Seattle Washington Building Expert Directory

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Suing the Lowest Bidder on Public Construction Projects

September 17, 2015 — Craig Martin – Construction Contractor Advisor
The California Court of Appeals has allowed the second lowest bidders on public construction projects to sue the lowest bidder where it appears that the lowest bidder was only the lowest because it paid its employees less than the established prevailing wage. This is a novel theory for recovery, but may provide for an opportunity to challenge improperly low bids. Background Between 2009 and 2012, American Asphalt outbid two asphalt companies on 23 public works projects, totaling nearly $15 million. The two asphalt companies sued American Asphalt alleging that they were the second lowest bidder all 23 construction projects and they would have been the lowest had American Asphalt paid its employees the required prevailing wage. Importantly, the municipality awarding the contracts was not sued by the second lowest bidders. Instead, the second lowest bidders alleged that American Asphalt intentionally interfered with a business expectancy and sought damages from American Asphalt, specifically the profit that they lost by not performing these contracts. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Can an Architect, Hired by an Owner, Be Sued by the General Contractor?

September 10, 2014 — Craig Martin – Construction Contractor Advisor
As is often the answer in this blog, maybe. And, it will likely depend on which state’s law is applied. Over the last few weeks, courts around the country have reached differing conclusions on whether a general contractor may sue an architect that it did not hire. Here’s the situation: The owner hires an architect to draft plans for a project. The project is then put out for bid and the owner hires a general contractor for the work. The general contractor and architect do not enter into a contract with each other. If, during construction, the general contractor finds fault with the plans, it may seek Request for Information and Change Orders, to shore up the perceived problems with the plans. Ultimately, the general contractor may sue the architect to recover damages it suffered in completing the project. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Rise in Home Building Helps Other Job Sectors

December 11, 2013 — CDJ STAFF
With home building on the rebound, the latest jobs report shows that the construction industry has added 17,000 jobs in the last year. But that’s not the only increase in employment that can be credited to the homebuilding industry. Most homes are built out of wood. That’s why the timber industry was able to create 2,200 new jobs. According to the Wall Street Journal’s Marketwatch, that’s the biggest jump in 16 years. Moving closer to homes, the makers of wood products have added 600 jobs, with five months of increasing employment. Finally, someone has to sell those homes. There are 2,100 more people working in real estate. Neal Dutta, head of economics at Renaissance Macro Research notes that “from the production of building materials to the construction of homes to the sales of homes, there was a confirmation of an ongoing housing recovery and all despite a sharp back-up in rates.” Read the court decision
Read the full story...
Reprinted courtesy of

Breaking the Impasse by Understanding Blame

January 13, 2020 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday (on a Thursday) here at Construction Law Musings, Victoria Pynchon (@vickiepynchon) joins us for the 4th time. Victoria is an attorney-mediator with ADR Services, Inc. in Century City; an arbitrator with the American Arbitration Association in Los Angeles, California; and, a negotiation consultant and trainer world-wide. Victoria co-founded She Negotiates Training and Consulting in 2010 and writes for ForbesWoman at its She Negotiates blog. She is the author of one of my favorite books on conflict resolution, A is for A*@!#, the Grownups’ ABC’s of Conflict Resolution reviewed at Musings here. First Let’s Talk About Anger Please raise your hand if your clients — corporate clients — are angry about the burdens of litigation. Irritated with the document “demands” and interrogatories. Frustrated about the e-discovery. Ticked off at the way opposing counsel asks them questions as if they’re lying. Hot under the collar about the mounting attorneys’ fees and the distance between the day suit was filed and the probable day on which a trial might eventually be scheduled. Simmering about the time the litigation consumes, time they’d prefer to be spending doing their actual jobs — planning for and implementing business strategies for a profitable future instead of fighting about the unprofitable past. And we’re not even talking about your clients’ anger at the defendant who has stolen their intellectual property or stopped worked at the construction site or refused to release the remaining funds in the construction loan account. And if you believe that powerful people in highly successful and profitable businesses do not fear that litigation might hurt their careers, think again. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

2017 Construction Outlook: Slow, Mature Growth, but No Decline, Expected

December 21, 2016 — Garret Murai – California Construction Law Blog
As we count down the remaining days of 2016 (thank God) it’s time to think about what the new year will bring (I’m good with pretty much anything at this point). The economists at Dodge Data & Analytics have a few predictions. According to their 2017 Dodge Construction Outlook, they predict that U.S. construction starts will increase modestly in 2017, up 5% to $713 billion, after rather anemic growth in 2016 following several years of steady growth. According to Robert Murray, chief economist for Dodge Data & Analytics, while the first half of 2016 lagged behind construction activity in 2015, that shortfall grew smaller as the year progressed, easing concern that the construction industry might be in the early stage of a cyclical decline. Rather, according to Murray, it appears that the construction industry has now entered a more mature phase of expansion, one characterized by slower rates of growth than during the 2012-2015 period and that construction spending can be expected to see moderate gains through 2017 and beyond[.] Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Monitoring Building Moisture with RFID – Interview with Jarmo Tuppurainen

February 22, 2018 — Aarni Heiskanen – aec business
I met Jarmo, the Technology Manager at Helsinki Metropolia University of Applied Sciences, at the leading event for housing markets in Helsinki (Asuntomarkkinat). He and his team had set up an impressive display of devices and structures in the KIRA-digi showroom. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, aec business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

It’s a COVID-19 Pandemic; It’s Everywhere – New Cal. Bill to Make Insurers Prove Otherwise

August 17, 2020 — Scott P. DeVries & Andrea DeField - Hunton Andrews Kurth
On June 29, in a development that may fundamentally change the landscape for California businesses which have sustained COVID-19 related business interruption loss, two California legislators amended pending legislation to address several of the most hotly contested issues regarding insurance recovery for these devastating losses. The bill, Assembly Bill 1552, focuses on All-Risk property insurance policies. As amended, it would create a “rebuttable presumption” that COVID-19 was present on and caused physical damage to property which was the direct cause of business interruption. A similar rebuttable presumption would apply to orders of civil authority coverage and to ingress/egress coverage. The bill would further prohibit COVID-19 from being construed as a pollutant or contaminant for purposes of any policy exclusion unless the exclusion specifically referred to viruses. The bill would apply to any All-Risk policy in effect on or after March 4, 2020 and is written to satisfy the standards for an “urgency” statute, taking effect immediately upon being signed into law. Reprinted courtesy of Scott P. DeVries , Hunton Andrews Kurth and Andrea DeField, Hunton Andrews Kurth Mr. DeVries may be contacted at sdevries@HuntonAK.com Ms. DeField may be contacted at adefield@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES