Seattle Washington Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Not Remotely Law as Usual: Don’t Settle for Delays – Settle at Remote Mediation

May 25, 2020 — Victor J. Zarrilli, Robert G. Devine & Michael W. Horner - White and Williams LLP
The emergence and rapid spread of COVID-19 has created extraordinary circumstances that have significantly impacted how we go about living, working and interacting with one another. The practice of law is no exception. While most cases have been postponed and some extended indefinitely, the issues and disputes that first triggered the litigation remain. In fact, the burdens created by social distancing and other responses to the COVID-19 outbreak have served to only increase these disputes and create an urgent need in some for quick resolution. In our previous article, we summarized some of the best practices that should be applied when taking and defending depositions in a remote, virtual setting. That technology can also offer the same benefits for alternative dispute resolutions. If planned properly, the use of technology allows remote mediations to be conducted as seamlessly as in-person mediations and, in some circumstances, affords additional benefits that can achieve the best possible resolution for all sides. This article summarizes the opportunities technology has created by which parties can attempt to resolve their disputes through alternative dispute resolution methods, even in a time of social distancing. Reprinted courtesy of White and Williams LLP attorneys Victor J. Zarrilli, Robert G. Devine and Michael W. Horner Mr. Zarrilli may be contacted at zarrilliv@whiteandwilliams.com Mr. Devine may be contacted at deviner@whiteandwilliams.com Mr. Horner may be contacted at hornerm@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Give Way or Yield? The Jurisdiction of Your Contract Does Matter! (Law note)

March 05, 2015 — Melissa Dewey Brumback – Construction Law in North Carolina
Have you ever been to England? If so, you’ve likely seen their version of our “Yield” sign– the “Give Way” sign. It is a bit jarring to those from this side of the “big pond”. Similarly, contracts can be worded differently– and, interpreted differently– depending on the state that you are in. This is why it is always a good idea to have your contract or proposal vetted for the state(s) where you provide professional services. When confronted with a “give way” sign you have the general idea of yielding, but might be confused by that whole “left side of the road” thing in some countries, where if you are turning right, you must give way to all vehicles coming towards you including those turning left. Likewise, you might have a good understanding of your construction contract in one state, but not how it would be interpreted in another state. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback may be contacted at mbrumback@rl-law.com

Luxury Homes Push City’s Building Permits Past $7.5 Million

December 30, 2013 — CDJ STAFF
The city of Ardmore, Oklahoma is seeing a building boom with the total value of building permits issued by the city in November slightly exceeded $7.5 million, reports Ardmoreite.com. Most of that total comes from residential construction, with the bulk of it coming from just three homes. While Lance Windel Construction plans on building 46 homes, the top value of those homes will be $153,000. The total value for the homes being built by three other firms is more $6.4 million, and those contractors are building just one home each. Read the court decision
Read the full story...
Reprinted courtesy of

Ensuring Efficient Arbitration of Construction Disputes Involving Mechanic’s Liens

February 18, 2020 — Robert G. Campbell & Trevor B. Potter - Construction Executive
There may be tension between the enforcement of statutory mechanic’s lien claims when a contractual dispute resolution provision calls for arbitration. Once the parties are in arbitration, it may not be clear whether the arbitrator has authority to make factual determinations regarding amount and validity of mechanic’s liens, and whether courts are bound by these determinations. This uncertainty stems from the fact that in most states a mechanic’s lien can only be enforced by a court of competent jurisdiction. Indeed, many mechanic’s liens statutes define foreclosure as a “judicial process,” and courts generally have exclusive jurisdiction to issue orders foreclosing on real property1. The risk for contractors and owners is that they will spend time and money re-litigating factual issues related to proving elements of a mechanic’s lien claim, including the proper lien amount, timeliness and other prerequisites. Without a clear understanding of what issues and elements are arbitrable, the parties run the risk that an arbitrator will rule on certain elements only to find out during post-arbitration lien foreclosure proceedings that the arbitrator lacked authority to make determinations on those elements. Questions therefore arise whether a court will enforce the arbitrator’s determinations and whether the parties must relitigate mechanic’s lien issues creating a further risk of inconsistent rulings. These risks can be minimized through arbitration provisions which address these issues, express requests in arbitration demands and by ensuring that arbitration awards contain explicit determinations of mechanic’s liens issues. Reprinted courtesy of Robert G. Campbell & Trevor B. Potter, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Potter may be contacted at tpotter@coxcastle.com Mr. Campbell may be contacted at rcampbell@coxcastle.com Read the court decision
Read the full story...
Reprinted courtesy of

Equal Access to Justice Act Fee Request Rejected in Flood Case

January 06, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The insured's claim for fees under the Equal Access to Justice Act (EAJA) for seeking coverage under a flood policy was rejected. Hampson v. Wright Nat'l Flood Ins. Co., No. 4:19-cv-10083-KMM (S.D. Fla. Aug. 11, 2019)(Order on Motion to Dismiss). The order is here. The insurer did not compensate plaintiff for flood-related damages under the terms of a Standard Flood Insurance Policy (SFIP). The insurer was a Write-Your-Own (WYO) Program insurance carrier participating in the National Flood Insurance Program (NFIP). By statute, a WYO carrier acts as a "fiscal agent" and "fiduciary" of the United States. The insured's property suffered damage from a hurricane. The insured sued the carrier for breach of contract and attorney's fees under EAJA. The insurer moved to dismiss the claim for fees under EAJA. A party could recover fees and costs under the EAJA as the prevailing party in a case "brought by or against the United States . . . unless the court finds the position of the United States was substantially justified." 28 U.S.C. 2412 (d) (1) (A), (b). The statute defined the "United States" to include "any agency and any official of the United States acting in his or her official capacity." However, attorney's fees were not recoverable under the EAJA in cases for breach of an SFIP brought against a WYO program insurance carrier participating in the NFIP because WYO carriers were not considered "agencies" under the EAJA. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Home Construction Slows in Las Vegas

November 27, 2013 — CDJ STAFF
Although home builders in the Las Vegas area are doing better than they were in 2012, growth is still slow and October saw a decline in the sale of new homes. However, as with other areas, the average home price actually increased over prior months, despite the cooling off the actual number of sales. Taken as a whole though, 2013 looks a lot better than 2012, with 44% more homes sold this year. Dennis Smith, the president of Home Builders Research said that 2013 “will be remembered as ‘the year of recovery,’” but added that “there is still a long path ahead for everyone to feel a sense of comfort.” Read the court decision
Read the full story...
Reprinted courtesy of

How a 10-Story Wood Building Survived More Than 100 Earthquakes

June 26, 2023 — Todd Woody - Bloomberg
One sunny morning last month, an earthquake jolted northeast San Diego. Minutes later, another temblor hit, causing a 10-story wood building to sway. The quakes, though, were triggered by a computer and the shaking was confined to a 1,000-square-foot platform on which the building — a full-size test model — stood. The structure is the tallest ever subjected to simulated earthquakes on the world’s largest high-performance “shake table,” which uses hydraulic actuators to thrust the steel platform through six degrees of motion to replicate seismic force. The shake-table trials at a University of California at San Diego facility are part of the TallWood Project, an initiative to test the seismic resiliency of high-rise buildings made of mass timber. An engineered wood building material, mass timber is increasingly popular as a more sustainable alternative to carbon-intensive concrete and steel. Read the court decision
Read the full story...
Reprinted courtesy of Todd Woody, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES