Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors
November 18, 2024 —
Matthew DeVries - Best Practices Construction LawWhen Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event.
In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays:
1. Include a Robust Force Majeure Clause in Your Contract
When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events.
Read the court decisionRead the full story...Reprinted courtesy of
Matthew DeVries, BuchalterMr. DeVries may be contacted at
mdevries@buchalter.com
$17B Agreement Streamlines Disney World Development Plans
July 22, 2024 —
Derek Lacey - Engineering News-RecordWalt Disney Parks and Resorts received the green light on $17 billion in development plans in and around Walt Disney World in Orange County, Fla,, garnering approval June 12 from the board of the Central Florida Tourism Oversight District (CFTOD) for its sprawling capital plan.
Reprinted courtesy of
Derek Lacey, Engineering News-Record
Mr. Lacey may be contacted at laceyd@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
White and Williams Lawyers Recognized by Best Lawyers
August 26, 2015 —
White and Williams LLPTwelve White and Williams lawyers have been listed in The Best Lawyers in America 2016. Inclusion in Best Lawyers is based entirely on peer-review. The methodology is designed to capture the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of the quality of legal services.
2016 Best Lawyers
Attorney / Practice Area
Frank Bruno / Patent Law
James Coffey / Mergers and Acquisitions Law
Timothy Davis / Real Estate Law
Joseph Foster / Personal Injury Litigation - Defendants
William Hussey / Tax Law; Trusts and Estates
Michael Kraemer / Employment Law - Management; Labor Law; Management; Litigation - Labor and Employment
Randy Maniloff / Insurance Law
John Orlando / Personal Injury Litigation - Defendants
Thomas Rogers / Real Estate Law
Joan Rosoff / Real Estate Law
Craig Stewart / Insurance Law; Product Liability - Defendants
William Taylor / Construction Law
Read the court decisionRead the full story...Reprinted courtesy of
You may contact White and Williams LLP attorneys at www.whiteandwilliams.com
Study Finds Construction Cranes Vulnerable to Hacking
May 20, 2019 —
Jeff Rubenstone - Engineering News-RecordWhen securing a jobsite against malicious hackers, most go to protect computer files, and few look up and worry about the tower cranes. But many cranes—whether tower, mobile or industrial—can be remotely run via radio wireless controllers, a useful feature for when operators need a clearer view of the load from the ground. Unfortunately, these wireless signals are vulnerable to hijacking, according to a study released earlier this year by security research firm Trend Micro. It found that the radio signals these crane controllers use are not encrypted over the air in any way, and can be easily intercepted and spoofed using off-the-shelf equipment and a basic knowledge of electronics and radio engineering.
Read the court decisionRead the full story...Reprinted courtesy of
Jeff Rubenstone, ENRMr. Rubenstone may be contacted at
rubenstonej@enr.com
The Looming Housing Crisis and Limited Government Relief—An Examination of the CDC Eviction Moratorium Two Months In
December 14, 2020 —
Zachary Kessler - Gravel2GavelMonths after the Centers for Disease Control and Prevention (CDC) issued a nationwide eviction moratorium using its emergency pandemic powers under the Public Health Service Act, the efficacy of this unprecedented measure remains unclear. While the Order ostensibly protects tenants facing homelessness or housing insecurity due to the financial impacts of the COVID-19 pandemic through the end of 2020, legal challenges have been initiated in Ohio and Georgia, with additional lawsuits appearing likely. Further, even barring legal challenges, courts have not handled these cases in a uniform manner. With lawmakers unable to reach any stimulus or COVID-19 relief agreement before the election, the CDC Order appears likely to remain the only federal eviction moratorium through its expiration on December 31, 2020.
Since the Order’s enactment, the CDC has since released new guidance, answering some of the open questions not covered by the initial Order. This guidance, while non-binding, is largely more favorable to landlords and property management companies than the initial text of the Order, as it provides that landlords are not required to make tenants aware of the Order’s protections and may challenge the truthfulness of the tenants’ declarations in any state or municipal court. The guidance also clarified the potential criminal penalties for violating the Order and the criminal penalties for perjury for bad faith submissions of the requisite declaration by tenants.
Read the court decisionRead the full story...Reprinted courtesy of
Zachary Kessler, PillsburyMr. Kessler may be contacted at
zachary.kessler@pillsburylaw.com
Construction Halted in Wisconsin Due to Alleged Bid Issues
March 26, 2014 —
Beverley BevenFlorez-CDJ STAFFA $9 million construction project in Middleton, Wisconsin has been halted due to an allegation that the construction company, Newcomb, did not comply with the advertised bid requirements and they were not the lowest bidder, according to the Wisconsin State Journal.
“Dane County Judge Rhonda Lanford issued a temporary restraining order at the request of Associated General Contractors of Wisconsin asking the city to stop work on the…facility,” the Wisconsin State Journal reported.
“We are pleased with the court’s decision. Fairness and transparency in public contracting is critical for the industry,” Robert Barker, Associated’s executive vice president, told the Wisconsin State Journal. “The city must abide by the rules so that all bidders are given a fair shake.”
However, the city stated that Newcomb was the construction company with the lowest bid in that category.
Read the court decisionRead the full story...Reprinted courtesy of
New York Appellate Team Obtains Affirmance of Dismissal of Would-Be Labor Law Action Against Municipal Entities
August 12, 2024 —
Lewis Brisbois NewsroomNew York, N.Y. (July 11, 2024) - In Charlot v. City of New York, ___ A.D.3d ___, 2024 NY Slip Op 03161 (2d Dep’t 2024), New York Associate Dean Pillarella, a member of the Appellate Practice, recently obtained an affirmance of the lower court’s dismissal of the plaintiff’s action against the City of New York (“the City”) for failure to timely serve a notice of claim. New York Partner Meghan Cavalieri, a member of the Construction Practice, and her team authored and argued the initial motion to dismiss.
The plaintiff alleged to have sustained injuries as a result of a construction-site accident on December 8, 2020, on City-owned property in the course of the construction of a school by the New York City School Construction Authority. N.Y. General Municipal Law (“GML”) § 50-e(1)(a), requires service of a notice of claim within 90 days after the claim arises as a condition precedent to the commencement of a tort action. The plaintiff served no notice of claim until June 2021 and commenced an action in January 2022, alleging violations of N.Y. Labor Law §§ 240(1), 241(6), and 200. Given the plaintiff’s failure to comply with GML § 50-e(1)(a), Meghan and her team rejected the notices of claim as untimely. The plaintiff then moved for leave to deem the notices of claim timely served nunc pro tunc. In response, Meghan and her team opposed the motion and cross-moved to dismiss the action.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Evaluating Construction Trends From 2023 and Forecasting For 2024
February 12, 2024 —
Jason Feld & Dominic Donato - Kahana FeldAs we begin 2024, it is informative to evaluate what transpired in 2023 in the construction industry, and especially the use of construction technology. 2023 ushered in a variety of newly implemented construction technologies including 3D printed entire houses, improved wearables that detect all aspects of the construction worker from location to temperature to heart rate, increased use of modular construction for entire apartments, hotels, and condominium projects, and eco-friendly and conservation minded technologies to minimize carbon footprint, water preservation and sustainable construction methods, to name a few.
2023 also identified some significant issues in the construction industry. First and foremost, the labor shortages and hiring of skilled and qualified workers continued to be an issue resulting in increased delays, construction accidents, and project mismanagement. The skyrocketing interest rates, decline in commercial/office projects, supply chain issues, material price fluctuation and increase changes in scope of projects all negatively impacted the construction industry in 2023. There is also the demand for renewable and infrastructure projects put strain on construction resources as the projects became “mega” with larger and more complex construction leading to multi-party, high dollar, and more complex claims. Finally, there is a growing trend of construction claims and litigation being financed by third party litigation funding sources for personal/bodily injury claims and construction defect claims.
Reprinted courtesy of
Jason Feld, Kahana Feld and
Dominic Donato, Kahana Feld
Mr. Feld may be contacted at jfeld@kahanafeld.com
Mr. Donato may be contacted at ddonato@kahanafeld.com
Read the court decisionRead the full story...Reprinted courtesy of