Seattle Washington Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Texas Supreme Court to Rehear Menchaca Bad Faith Case

January 10, 2018 — Sean P. Mahoney – Complex Insurance Coverage Reporter
On December 15th, the Texas Supreme Court agreed to revisit its April 7, 2017 decision in USAA Texas Lloyds Co. v. Menchaca, No. 14-0721, a “bad faith” case arising out of Hurricane Ike damage, in which the court held that a policyholder could potentially recover policy benefits for statutory bad faith under Texas law, even though a jury concluded that the insurer did not breach the terms of the policy, if the policyholder could show that she was nevertheless entitled to the benefit. The decision to rehear this matter comes at the urging of insurers and interested groups, including the Insurance Council of Texas and the U.S. Chamber of Commerce, who argued that the April 7, 2017 ruling substantially unsettled Texas insurance law. Menchaca is a first-party property insurance coverage case. After Hurricane Ike struck in 2008, plaintiff Menchaca submitted a claim under her homeowners policy to USAA. A USAA adjuster later concluded that Menchaca’s property suffered only “minimal damage” that fell below the deductible. Menchaca sued claiming breach of contract and unfair claims settlement practices in violation of the Texas Insurance Code. As damages, she sought only the policy benefit, court costs, and attorneys’ fees. Read the court decision
Read the full story...
Reprinted courtesy of Sean P. Mahoney, White and Williams LLP
Mr. Mahoney may be contacted at mahoneys@whiteandwilliams.com

Creative Avenue for Judgment Creditor to Collect a Judgment

October 27, 2016 — David Adelstein – Florida Construction Legal Updates
I have a judgment against another entity. Now what? I want to briefly talk about this “now what?” in the context of the recent decision in MYD Marine Distributor, Inc. v. International Paint, Ltd., 41 Fla. L. Weekly D2364a (Fla. 4th DCA 2016). Although this case is not a construction case, it poses an interesting issue for any entity that has a judgment entered against it (known as the judgment debtor) while it is contemporaneously the plaintiff and pursuing monetary damages in an unrelated case or cases. This case also presents an avenue for any judgment creditor to pursue in the event other post-judgment collection efforts are unsuccessful. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Phoenix Flood Victims Can’t Catch a Break as Storm Nears

September 17, 2014 — Brian K. Sullivan – Bloomberg
A week ago, Hurricane Norbert pumped tropical moisture across the U.S. Southwest, touching off record rainfall in Phoenix and Tucson that killed at least two people, flooded hundreds of homes and shut highways throughout the region. This week, Hurricane Odile moved onto the Baja California peninsula after becoming the strongest system since 1967 to hit that part of Mexico, the U.S. National Hurricane Center said. While it isn’t time to get the rowboat out again for the morning commute, the earth in the desert Southwest doesn’t absorb water very well, the way a Florida swamp or Louisiana bayou might. A lot of rain can be far more unpredictable. Read the court decision
Read the full story...
Reprinted courtesy of Brian K. Sullivan, Bloomberg
Mr. Sullivan may be contacted at bsullivan10@bloomberg.net

16 Wilke Fleury Attorneys Featured in Sacramento Magazine 2021 Top Lawyers!

September 20, 2021 — Wilke Fleury LLP
Congratulations to Wilke Fleury’s featured attorneys who made the Sacramento Magazine’s Top Lawyer List for 2021! The voting for Professional Research Services’ survey to determine the top attorneys in 2021 for Sacramento Magazine was open to all licensed attorneys in Sacramento, Calif. Attorneys were asked whom they would recommend among 56 legal specialties, other than themselves, in the Sacramento area. Each attorney was allowed to recommend up to three colleagues in each given legal specialty. Once the online nominations were complete, each nominee was carefully evaluated on the basis of the survey results, the legitimacy of their license, and their current standing with the State Bar of California. Attorneys who received the highest number of votes in each specialty are reflected in the following list. – Sacramento Magazine

Kathryne E. Baldwin – Insurance
Adriana C. Cervantes – Medical Malpractice
Heather M. Claus – Health Care
Aaron R. Claxton – Health Care
Daniel L. Egan – Bankruptcy and Creditor/Debtor
Daniel J. Foster – Litigation Insurance
David A. Frenznick – Litigation Construction
George Guthrie – Construction
Neal C. Lutterman – Medical Malpractice
Stephen K. Marmaduke – Business/Corporate
Gene E. Pendergast Jr. – Estate Planning & Probate
Michael G. Polis – Health Care
Matthew W. Powell – Business Litigation
Trevor Stapleton – Estate Planning & Probate
Steve Williamson – Bankruptcy and Creditor/Debtor

Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

JPMorgan Blamed for ‘Zombie’ Properties in Miami Lawsuit

June 18, 2014 — Christie Smythe – Bloomberg
JPMorgan Chase & Co. (JPM) engaged in a “pattern of discriminatory” lending that led to foreclosures, the city of Miami said in a lawsuit filed last week in federal court, the latest in a series of similar claims against the nation’s largest banks. Last month, Banco Santander SA’s (SAN) U.S. unit was sued by the city of Providence, Rhode Island, over claims it stopped issuing mortgages in minority neighborhoods after the housing bubble burst. Santander Bank, previously named Sovereign Bank, pulled out of the neighborhoods and focused on white communities after being acquired by the Madrid-based lender in 2009, the city alleged. Miami and Los Angeles are among cities to have filed similar lawsuits against Bank of America Corp., Citigroup Inc. (C) and Wells Fargo & Co. (WFC) for allegedly “red-lining” black and Hispanic areas as no-loan zones, and then “reverse red-lining,” flooding the areas with predatory mortgages even when minorities qualified for better terms. Read the court decision
Read the full story...
Reprinted courtesy of Christie Smythe, Bloomberg
Ms. Smythe may be contacted at csmythe1@bloomberg.net

BWBO Celebrating Attorney Award and Two New Partners

July 14, 2016 — Beverley BevenFlorez-CDJ STAFF
Congratulations is due to Nicole Whyte of Bremer Whyte Brown & O’Meara LLP (BWBO) for being recognized as one of America’s Top 100 Attorneys by America’s Top 100, which identifies the top 100 attorneys in each state. In an email release, the firm stated, “We are pleased to celebrate this lifetime achievement and it is an honor to have Ms. Whyte listed alongside her esteemed peers.” Furthermore, BWBO announced that two of their attorneys have been promoted to partner: Alex Giannetto and Benjamin Price. “Mr. Giannetto believes that hard work, dedication, caring about clients and work product, and surrounding himself with good people, has helped him become successful in his profession,” as stated in an email release. “To be successful you have to surround yourself with successful people,” Mr. Price stated. “A combination of humility, confidence, and hard work is also important.” Read the court decision
Read the full story...
Reprinted courtesy of

Texas Federal Court Delivers Another Big Win for Policyholders on CGL Coverage for Construction-Defect Claims and “Rip-and-Tear” Damages

March 14, 2022 — Blake A. Dillion, Jared De Jong & Scott S. Thomas - Payne & Fears
Insurers regularly argue that commercial general liability (“CGL”) policies are not performance bonds and therefore there is no coverage for claims seeking damages for defective or faulty workmanship. Insurers also argue there is no coverage for so-called “tear-out” or “rip-and-tear” damages, where fixing property damage requires replacing defective work that has not itself been damaged. Fortunately, in a newly decided case, a Texas federal district court rejected both arguments by an insurer. Amerisure Mutual Insurance Company v. McMillin Texas Homes, LLC, No. SA-20-CV-01332-XR, 2022 WL 686727 (W.D. Tex. Mar. 8, 2022). As with most construction-defect claims, this case involved homeowner claims against a residential developer, McMillin Texas Homes (“McMillin”). After the homes were completed, homeowners complained about defects in the artificial stucco exterior finish and filed suit. McMillin tendered to its insurer, Amerisure Mutual Insurance Company (“Amerisure”). Amerisure then sued McMillin for declaratory relief, arguing that it had no duty to defend or indemnify the homeowner claims. McMillin filed a counterclaim alleging Amerisure breached its policies by refusing to defend or indemnify McMillin. Reprinted courtesy of Blake A. Dillion, Payne & Fears, Jared De Jong, Payne & Fears and Scott S. Thomas, Payne & Fears Mr. Dillion may be contacted at bad@paynefears.com Mr. De Jong may be contacted at jdj@paynefears.com Mr. Thomas may be contacted at sst@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES