FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Forget the Apple Watch. Apple’s Next Biggest Thing Isn’t for Sale

May 20, 2015 — Garret Murai – California Construction Law Blog
Apple released its much anticipated Apple Watch this past month. The Apple Watch is significant for Apple, not only because its profit and loss statement has a lot riding on it, but because it’s the company’s first foray into consumer “wearables.” This isn’t the first time the Cupertino company has ventured into new areas, through. Since its first consumer product, the Apple I, was released in 1976, Apple has gone from personal computers – and its iterations, including, desktops, laptops and tablets – to music players, cell phones and now watches. Today, Apple is less a computer company than a consumer electronics company, and even that doesn’t quite seem to go far enough, as it has become a lifestyle brand for many. Comparisons can be drawn to Sony during the mid-1980s when everyone aspired to a home filled with Sony televisions, Sony receivers and Sony Walkmans. Part of Apple’s success is that it sells a lifestyle that transcends its products, in which a glossy, sophisticated minimalism and simplicity, are among its most recognizable characteristics. It goes beyond their products, and is embodied in their advertising, their online and retail stores, and their packaging. And while the Apple Watch may be Apple’s latest “big” thing, I think something even bigger is underfoot at Apple, and it’s something you can’t buy. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Pennsylvania Supreme Court Dismisses Appeal of Attorney Fee Award Under the Contractor and Subcontractor Payment Act

February 16, 2016 — William J. Taylor – White and Williams LLP
In late December, the Supreme Court of Pennsylvania dismissed, as improvidently granted, the appeal in Waller Corporation v. Warren Plaza, Inc., No. 6 WAP 2015 (December 21, 2015). As a result, the Superior Court’s holding in that case that there is no good faith exception to the attorney fee provision of the Pennsylvania Contractor and Subcontractor Payment Act (CASPA), 73 P.S. §§ 501-516, remains intact. In its decision in Waller, 95 A.3d 313 (Pa. Super. 2014), the Superior Court considered if there was a “good faith” exception to the interest and penalties provision of CASPA, 73 P.S. § 512(a), and whether there was a similar good faith exception to the attorney fee provision of the statute, 73 P.S. § 512(b). The court held that while an award of interest and penalties under § 512(a) could be denied if a party had a good faith basis for withholding payments due under a construction contract, no such exception exists for an award of attorney fees under § 512(b). Rather, an award of attorney fees is appropriate for the “substantially prevailing party” under a CASPA claim, and a claimant can be the substantially prevailing party even if the other party withheld payments in good faith. Read the court decision
Read the full story...
Reprinted courtesy of William J. Taylor, White and Williams LLP
Mr. Taylor may be contacted at taylorw@whiteandwilliams.com

---

Building Group Has Successful 2012, Looks to 2013

February 14, 2013 — CDJ STAFF
The North State Building Industry Association has looked back at 2012, and feels that they are “well-positioned to addressed future challenges in 2013 and beyond.” The organization, which represents home builders in Northern California, had several major accomplishments in 2012. The NSBIA has managed to reduce fees that builders must pay. Due to their work with the Sacramento Regional County Sanitation District and the Sacramento Area Sewer District over the last several years, a new rate and fee methodology has been adopted, saving builders $3,000 per single family unit in SRCSD fees and $1,000 per acre in SASD fees. Fees were also reduced through agreements with the Folsom Cordova unified and Elk Grove school districts. The city of Rancho Cordova reduced its transportation fee by $3,500 per home. In addition to their advocacy work, the NSBIA has continued its worker training programs. During 2012, 113 people participated in their Journeyman Upgrade classes, an increase of 20 from the prior year. Read the court decision
Read the full story...
Reprinted courtesy of

---

Oregon Duty to Defend Triggered by Potential Timing of Damage

June 28, 2013 — CDJ STAFF
The Oregon Supreme Court has concluded that if it is possible that damage could have occurred prior to the completion of the project, then the policies in effect at that time are triggered. John Green of Farella Braun + Martel LLP writes that “we have long argued that, since the duty to defend exists if there is any ‘potential’ of covered liability, there is a potential that damage happened before that project was completed, or at any time after completion, triggering all policies in that time frame.” The Oregon court concluded that if property damage could have happened during construction, the insuerer had a duty to defend and “the insured had no burden to establish any additional facts to support that potential.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Dust Infiltration Due to Construction Defect Excluded from Policy

September 09, 2011 — CDJ STAFF

A summary judgment was affirmed in the case of Brown v. Farmers Group, by the California Court of Appeals. The Browns bought a new home in Oakley, California. At the time, they signed disclosure statement “acknowledging that the area around their home experienced gusty winds and would be in development for years to come, which might result in dust and airborne mold.”

The Browns found an unusual amount of dust in their home, which became worse when they ran their heating and air conditioning system. Shelia Brown was later diagnosed with chronic valley fever, which was attributed to airborne mold. The Browns contacted Farmers which investigated the house. Although the adjustor from Farmers said the Browns would be covered, Farmers denied the claim.

After the Browns moved out of the house, an inspector found that the HVAC line in the attic was disconnected, sending dust into the home. The Browns brought action against Mid-Century Insurance, which managed the policy, and Farmers. The identified the HVAC defect, window problems, and valley fever as causes, suing for breach of contact, breach of implied covenant of good faith and fair dealing, and the intentional infliction of emotional distress.

The court rejected all these claims. The policy with Farmers excluded losses due to defective construction. This ruled out the faulty HVAC system and any problems there might have been from the windows. The policy also specifically excluded losses from contamination, fungi, pathogens, and noxious substances. The court further found that the adjustor’s opinion was irrelevant to the question of what the policy actually covered. Finally, the court found no evidence of intentional infliction of emotional stress.

On review, the appeals court upheld the trial court’s conclusions and affirmed the summary judgment.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Chicago Criticized for Not Maintaining Elevator Inspections

October 29, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Crain’s Chicago Business, “as few as a fifth of elevators get the required annual checkup,” Chicago Inspector General Joe Ferguson claimed. Ferguson audited the roughly 5,100 buildings that city inspectors were assigned to inspect elevators, and found that only 965 were actually inspected, reported Crain’s Chicago Business. Furthermore, “when problems were found in inspections conducted by city personnel, they often were not fixed in a timely manner, again according to city records.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Ahlers Cressman & Sleight Rated as One of the Top 50 in a Survey of Construction Law Firms in the United States

July 22, 2019 — Jonathan Schirmer - Ahlers Cressman & Sleight PLLC
The magazine, Construction Executive, recently rated the top construction law firms in the United States. We are pleased to announce that our firm was rated as number one in Oregon and Alaska and number two in the state of Washington behind Perkins Coie, LLP. In its inaugural ranking, Construction Executive reached out to hundreds of law firms nationwide with a dedicated construction practice to determine who the industry leaders were. Ahlers Cressman & Sleight ranked 22nd overall in the United States among all construction law firms. This survey considered revenues from each of the law firm’s construction practices, the number of lawyers in the firm’s construction practice, the percentage of the firm’s total revenues derived from construction practice, the number of states in which the firm is licensed to practice and the year in which the construction practice was established. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan Schirmer, Ahlers Cressman & Sleight PLLC
Mr. Schirmer may be contacted at jonathan.schirmer@acslawyers.com

---