Seattle Washington Building Expert Directory

Sometimes you Need to Consider the Coblentz Agreement

January 19, 2017 — David Adelstein – Florida Construction Legal Updates
Since insurance, particularly liability insurance, is such an important component when it comes a construction project, understanding certain nuances such as a Coblentz Agreement (a what kind of agreement agreement?!?—keep reading) becomes helpful. If there is a construction defect claim / lawsuit, the implicated parties (e.g., contractor, design professional, subcontractor, sub-consultants) are going to tender the claim / lawsuit to their respective liability insurer. This is what they should be doing – notifying the insurer so that the insurer can defend them from the claim / lawsuit and indemnify them from covered damages associated with the claim / lawsuit. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Construction Law Client Advisory: What The Recent Beacon Decision Means For Developers And General Contractors

August 20, 2014 — Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel LLP
On July 3, 2014, the California Supreme Court (the “Court”) came out with its decision in Beacon Residential Community Association v. Skidmore, Owings & Merrill, et al. The Beacon decision settled a long-standing dispute in California about whether design professionals such as architects and engineers owe a duty to non-client third parties. In finding that the plaintiffs in Beacon could state a claim against the architects of the Beacon project, the Court also sowed the seeds of change in the way contracts are structured between developers, architects, engineers, and even general contractors. So, how will Beacon change the landscape for developers and general contractors? It is important to understand the factual background in Beacon to predict how the decision may alter the playing field. For a detailed analysis of the Amicus briefs in the Beacon matter from the AIA, the CBIA, and the Consumer Attorneys of California, please click here. The Beacon case arose from a common development model in California: a developer conceives a multi-unit project, maps the project as a condo development but rents as apartments. Shortly after completion of the Beacon project, the developer sold the entire project and the new owner finalized the existing condominium map and placed the units on the market as condominiums. Although the architects always knew they had designed a residential structure, the project ultimately became a condominium development. The newly formed homeowners’ association filed a construction defect suit against the developers, general contractor, the subcontractors and the architects for design and construction defects. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Loss Caused by Subcontractor's Faulty Work Covered in Georgia

January 17, 2013 — Tred Eyerly, Insurance Law Hawaii

The Georgia Court of Appeals found a subcontractor was covered under a CGL policy for loss caused by alleged faulty workmanship. Maxum Indem. Co. v. Jimenez, 2012 Ga. App. LEXIS 970 (Ga. Ct. App. Nov. 20, 2012).

Jimenez was hired as a subcontractor to install pipes for a dormitory construction project at Georgia Southern University. Subsequent to the construction, a pipe burst occurred at the dormitory, causing damage to several units. After a jury trial, Jimenez was found liable for $191,382 in damages that arose from his negligent pipe work.

Jimenez was insured under a CGL policy issued by Maxum. Maxum filed a suit for a declaratory judgment, seeking a declaration that the claim against Jimenez was not covered.

Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Is Your Home Improvement Contract Putting You At Risk?

February 10, 2020 — Hannah Kreuser - Porter Law Group
If you are like many contractors, odds are that your home improvement contract (HIC) is not compliant with California law, putting you at risk for disciplinary action, voiding of the contract, and even criminal prosecution. Generally, the laws allow parties to contract how they wish. However, California HICs are an exception and California Business and Professions Code (BPC) requires much in the way of content, form and formatting for a HIC to meet the legal requirements. This is because California has written its laws to provide broad protections to homeowners when it comes to construction work performed at their residence. However, in attempting to promote this goal, the laws surrounding HICs have produced requirements that are confusing and fail to account for the realities of a home improvement project, making it difficult and uncomfortable for contractors to comply. A HIC is required for home improvement projects that change a residence or property. Specifically, the law defines a “home improvement” as “the repairing, remodeling, altering, converting, or modernizing of, or adding to, residential property and shall include, but not be limited to, the construction, erection, replacement or improvement of driveways, swimming pools, including spas and hot tubs, terraces, patios, awnings, storm windows, landscaping, fences, porches, garages, fallout shelters, basements, and other improvements of the structures or land which is adjacent to a dwelling house.” (BPC section 7151.) A HIC is not required for new residential construction; for work priced at $500 or less; the sale, installation, and service of a fire alarm or burglar system; or a service and repair contract (which has its own requirements). When a HIC is used, BPC section 7159 specifies certain content, form, and format requirements, all of which must be followed to produce a compliant HIC. While this article will not discuss all of these requirements, it will discuss some of the problems commonly seen in HICs. Read the court decision
Read the full story...
Reprinted courtesy of Hannah Kreuser, Porter Law Group
Ms. Kreuser may be contacted at hkreuser@porterlaw.com

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

Newmeyer & Dillion Partner Aaron Lovaas & Casey Quinn Recognized by Super Lawyers

July 21, 2018 — Newmeyer & Dillion
LAS VEGAS, Nev. – JUNE 11, 2018 – Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that partner Aaron Lovaas has been selected to the 2018 Mountain States Super Lawyers list, and associate Casey Quinn has been selected to the 2018 Mountain States Rising Stars list by Super Lawyers. Each year, no more than 5 percent of lawyers are named to a Super Lawyers list and less than 2.5 percent are named to the Rising Stars list. This is the 9th consecutive year Lovaas has been honored, while Quinn has been consistently selected as a Rising Star honoree in prior years. Aaron Lovaas is a partner in the Las Vegas office. As a transactional attorney and business litigator, Lovaas has the ability to evaluate legal issues from both points of view and help his clients understand their best option. He also brings to the table experience as a business owner, having owned and managed his own boutique law firm for 12 years. Casey Quinn, an associate in the Las Vegas office, focuses his practice in complex commercial and construction litigation. He represents a variety of business entities in commercial disputes, including contract claims, business torts, privacy lawsuits, defamation, and fraud. Quinn is a past chair of the Construction Law section of the State Bar of Nevada and has successfully argued before the Supreme Court of Nevada, as well as settled disputes through various forms of conflict resolution including mediation and arbitration. Super Lawyers is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high-degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations and peer evaluations. About Newmeyer & Dillion For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client's needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.ndlf.com. Read the court decision
Read the full story...
Reprinted courtesy of

Congress to be Discussing Housing

June 11, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Housing Wire, several housing discussions will be taking place in Washington D. C. soon. Investors Unite on Solutions for U.S. Housing Policy hosts the first forum, which will be followed by a presentation by Joshua Rosner, author of Reckless Endangerment. Rosner will speak on “how to move forward on housing reform and what are the consequences of getting housing reform wrong.” Furthermore, “he will critique the recent efforts in Congress to reform Fannie Mae and Freddie Mac.” Read the court decision
Read the full story...
Reprinted courtesy of

Karen Campbell, Kristen Perkins to Speak at CLM 2020 Annual Conference in Dallas

March 02, 2020 — Karen Campbell & Kristen Perkins - Lewis Brisbois
New York Partner Karen L. Campbell and Fort Lauderdale Partner Kristen D. Perkins will both speak at the upcoming CLM 2020 Annual Conference taking place March 18 to 20 at the Gaylord Texan Resort outside Dallas, Texas. On March 19 at 2:00 p.m., Ms. Perkins will join a panel discussion titled “Predictive Analytics – You Don’t Need a Crystal Ball to Predict the Future,” exploring how predictive analytics affects litigation management programs, including case budgets, case cycle times, and claims outcomes. The panelists will also look at how machine learning picks up on nuances or anomalies that can affect analytics and give attendees a clearer picture on expected case parameters, and how that information can empower claims professionals during firm selection. Then, on March 20 at 10:40 a.m., Ms. Campbell will join a roundtable discussion titled “How to Calculate Damages and Defend in Serious Injury Cases,” covering the calculation of both economic and non-economic damages, as well as trends and recent verdicts involving punitive damages and assessing the various types of third-party liability. Reprinted courtesy of Karen Campbell, Lewis Brisbois and Kristen Perkins, Lewis Brisbois Ms. Campbell may be contacted at Karen.Campbell@lewisbrisbois.com Ms. Perkins may be contacted at Kristen.Perkins@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES