Seattle Washington Building Expert Directory

COVID-19 Damages and Time Recovery: Contract Checklist and Analysis

April 27, 2020 — Patrick J. Greene, Jr. - Peckar & Abramson
This Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist. Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool. Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present: a) complete or partial suspension of work, b) additional work or requirements, c) added cost, d) delay, and e) disruption. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Greene, Jr., Peckar & Abramson
Mr. Greene may be contacted at pgreene@pecklaw.com

Homebuilding Down in North Dakota

October 30, 2013 — CDJ STAFF
Only eleven new homes have been started this year in the Pierre area in North Dakota. Last year saw 35 homes built in the same area. Brad Lawrence, the Fort Pierre Director of Public Works, blamed last year’s Hurricane Sandy in New Jersey, stating that “superstorm Sandy has just devoured a tremendous amount of building projects.” Area builders did say that some building materials went up in price after the storm, describing it as an “availability scare,” but some prices went down during the summer of 2013. Susan Ogan, of Neil Ogan Construction said that “our biggest thing is that people cannot find a lot they can afford and still say within their budget for the overall project.” Although single-family homes aren’t being built, apartments are. “We’ve got a 24-unit apartment going in as we speak,” said Mr. Lawrence. That, some feel, may be responsible for the lack of demand for single-family homes. Read the court decision
Read the full story...
Reprinted courtesy of

Orion Group Holdings Honored with Leadership in Safety Award

October 09, 2023 — Orion Group Holdings, Inc.
HOUSTON, Oct. 06, 2023 (GLOBE NEWSWIRE) -- Orion Group Holdings, Inc. (NYSE: ORN) ("Orion" and "Company"), a leading specialty construction and engineering company today announced it received the Company Award for Leadership in Safety from the Council of Dredging and Marine Construction Safety (CDMCS). The award, presented at the 2023 CDMCS Annual Awards Dinner in Washington, D.C. on September 28, recognizes outstanding safety leadership in the dredging and marine construction industry. Orion Group Holdings was recognized for advancing a safety-first culture through safety-conscious policies and procedures in the workplace, mentoring others in safety, training on identifying and properly controlling hazards, and placing high personal value on collaborative and proactive work toward improving safety. Travis Boone, President and Chief Executive Officer of Orion Group Holdings, accepted the award at the ceremony. "I am honored to accept this award on behalf of our Orion team, who work collaboratively every day to meet exacting standards while safely delivering world-class marine construction and dredging services to our customers," said Orion Group Holdings CEO Travis Boone. "Our safety-through-leadership success is born out of a strong advocacy for accident prevention, innovative training and a commitment to exceeding regulatory compliance. Being responsible and accountable is a priority for every team member, with special emphasis on performing every task safely, every time." About Orion Group Holdings Orion Group Holdings, Inc., a leading specialty construction company serving the infrastructure, industrial and building sectors, provides services both on and off the water in the continental United States, Alaska, Hawaii, Canada and the Caribbean Basin through its marine segment and its concrete segment. The Company's marine segment provides construction and dredging services relating to marine transportation facility construction, marine pipeline construction, marine environmental structures, dredging of waterways, channels and ports, environmental dredging, design, and specialty services. Its concrete segment provides turnkey concrete construction services including place and finish, site prep, layout, forming, and rebar placement for large commercial, structural and other associated business areas. The Company is headquartered in Houston, Texas with regional offices throughout its operating areas. https://www.oriongroupholdingsinc.com. Read the court decision
Read the full story...
Reprinted courtesy of

Survey: Workers Lack Awareness of Potentially Hazardous Nanomaterials

December 11, 2018 — Scott Van Voorhis – Engineering News-Record
Microscopic nanoparticles are part of the mix in nearly 600 construction products. The particles add strength, durability and other desired characteristics. Read the court decision
Read the full story...
Reprinted courtesy of Scott Van Voorhis, ENR
ENR may be contacted at ENR.com@bnpmedia.com

SFAA Commends U.S. Senate for Historic Bipartisan Infrastructure Bill

August 16, 2021 — The Surety & Fidelity Association of America
August 10, 2021 (WASHINGTON, DC) – The Surety & Fidelity Association of America (SFAA) commends the U.S. Senate for passing the historic, bipartisan Infrastructure Investment and Jobs Act. The $1.2 trillion deal will lay the foundation for extensive improvements in the nation’s roadways, bridges, railways, waterways and broadband access. “Investing in infrastructure will create millions of jobs across the country, growing our national and local economies in both the short and long term,” said SFAA president and CEO, Lee Covington. “The surety industry fully supports this investment and will continue to provide the essential protections necessary to support our country’s infrastructure needs through our suite of products and services.” SFAA also commends the inclusion of the Van Hollen 2354 amendment to the bill, accepted by a unanimous vote of 97-0. The amendment requires payment and performance bonds on all federally-financed infrastructure projects receiving loans and grants under the Transportation Infrastructure Finance and Innovation Act (TIFIA), protecting taxpayers’ dollars, ensuring project completion, protecting local small business contractors and workers, and promoting economic growth. The Surety & Fidelity Association of America (SFAA) is a trade association of more than 425 insurance companies that write 98 percent of surety and fidelity bonds in the U.S. SFAA is licensed as a rating or advisory organization in all states and it has been designated by state insurance departments as a statistical agent for the reporting of fidelity and surety experience. https://www.surety.org/ Read the court decision
Read the full story...
Reprinted courtesy of

Landlords Beware: Subordination Agreements

May 03, 2017 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In the recent Arizona Court of Appeals case Earle Investments, LLC v. Southern Desert Medical Center Partners, 762 Ariz. Adv. Rep. 12 (2017), the Court of Appeals addressed the question of the scope of a subordination agreement signed by the property owner (Lessor/Landlord) at the request of the Lessee/Tenant and Lessee/Tenant’s Lender. In general, by subordination, Party No. 1 with a higher/better lien priority agrees to allow Party No. 2 (usually a lender providing construction funds for the overall betterment of the property) to get a lien position in front of Party No. 1. Party No. 1 presumably believes the switch of lien position in return for someone else paying for the property improvements will benefit Party No. 1 in the long run by resulting in an increase in the value of Party No. 1’s position. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

Federal Court Predicts Coverage In Utah for Damage Caused By Faulty Workmanship

April 03, 2013 — Tred Eyerly
The federal district court predicted that the Utah Supreme Court would find that damage to property other than the insured's work product is unexpected and arises from an occurrence. Cincinnati Ins. Co. v. AMSCO Windows, 2013 U.S. Dist. LEXIS 15999 (D. Utah Feb. 5, 2013). The insured, AMSCO Windows, installed windows in new homes constructed in Nevada. A number of homeowners asserted claims against the contractors who built their homes, alleging numerous construction defects, including the windows, and that the defects caused property damage to their homes. The contractors, in turn, asserted claims against AMSCO. The insurer, Cincinnati Insurance Company, filed for a declaratory judgment that it had no duty to defend or indemnify AMSCO. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Texas Federal Court Upholds Professional Services Exclusion to Preclude Duty to Defend

March 16, 2020 — Jeremy S. Macklin - Traub Lieberman Insurance Law Blog
In Project Surveillance, Inc. v. The Travelers Indemnity Company, No. 4:19-CV-03324, 2020 WL 292247 (S.D. Tex. Jan. 21, 2020), a Texas federal court held that a professional services exclusion in a commercial general liability policy precluded Travelers’ duty to defend its insured. The underlying lawsuit was a wrongful death action brought by the family of a worker killed on a construction site. Project Surveillance was present at the construction site “to provide safety supervision or other services.” The underlying lawsuit alleged that Project Surveillance negligently failed to inspect or adequately inspect the project and failed to warn or adequately warn the decedent of a dangerous condition. The underlying lawsuit also alleged that Project Surveillance was negligent in failing to stop work. At the time of the incident, Project Surveillance had commercial general liability insurance through Travelers and professional liability insurance through RLI. RLI agreed to defend Project Surveillance in the underlying lawsuit. Travelers, however, denied owing a duty to defend or indemnify based on an exclusion for “bodily injury” arising out of the rendering or failure to render any “professional service.” The Traveler policy defined the term “professional services” to mean any service requiring specialized skill or training, including “failure to prepare [. . .] any warning,” “supervision,” “inspection,” “control,” “surveying activity or service,” “job site safety,” “construction administration,” and “monitoring [. . .] necessary to perform and of [those] services.” Read the court decision
Read the full story...
Reprinted courtesy of Jeremy S. Macklin, Traub Lieberman
Mr. Macklin may be contacted at jmacklin@tlsslaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES