Fairfield Connecticut Building Expert Directory

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Biden Administration Focus on Environmental Justice Raises Questions for Industry

March 22, 2021 — Karen C. Bennett, Jane C. Luxton, Rose Quam-Wickham & William J. Walsh - Lewis Brisbois
The Biden Administration has left no doubt that it intends to prioritize environmental justice (EJ) in implementing energy and environmental policy. While EJ is not new – in fact, President Clinton signed the first EJ Executive Order (EO 12898) in 1994 – the new Administration’s plan to expand the concept to include “climate justice” and “health equity” is both novel and undefined. Similar to actions taken on climate change (see our previous alert from January 28), President Biden has announced plans for elevating EJ by designating new Cabinet level offices, intensifying enforcement, and advocating for Congressional action. Given the likelihood of serious impacts from these sweeping changes, industry will need to step up engagement as these concepts are integrated into regulatory decisions and U.S. positions globally. Authority for addressing injustice caused by environmental pollution that disproportionately affects certain communities is found in Title VI of the Civil Rights Act of 1964. The Act imposed a responsibility on the Environmental Protection Agency (EPA or Agency) to ensure that its funds are not being used to subsidize discrimination, based on race, color, or national origin, making EPA’s Office of Civil Rights responsible for the investigation and enforcement of Title VI within the Agency. President Clinton relied on this authority in signing EO 12898, which directed federal agencies to identify and address disproportionately high adverse human health and environmental effects of their programs, policies, and activities on minority and, going beyond the protections covered by Title VI, low-income populations. Reprinted courtesy of Karen C. Bennett, Lewis Brisbois, Jane C. Luxton, Lewis Brisbois, Rose Quam-Wickham, Lewis Brisbois and William J. Walsh, Lewis Brisbois Ms. Bennett may be contacted at Karen.Bennett@lewisbrisbois.com Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com Ms. Quam-Wickham may be contacted at Rose.QuamWickham@lewisbrisbois.com Mr. Walsh may be contacted at William.Walsh@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Tesla Powerwalls for Home Energy Storage Hit U.S. Market

May 12, 2016 — Dana Hull – Bloomberg
To Steve Yates, the best thing about his new Tesla Powerwall is that he doesn’t have to worry anymore about the lights going out during a storm. Or maybe it’s how cool an addition it is to the entryway of his house in Monkton, Vermont. “I’ve always wanted to have a backup power source,” said Yates, who was without electricity for 36 hours during Hurricane Irene in 2011. He also admires the Powerwall’s sleek white contours. “It’s kind of art-deco looking.” A year after Elon Musk unveiled the Powerwall at Tesla Motors Inc.’s design studio near Los Angeles, the first wave of residential installations has started in the U.S. The 6.4-kilowatt-hour unit stores electricity from home solar systems and provides backup in the case of a conventional outage. Weighing 214 pounds and standing about 4-feet tall, it retails for around $3,000. But hookup by a trained electrician is required, as is something called a bi-directional inverter that converts direct-current electricity into the kind used by dishwashers and refrigerators. The costs add up quickly -- which has fueled skepticism about Musk’s dream of changing the way the world uses energy. Read the court decision
Read the full story...
Reprinted courtesy of Dana Hull, Bloomberg

Dallas Home Being Built of Shipping Containers

October 22, 2013 — CDJ STAFF
Some people wonder what it is. Others think it’s an eyesore. A Dallas architect is constructing a home using shipping containers for the upper story. Matt Mooney is using fourteen in all, with seven running across the front of the building. Mr. Mooney intends to have glass doors at the front back. Most of the home’s living area will be constructed in the shipping containers. The bottom floor will be for storage and garage. Mr. Mooney says that “30 or 40 times a day” people are stopping to look at the house. He also said that the delivery of the shipping containers brought some attention. “People call these things shipping containers, but technically they are prefabricated steel modules.” Read the court decision
Read the full story...
Reprinted courtesy of

High School Gym Closed by Construction Defects

October 28, 2011 — CDJ STAFF

The high school gym in Lake Oswego, Oregon has been shut down because testing has revealed that the construction defects have lead to deterioration of the structural integrity of the roof. The school district noted that there was a chance of collapse if there were a “significant seismic event or heavy rain and winds and snow.” The school district has been in a lawsuit with the builders since 2008, which was recently settled for $600,000.

The school board is still determining whether the original contractor will be asked to correct the defect or if they will bid the job out.

Read the full story...

Read the court decision
Read the full story...
Reprinted courtesy of

Georgia Passes Solar CUVA Bill

April 20, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
Georgia House Bill 238 authorizes the withdrawal of property from a conservation use covenant for purposes of developing a solar generation plant. Before the law was passed, subject to certain limited exceptions, properties under a conservation use covenant generally could not be developed without breaching the covenant. The new law permits the removal of a portion of the property to be used for solar development without breaching the covenant for the rest of the property. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

City Potentially Liable for Cost Overrun on Not-to-Exceed Public Works Contract

June 29, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
On a public works construction project, a contractor incurred additional costs and asserted a claim against the city. The city denied the claim because the contract had a not-to-exceed price, and the city council and mayor did not approve contract modifications to exceed that amount. City ordinances require approval for contract modifications and change orders exceeding ten percent of the original not-to-exceed amount. But the contractor argued that the ordinance did not apply because the excess costs did not result from a contract modification or change order. In addition, the contractor argued that, in refusing to approve an increase in the not-to-exceed amount, the city breached the implied duty of good faith and fair dealing. The court concluded that these questions were factual issues for the jury to decide. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Counterpoint: Washington Supreme Court to Rule on Resulting Losses in Insurance Disputes

September 01, 2011 — Douglas Reiser, Builders Council Blog

This is the fourth installment of posts on Vision One v. Philadelphia Indemnity, a Washington Supreme Court case touching on Washington construction and insurance law. After Williams v. Athletic Field got so much coverage, I wished that I had provided a forum for argument on Builders Counsel. While we await that opinion from the Supreme Court, I decided to let a few good writers have at Vision One here on the blog. Last week, attorney Chris Carr weighed in. Today, insurance expert David Thayer returns to give his final impression. David provided an initial peak at the case earlier this year. Thanks to both Chris and David for contributing to the debate.

In August 2011 the Washington Supreme Court will rule on a pair of joined cases that involve critical insurance coverage issues. The outcome of the ruling will impact a large swath of policyholders in Washington State including builders, developers, and homeowners to name a few.

The cases are Vision One vs. Philadelphia Indemnity Insurance and Sprague vs. Safeco. The Vision one case comes from Division Two of the Appellate Court which overturned a lower court decision in favor the plaintiff, Vision One. Division Two decided that the collapse of a concrete pour during the course of construction did not constitute a resulting loss due to faulty workmanship. They further went on to redefine efficient proximate cause in a way that is harmful to policyholders by broadening rather than narrowing the meaning of exclusionary language in Philadelphia’s Builders Risk Policy.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com