Clean Water Act’s term “Waters of the United States” which is the linchpin of these agencies’ regulatory power under the CWA, was made available on September 12, 2019. The rule should be published in the Federal Register in the next few weeks, and it will be effective 60 days thereafter. Many challenges are expected to be filed in the federal courts. The 2015 rule was very controversial, and petitions challenging the rule were filed in many federal district courts, several courts of appeal, and finally in the Supreme Court (see NAM v. Department of Defense), which held that all initial challenges must be filed in the federal district courts. The upshot of these challenges is that, at this time, the 2015 rule has been enjoined in more than half the states while the other states are bound by the 2015 rule, a situation which is frustrating for everyone. In addition to repealing the 2015 rule, the agencies also restored the pre-2015 definition had had been in place since 1986. As a result, the pre-2015 definition of waters of the U.S. will again govern the application of the following rules: (a) the ACOE’s definition of “waters of the U.S.” at 33 CFR Section 328.3; (b) EPA’s general Oil Discharge rule at 40 CFR Section 110; (c) the SPCC rules at 40 CFR Part 112; (d) EPA’s designation of hazardous substances at 40 CFR Part 116; (e) EPA’s hazardous substance reportable quantity rule at 40 CFR Part 117; (f) the NPDES permitting rules at 40 CFR Part 122; (g) the guidelines for dredged or fill disposal sites at 40 CFR Part 230; (g) Exempt activities not requiring a CWA 404 permit (guidelines for 404 disposal sites at 40 CFR Part 232); (h) the National Contingency Plan rules at 40 CFR Part 300; (i) the designation of reportable quantities of hazardous substances at 40 CFR Part 302; and (j) EPA’s Effluent Guidelines standards at 40 CFR Part 401. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

CSLB Reminds California Public Works Contractors to Renew Their Public Works Registration

October 02, 2015 — Garret Murai – California Construction Law Blog
A friendly reminder from the Contractors State License Board . . . CSLB Urges Public Works Contractors to Renew Dept. of Industrial Relations Registration before October 1 to Avoid Hefty Penalty SACRAMENTO — A mandatory renewal deadline is approaching for licensees who work on public works projects. Contractors whose registration with the California Department of Industrial Relations (DIR) expired June 30, 2015, and have ongoing public works projects or plan to bid on new ones, must pay the $300 renewal fee before October 1, 2015, or face an additional $2,000 late penalty after that date. As a result of Senate Bill (SB) 854, all contractors have been required since April 1, 2015, to register with DIR to be awarded a public works contract, even if the project did not go out to bid. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---