FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Appraisal Goes Forward Even Though Insurer Has Yet to Determine Coverage on Additional Claims

December 11, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's order granting the insured's motion to stay litigation and compel an appraisal was affirmed even though the insurer had not determined coverage on the insured's additional claims.Heritage Prop. & Cas. Ins. Co. v. Wellington Place HOA, 2023 Fla. App. LEXIS 6405 (Fla. Ct. App. Sept. 13, 2023). The insured homeowner's association reported roof damage to its insurer, Heritage, after Hurrican Irma struck. Heritage agreed the damage was covered, but issued no payment because the amount of loss was less than the deductible. The insured hired its own adjuster. The insured requested an extension of the policy's two year time limit to complete repairs because the claim was still in dispute and the insurer had not yet paid sufficient funds to allow necessary repairs. Heritage sent a revised estimate and asked the insured to send its adjuster's estimate in order to address any disputes. The insured submitted its adjuster's estimate of more than $6 million, including, for the first time, the cost to replace all the windows and sliding glass doors. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

HHMR Lawyers Recognized by Best Lawyers

December 27, 2021 — David M. McLain – Colorado Construction Litigation
For over twenty years, Higgins, Hopkins, McLain & Roswell has embodied and exemplified the principles of service and stewardship. In everything we do, we focus on serving our clients selflessly and to the best of our ability. In doing so, we always have in the forefront of our minds our obligation to act as the stewards of our clients’ trust, confidences, and resources. The firm itself, along with Carin Ramirez (in the area of Litigation - Insurance), and Dave McLain (in the area of Construction) were all recognized in this year's edition of the U.S. News Best Lawyers Journal. We could not be more proud of the firm we have created, or the service we are able to provide to Colorado's construction industry and its insurers. Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell Mr. McLain may be contacted at mclain@hhmrlaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Spencer Mayer Receives Miami-Dade Bar Association's '40 Under 40' Award

March 04, 2024 — Lewis Brisbois Newsroom
Miami, Fla. (February 23, 2024) – Miami Associate Spencer Mayer received the 2024 Miami-Dade Bar Association Young Lawyers Section’s '40 under 40' Award at the association's annual "Miami Nights" event on February 22. Mr. Mayer serves on the Board of Directors of the Miami Dade Bar Association’s Young Lawyers Section. Lewis Brisbois was a proud sponsor of this event, which raised funds for the organization's community service initiatives and pro bono programming. Mr. Mayer is a member of the General Liability Practice. His practice focuses on all aspects of civil litigation, including complex commercial litigation, products liability, premises liability, wrongful death, catastrophic injury, and insurance coverage. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Europe’s Satellites Could Help Catch the Next Climate Disaster

February 15, 2021 — Jonathan Tirone - Bloomberg
Spain began the new year battling Storm Filomena, a once-in-a-generation weather event that blanketed Madrid in snow and paralyzed the economy. Health workers were stranded, supermarkets shut, and the army was called in. At least four people died. “Now, consider a government or company that knew two weeks ago there was a risk that this would happen,” said Francisco Doblas-Reyes, a physicist at Barcelona’s Supercomputing Center. “Knowing the risk that a 1-in-20-year event was going to happen would have given more possibilities to prepare.” Doblas-Reyes and his team are working on complex models that they hope can better detect the next Filomena, a job that’s become increasingly important as climate change makes weather more unpredictable — and extreme. The data collected by European satellites is at the heart of the continent’s multibillion-euro Destination Earth program seeking to develop the world’s best digital simulation of Earth. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan Tirone, Bloomberg

---

Oregon agreement to procure insurance, anti-indemnity statute, and self-insured retention

March 05, 2011 — CDCoverage.com

In Continental Casualty Ins. Co. v. Zurich American Ins. Co., No. 09-35484 (9th Cir. Oct. 28, 2010), general contractor TCR was sued by an employee of subcontractor Safeway for bodily injuries suffered while working on the project. In the subcontract, Safeway agreed to procure primary insurance providing coverage for TCR for liability arising out of Safeway’s negligence. Safeway’s CGL policy included a self-insured retention that had to be satisfied before the insurer had a duty to defend. TCR filed suit against Safeway alleging that

Read the full story...

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

U.S. Firm Helps Thais to Pump Water From Cave to Save Boys

August 14, 2018 — Dan Murtaugh - Bloomberg
Like much of the world, Patrick Decker has been engrossed in the saga of 12 boys and their soccer coach who became trapped in a flooded cave in Thailand. Unlike most, Decker is in a position to do something about it. As chief executive officer of Xylem Inc., one of the world’s top water technology firms, Decker spent much of last week reaching out to Thai officials and mobilizing his company of 17,000 employees to help. Decker said he sent four engineers to the cave site, and they assisted rescuers by boosting pumping power 40 percent. Thai Navy SEALs and international cave diving experts extracted eight boys over Sunday and Monday. Read the court decision
Read the full story...
Reprinted courtesy of Dan Murtaugh, Bloomberg

---

Florida Supreme Court Adopts Federal Summary Judgment Standard, Substantially Conforming Florida’s Rule 1.510 to Federal Rule 56

June 07, 2021 — Lewis Brisbois
Effective May 1, 2021, the Florida courts will transition to a new summary judgment standard meant to “align Florida’s summary judgment standard with that of the federal courts and of the supermajority of states that have already adopted the federal summary judgment standard.” In re Amends. to Fla. Rule of Civ. Pro. 1.510, 309 So. 3d 192, 192 (Fla. 2020). Consistent with this amendment, Florida Rule of Civil Procedure 1.510 has been amended to adopt the federal summary judgment rule, with exceptions for timing-related issues. The Florida Supreme Court’s most recent opinion on rule 1.510 and the text of new rule 1.510 can be found here. As background, on December 31, 2020, the Florida Supreme Court adopted the federal summary judgment standard by amending Florida Rule of Civil Procedure 1.510(c) to include the following sentence: “The summary judgment standard provided for in this rule shall be construed and applied in accordance with the federal summary judgment standard articulated in Celotex Corp. v. Catrett, 477 U.S. 317 (1986); Anderson v. Liberty Lobby, Inc., 477 U.S. 242 (1976); and Matsushita Electric Industrial Co. v. Zenith Radio Corp., 475 U.S. 574 (1986) [(the ‘Celotex trilogy’)].” In re Amends. to Fla. Rule of Civ. Pro. 1.510, 309 So. 3d at 196. The court’s amendment was slated to take effect on May 1, 2021, subject to a public comment period. The court also sought guidance from the Florida Bar’s Civil Procedure Rules Committee. After careful consideration of numerous responses, the court ultimately chose to adopt the substance of the text from federal rule 56. Along with its amendments, the court provides substantial guidance as to how the Florida courts and practitioners should interpret the new rule. A summary of the court’s thorough discussion follows. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---