Seattle Washington Building Expert Directory

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Former Mayor Arrested for Violating Stop Work Order

October 30, 2013 — CDJ STAFF
The former mayor of Springfield, Florida has been arrested on charges of insurance fraud. More than a year ago, an investigator for the Bureau of Workers’ Compensation found that an employee of Walker’s construction company was working without workers’ compensation and issued a stop work order. Walker’s employees continued work. The charges were delayed because Walker challenged the stop work order. Once it was determined that the stop work order was issued properly, Walker was charged with a third-degree felony. Read the court decision
Read the full story...
Reprinted courtesy of

After 15 Years, Settlement Arrested at San Francisco's Millennium Tower

June 26, 2023 — Nadine M. Post - Engineering News-Record
After overcoming several snags, the team for the voluntary effort to stem future significant settlement and tilting at San Francisco’s 645-ft-tall Millennium Tower has declared the project a success, now that loads have been fully transferred to 18 new perimeter piles driven to bedrock. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Not so Fast! How Does Revoking Acceleration of a Note Impact the Statute of Limitations?

July 30, 2018 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
Introduction Lenders routinely accelerate notes after a default occurs, calling the entire loan due immediately. Less regularly, a lender may change its mind and unilaterally revoke the acceleration. Rarely, however, does a lender fail to foreclose on its real property collateral before the statute of limitations expires. In Andra R. Miller Designs, LLC v. U.S. Bank, N.A., 244 Ariz. 265, 418 P.3d 1038 (Ct. App. 2018), a unique set of facts involving these issues led the Arizona Court of Appeals to hold that proper revocation of acceleration resets the statute of limitations. The Facts In Miller, a lender made a $1,940,000 loan evidenced by a promissory note and secured by a deed of trust against a home in Paradise Valley, Arizona. The borrower defaulted in September 2008. The default prompted the lender to notice a default, accelerate the note, and initiate a trustee’s sale of the home in 2009. After the lender accelerated the note, the six year statute of limitations began to run. See A.R.S. § 12-548(A)(1) and A.R.S. § 33-816. Pretty standard facts so far, right? Don’t worry, it gets a bit more convoluted. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

Las Vegas Student Housing Developer Will Name Replacement Contractor

February 15, 2018 — John Guzzon – ENR
More than four months after construction abruptly stopped on a $76-million student housing project for the University of Nevada at Las Vegas, the developer is seeking a new contractor. Read the court decision
Read the full story...
Reprinted courtesy of John Guzzon, Engineering News- Record
Mr. Guzzon may be contacted at ENRSouthWestEditor@enr.com

Insurer Fails to Establish Prejudice Due to Late Notice

October 17, 2022 — Tred R. Eyerly - Insurance Law Hawaii
Summary judgment awarded to the insurer was reversed because the insurer presented no evidence of prejudice caused by untimely notice. Perez v. Citizens Prop. Ins. Corp., 2022 Fla. App. LEXIS 5435 (Fla. Ct. App. Aug. 10, 2022). The insureds' home suffered water damage due to Hurricane Irma around September 10, 2017. A claim was submitted to Citizens on November 27, 2018. Citizens had an independent adjuster inspect, but then denied the claim due to untimely notice. The insureds sued and Citizens moved for summary judgment. Citizens argued it was prejudiced because it could not confirm the cause of the loss or the property damage attributed to it. The court agreed that the insureds' notice was untimely. The insureds were notified by tenants renting the property that leaks appeared around the time of Hurriane Irma. The policy language, however, placed the burden to rebut the presumption of prejudice caused by late notice on Citizens. Whether the insurer was prejudiced was a question of fact. Citizens failed to demonstrate any prejudice due to the untimely notice. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

A Court-Side Seat: Waters, Walls and Pipelines

August 03, 2020 — Anthony B. Cavender - Gravel2Gavel
Several interesting decisions have recently been made by federal and state courts. FEDERAL APPELLATE COURTS The U.S. Seventh Circuit Court of Appeals – ARCO Shifts from State to Federal and No Vigor for VIM On June 18, 2020, the court decided the case of Baker, et al. v. ARCO, holding that the revised federal removal statutes authorize the removal to federal court of a state-filed complaint against several defendants by the former residents of an Indiana housing complex who contended that the defendants were responsible for the industrial pollution attributed to the operations of a now-closed industrial plant. The housing complex was constructed at the site of the former U.S. Smelter and Lead Refinery. During the Second World War, the plant produced products for the use of the government war effort, thus triggering the applicability of the federal removal statutes. On June 25, 2020, the court decided the case of Greene, et al. v. Westfield Insurance Company. As the court notes, this is a matter that “began as a case about environmental pollution and evolved into a joint garnishment action.” An Indiana wood recycling facility, VIM Recycling, was the subject of many complaints by nearby residents that its operations and waste disposal activities exposed then to dust and odors in violation of federal law and triggered state tort law claims. VIM was sued in state court, but neglected to notify its insurer, as required by its insurance policy with Westfield Insurance. One thing led to another, and a default judgment in the amount of $ 50 million was entered against VIM. Since VIM at that point had no assets, the plaintiffs and later VIM sought recovery from Westfield. When this dispute landed in federal court, the court, after reviewing the policy, concluded that there was a provision excluding coverage when the insured knew it had these liabilities when it purchased the insurance. As a result, the lower court dismissed the lawsuit, and this decision has been affirmed by the Seventh Circuit. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

A Court-Side Seat: NWP 12 and the Dakota Access Pipeline Easement Get Forced Vacations, while a Potential Violation of the Eighth Amendment Isn’t Going Anywhere

August 10, 2020 — Anthony B. Cavender - Gravel2Gavel
Here’s a report on several new decisions made over the past few days. U.S. SUPREME COURT U.S. Army Corps of Engineers v. Northern Plains Resources Council On July 8, 2020, the Court has issued a partial stay of the decision of the U.S. District Court for Montana, which had held that the nationwide use by the Corps of Engineers of its Nationwide Permit 12 to permit oil and gas pipelines must be vacated because the Corps, when it reissued these permits in 2012, failed to follow the requirements of the Endangered Species Act. The breadth of this ruling seems to have surprised and alarmed many past and perspective permittees of the Corps. The stay will not apply to the ongoing Ninth Circuit litigation. FEDERAL COURTS OF APPEAL Vega, et al. v. Semple (The U.S. Court of Appeals for the Second Circuit) On June 29, 2020, the court refused to dismiss a putative class action by past and present inmates of Connecticut’s Garner Correctional Institution who alleged that state correctional officials exposed them to excessive amounts of radon gas in violation of the Eighth Amendment. These officials are alleged to have been “deliberately indifferent” to inmate safety. A 1993 Supreme Court decision, Helling v. McKiney, clearly established the law in this area, and the Garner facility opened in 1992. The defense clams of limited immunity as to federal law violations were rejected. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES