Seattle Washington Building Expert Directory

BWB&O is Recognized in the 2024 Edition of Best Law Firms®!

November 16, 2023 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is honored to announce the firm has been recognized for its fourth consecutive year in the 2024 edition of Best Law Firms® and is ranked by Best Lawyers® regionally in three practice areas. To read the publication, please click here. Regional Tier 1 Las Vegas: Litigation – Construction Orange County: Litigation – Construction Regional Tier 2 Orange County: Family Law Regional Tier 3 Orange County: Commercial Litigation Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Thank You to Virginia Super Lawyers

July 13, 2017 — Christopher G. Hill - Construction Law Musings
Thank you to all of my peers and those at Virginia Super Lawyers for nominating and electing me to the Virginia Super Lawyers Rising Stars for 2011. I am particularly honored because this puts me in a group of only 2.5% of lawyers in Virginia. I am truly honored to be a part of this list. Add this honor to my election to the Virginia Business Legal Elite in Construction Law and 2010 has been a great year for my new firm! Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Coverage for Construction Defects Barred By Exclusion j (5)

April 15, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court Appeal reversed a trial court judgment which found coverage in favor of the contractor based upon exclusion j(5). Dallas Nat'l Ins. Co. v. Calitex Corp., 2015 Tex. App. LEXIS 2002 (Tex. Ct. App. March 3, 2015). Turnkey Residential Group, Inc., was the contractor to construct a twelve-unit townhome complex in Dallas. The owner of the project was Calitex Corporation. Construction began on November 2006. The project was to be completed by Turnkey by October 27, 2007. Calitex filed suit against Turnkey and some of its subcontractors in February 2008. Calitex alleged problems with Turnkey's work included: (1) the stone exterior was not properly treated and leaked, and some areas were left uncovered with stone; and (2) windows leaked. It was further alleged that the quality of materials, labor and craftsmanship did not meet the standards of the contract and resulted in damages. Turnkey submitted a notice of claim to its insurer, Dallas National Insurance Company (DNIC). Coverage was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Drill Rig Accident Kills Engineering Manager, Injures Operator in Philadelphia

August 10, 2021 — Stephanie Loder - Engineering News-Record
Philadelphia officials and engineering firm Langan have confirmed that a company project manager and geotechnical engineer died July 6 in a nighttime drill rig accident while he was on site to inspect foundation work for a pedestrian bridge project. Reprinted courtesy of Stephanie Loder, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Full Extent of Damage From Turkey Quakes Takes Shape

February 20, 2023 — Jeff Rubenstone - Engineering News-Record
Nearly two weeks after a pair of severe earthquakes rocked central Turkey and northern Syria, the full extent of damage to buildings and other structures is beginning to emerge. With the magnitude 7.8 and 7.5 epicenters located hundreds of kilometers apart, the area affected is vast. Reprinted courtesy of Jeff Rubenstone, Engineering News-Record Mr. Rubenstone may be contacted at rubenstonej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Recovery Crews Swing Into Action as Hurricane Michael Departs

October 23, 2018 — Tom Sawyer, Luke Abaffy, Thomas F. Armistead, & Jim Parsons - Engineering News-Record
By the time the blustery remnants Hurricane Michael departed the East Coast around mid day on Oct. 12, with one last lashing of eastern regions from Virginia to New York, the trail of woe stretched from the Florida Panhandle through the southeastern states and well up the Eastern Seaboard. Authorities report the death toll stood at 16, with victims in Florida, Georgia, North Carolina and Virginia. Reprinted courtesy of ENR reporters Tom Sawyer, Luke Abaffy, Thomas F. Armistead and Jim Parsons Mr. Sawyer may be contacted at sawyert@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

Property Owner’s Defense Goes Up in Smoke in Careless Smoking Case

September 23, 2019 — Michael J. Ciamaichelo - The Subrogation Strategist
Property owners owe a duty of reasonable care to avoid causing harm to neighboring properties. When a property owner knows or should know about a condition that poses a risk of danger to neighboring properties, the property owner must exercise reasonable care to make the condition safe. The Court of Special Appeals of Maryland recently held that, where hundreds of discarded cigarette butts had accumulated in a bed of mulch over an extended period of time prior to the fire at issue, the owner of the property with the mulch beds owed a duty of care to its neighbors to prevent a foreseeable fire. In Steamfitters Local Union No. 602 v. Erie Insurance Exchange, 2019 Md. App. LEXIS 430 (May 30, 2019), a fire originated in a strip of mulch at property owned by the Steamfitters Local Union No. 602 (Union) and caused damage to neighboring properties. The fire occurred when an unknown person discarded a cigarette butt into the mulch. Following the fire, investigators found “hundreds, if not thousands of cigarettes” in the mulch where the fire originated. A representative for the Union acknowledged that there were more butts in the mulch “than there should have been” and that, “[i]n the right situation,” a carelessly discarded cigarette could cause a fire. The Union, however, had no rules or signs to prohibit or regulate smoking at the property, where apprentices would often gather prior to class. The insurance companies for the damaged neighbors filed subrogation actions alleging that the Union, as the property owner, failed to use reasonable care to prevent a foreseeable fire. A jury found in favor of the subrogating insurers and against the Union. Read the court decision
Read the full story...
Reprinted courtesy of Michael J. Ciamaichelo, White and Williams LLP
Mr. Ciamaichelo may be contacted at ciamaichelom@whiteandwilliams.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES