Fairfield Connecticut Building Expert Directory

Risk Management and Contracting after Hurricane Irma: Suggestions to Avoid a Second Disaster

September 14, 2017 — Stephen H. Reisman, Gary M. Stein & Adam P. Handfinger – Peckar & Abramson, P.C.
Peckar & Abramson attorneys have assisted contractors in the immediate aftermath of several Hurricanes, including Andrew in 1992, Wilma in 2005, Ike in 2008, and Sandy in 2012. Based on this experience, we offer some post-storm strategies for contracting and risk management in three situations:

Ongoing projects in the area directly impacted by the storm;
Projects remote from the storm-impacted areas, but which may be affected by material or labor shortages; and
Requests for assistance in recovery/clean-up/rebuild eff orts, which would be new projects.

Projects Directly Impacted By Hurricane Irma: 1. Immediately review each Owner contract to determine what notices are required for delays and/or extra costs arising from the storm. Contract notice requirements and time limits vary, whether for force majeure or other similar time and compensation rights. There is no effective one-size-fits-all solution. While the initial notice letters will likely look very similar, you should make sure that each is sent as required by the contract. Check each contract’s requirements for particulars regarding content, the form of delivery, and parties and individuals designated to receive the letters as well as carbon copy recipients like the architect. Follow-up notices and time periods differ from contract to contract and should be tracked so that if, for example, a follow-up notice is required in a week per the contract terms, it is tracked to ensure compliance. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Stephen H. Reisman, Gary M. Stein and Adam P. Handfinger Mr. Reisman may be contacted at sreisman@pecklaw.com Mr. Stein may be contacted at gstein@pecklaw.com Mr. Handfinger may be contacted at ahandfinger@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Breaking Down Homeowners Association Laws In California

April 03, 2019 — Lauren Hickey - Bremer Whyte Brown & O'Meara LLP
Purpose of HOAs Property ownership often combines elements of individual and common ownership interests. For example, a property owner may individually own his or her living quarters, but also own a common interest in amenities that are considered too expensive for a single homeowner to purchase individually (such as a pool, gym, or trash collection service). Properties with such elements usually take the form of apartments, condominiums, planned developments, or stock cooperatives (together known as “common interest developments” or “CIDs”). Whenever a CID is built, California law requires the developer to organize a homeowner association (or “HOA), which can take several different names, including “community association”. Initially, the developer relies on the HOA to market the development to prospective buyers. Once each unit in the development is sold, management of the HOA is passed to a board of directors elected by the homeowners. At that point, the primary purpose of the HOA shifts to maintenance of common amenities and enforcement of community standards. Dues/Assessments HOAs generally charge each homeowner monthly or annual dues to cover the cost of their services. HOAs may also charge special assessments to cover large, abnormal expenses, such as the cost of upgrades or improvements. The amount charged in dues and assessments is established by the HOA’s board of directors, within the limits set by the HOA’s governing documents and California Civil Code section 1366. Section 1366 provides that HOA dues may not be increased by more than 20 percent of the amount set in the previous year, and the total amount of any special assessments charged in a given year generally may not exceed 5 percent of the HOA’s budgeted expenses. Read the court decision
Read the full story...
Reprinted courtesy of Lauren Hickey, Bremer Whyte Brown & O'Meara LLP

Contractor's Agreement to Perform Does Not Preclude Coverage Under Contractual Liability Exclusion

January 31, 2014 — Tred R. Eyerly – Insurance Law Hawaii
In a much anticipated decision, the Texas Supreme Court ruled that a general contractor who agrees to perform its work in a good and workmanlike manner does not "assume liability" for damages arising out of its defective work so as to trigger the Contractual Liability Exclusion. Ewing Constr. Co., Inc. v. Amerisure Ins. Co., 2014 Tex. LEXIS 39 (Tex. Jan.17, 2014). Ewing signed an agreement with the School District to serve as general contractor to renovate and build additions to a school, including tennis courts. After construction was completed, the tennis courts started flaking, crumbling, and cracking. The School District filed suit, alleging breach of contract and negligence. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Sacramento Army Corps District Projects Get $2.1 Billion in Supplemental Appropriation

September 04, 2018 — Greg Aragon - Engineering News-Record
The U.S. Army Corps of Engineers Sacramento District has received supplemental funding for five District projects, totaling an investment of more than $2.1 billion in flood risk management efforts. Read the court decision
Read the full story...
Reprinted courtesy of Greg Aragon, ENR
ENR may be contacted at ENR.com@bnpmedia.com

New Illinois Supreme Court Trigger Rule for CGL Personal Injury “Offenses” Could Have Costly Consequences for Policyholders

March 09, 2020 — Michael S. Levine & Kevin V. Small - Hunton Insurance Recovery Blog
The Illinois Supreme Court’s recent decision in Sanders v. Illinois Union Insurance Co., 2019 IL 124565 (2019), announced the standard for triggering general liability coverage for malicious prosecution claims under Illinois law. In its decision, the court construed what appears to be a policy ambiguity against the policyholder in spite of the longstanding rule of contra proferentem, limiting coverage to policies in place at the time of the wrongful prosecution, and not the policies in effect when the final element of the tort of malicious prosecution occurred (i.e. the exoneration of the plaintiff). The net result of the court’s ruling for policyholders susceptible to such claims is that coverage for jury verdicts for malicious prosecution – awarded in today’s dollars – is limited to the coverage procured at the time of the wrongful prosecution, which may (as in this case) be decades old. Such a scenario can have costly consequences for policyholders given that the limits procured decades ago are often inadequate due to the ever-increasing awards by juries as well as inflation. Moreover, it may be difficult to locate the legacy policies and the insurers that issued such policies may no longer be solvent or even exist. A copy of the decision can be found here. The Sanders case arose out of the wrongful conviction of Rodell Sanders in 1994 by the City of Chicago Heights (the “City”). Mr. Sanders sought recompense for, among other things, malicious prosecution through a federal civil rights action against the City. In September 2016, Mr. Sanders obtained a consent judgment for $15 Million; however, at the time of the wrongful conviction, seventeen years earlier, the City’s only applicable insurance policy provided just $3 million in coverage. The City contributed another $2 million towards the judgment and, in exchange for Mr. Sanders’s agreement not to seek the $10 million balance from the City, assigned its rights under the policies for the 2012 to 2014 period. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Kevin V. Small, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Small may be contacted at ksmall@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Blackstone Said in $1.7 Billion Deal to Buy Apartments

January 21, 2015 — Hui-yong Yu – Bloomberg
Blackstone Group LP (BX), the biggest owner of U.S. single-family houses, agreed to buy 36 apartment properties across the country for about $1.7 billion as it expands its rental business, according to two people with knowledge of the transaction. The low-rise, garden-style properties are being sold by Praedium Group, a New York-based real estate investment firm, and contain about 11,000 apartments, said the people, who asked not to be identified because the deal is private. About half of the buildings are in California, Washington, D.C., and Boston, with the rest located around the U.S., they said. Read the court decision
Read the full story...
Reprinted courtesy of Hui-yong Yu, Bloomberg
Hui-yong Yu may be contacted at hyu@bloomberg.net

Consolidated Case With Covered and Uncovered Allegations Triggers Duty to Defend

May 20, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Illinois Court of Appeals held that the insurer had a duty to defend a consolidated case that included one complaint alleging intentional acts and another complaint alleging negligence. Farmers Auto. Ins. Ass'n v. Neumann, 2015 Il. App. 140026 (Ill. Ct. App. March 24, 2015, reh'g denied March 24, 2015). Neumann allegedly hit Bitner with his automobile as Bitner, a police offier, was directing traffic. Bitner sued Neumann, alleging intentional assault and intentional battery. Farmers rejected Neumann's tender because the policy did not cover intentional acts. Farmers filed for a declaratory judgment. In his answer, Neumann included an affidavit stating that he did not intend to strike or cause bodily harm to Bitner. The trial court granted the motion to strike the affidavit. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Reminder: Your MLA Notice Must Have Your License Number

November 26, 2014 — Christopher G. Hill – Construction Law Musings
Remember a couple of years ago when the Virginia mechanic’s lien rules changed to require inclusion of a claimant’s contractor’s license number (where a license is required)? If not, then this is a reminder of that particular wrinkle in the strictly interpreted mechanic’s lien statute. This requirement applies to all mechanic’s lien memoranda and, like all parts of this crazy statute, will invalidate a lien if not met. Well, another change to the statute happened with a bit less fanfare. The change back in 2013 that came along with the license number requirement for a lien memorandum is a change in the mechanic’s lien agent notice requirement that applies to residential construction. The basic requirement, namely that those performing residential construction must notify any mechanic’s lien agent (“MLA”) listed on a building permit within 30 days of starting work that they are on the job and could file a lien, has not changed. What the amendments to the lien statutes in 2013 added was a requirement that the notice, like a lien memorandum, must include the contractor’s or subcontractor’s license number. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES