Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Unbilled Costs Remain in Tutor Perini's Finances
October 23, 2018 —
Scott Van Voorhis – Engineering News-RecordTutor Perini is struggling to shake off long-running concerns over the hundreds of millions in unbilled costs that have been on the contractor’s balance sheet for years. The Sylmar, Calif.-based construction giant reported more than $1 billion in unbilled costs or receivables at the end of the second quarter, up by more than $100 million from the start of the year, according to the company’s federal filings. That was $100 million higher than at the end of 2016, when the amount was $832 million.
Read the court decisionRead the full story...Reprinted courtesy of
Scott Van Voorhis, ENRENR may be contacted at
ENR.com@bnpmedia.com
24th Annual West Coast Casualty Construction Defect Seminar A Success
June 05, 2017 —
Margaret Graham - CDJ STAFFThe 24th Annual West Coast Casualty Construction Defect seminar was once again, a huge success . On May 18-19, 2017 attendees from the legal, insurance, builder, contractor, subcontractor and numerous other industries came from across the United States and several foreign countries to the 24th Annual West Coast Casualty Construction Defect Seminar.
Caryn Siebert, Vice President and Chief Claims Officer of The Knight Insurance Group was awarded The Jerrold S. Oliver Award of Excellence. This award recognizes a person who has contributed to the betterment of the construction defect community. For more information on the Oliver Award of Excellence, please visit: http://www.westcoastcasualty.com/seminar/ollie-award-voting/
Bert L. Howe & Associates, Inc.’s golf challenge raised $2,225.00 for the National Coalition for Homeless Veterans and $1,900 for Final Salute.
The grand total for all charitable contributions raised this year at the seminar was $45,300.00.
For more information on the National Coalition for Homeless Vets, please visit: http://nchv.org/
To learn more about how Final Salute provides homeless women Veterans with safe and suitable housing, please visit: http://www.finalsaluteinc.org/
Read the court decisionRead the full story...Reprinted courtesy of
Contractors Set to Implement Air Quality Upgrades for Healthier Buildings
April 12, 2021 —
Nate Echtenkamp - Construction ExecutiveAs people spend more time in offices, stores and other buildings, and colder weather forces many outdoor activities to be held indoors during the COVID-19 pandemic, construction contractors are increasingly being asked by building owners and operators to provide various mitigation strategies to improve indoor air quality to help occupants avoid being exposed to lingering airborne viral particles.
Lowering the concentration of SARS-CoV-2 and other pathogens in enclosed public spaces is of the utmost importance nowadays given that Americans, on average, spend nearly 90% of their time indoors, according to the EPA.
It’s fairly common knowledge that the best way to avoid infection is to follow guidelines issued by the Centers for Disease Control and Prevention that include:
- wearing masks or other face coverings;
- frequent hand-washing;
- physical distancing of at least six feet; and
- deep-cleaning procedures.
Reprinted courtesy of
Nate Echtenkamp, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Subcontractor Not Liable for Defending Contractor in Construction Defect Case
February 10, 2012 —
CDJ STAFFThe California Court of Appeals has ruled on January 9, 2012 in Hensel Phelps Construction Company v. Urata & Sons Cement, upholding the judgment of the lower court.
Hensel Phelps was the general contractor for a high-rise in Sacramento. They were sued by the owners of the building after problems were discovered in the concrete slabs of the building’s parking garage. Instead of welded steel wire mesh, the slabs had been constructed with fiber mesh. Hensel Phelps filed a cross-complaint against Urata Cement, the subcontractor that had performed the cement work. Urata refused to defend Hensel Phelps. The owners’ case was subsequently dismissed due to the statute of limitations.
Although the original case was over, Hensel Phelps continued in their claims against Urata. “Urata argued that a handwritten interlineation required Hensel Phelps to prove Urata was at fault for the injury alleged in the building owners’ complaint before Urata was obliged to defend Hensel Phelps in that action.”
The lower court concluded that Urata would have been obligated to defend Hensel Phelps if the owners’ lawsuit had alleged that the damage was due to the subcontractor’s work or if evidence at trial established this. The lower court found neither of these true. Instead, the use of the fiber mesh was a design issue and “that decision was outside the scope of the subcontractor’s work.”
During the trial, Hensel Phelps conceded that Urata was not at fault. The appeals court could find no reading of the contract that would cause Urata to be obligated to defend Hensel Phelps, calling Hensel Phelps’s reading of the contact as “grammatically infeasible.”
Judges Nicholson, Raye, and Butz upheld the decision of the lower court and awarded costs on appeal to Urata.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Government Claims Act Does Not Apply to Actions Solely Seeking Declaratory Relief and Not Monetary Relief
March 25, 2024 —
Garret Murai - California Construction Law BlogPerhaps it should come as no surprise, but public entities get special treatment under the law, and when filing a claim against a public entity, in most cases, a claimant is required to file a claim with the public entity before filing suit under the Government Claims Act (Gov. Code §810 et seq.).
But, as the next case demonstrates, that’s not always the case. In Stronghold Engineering Incorporated v. City of Monterey, 96 Cal.App.5th 1203 (2023), the 6th District Court of Appeals examined whether a public works contractor that alleged an extended overhead claim was required to file a Government Claims Act claim before filing suit when its initial complaint was limited to a claim for declaratory relief.
The Stronghold Case
In December 2015, general contractor Stronghold Engineering Incorporated entered into a construction contract with the City of Monterey for the renovation of the City’s conference center and an adjacent city-owned plaza. The construction contract provided that any modification to the construction contract had to be approved by the City through a written change order. No surprise there.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Wall Failure Due to Construction Defect Says Insurer
October 09, 2013 —
CDJ STAFFA wall built by J. F. Smith Construction collapsed during Hurricane Isaac, and Bankers Insurance Group is blaming the builder not the hurricane. The insurer claims that if the wall had been built properly it would have withstood the storm. The suit is being filed in the Louisiana courts. Bankers Insurance is seeking $49,625.25 in damages.
Read the court decisionRead the full story...Reprinted courtesy of
Subcontractor Sued for Alleged Defective Work
June 11, 2014 —
Beverley BevenFlorez-CDJ STAFFThe Louisiana Record reported that “[a] construction company is suing a subcontractor for alleged defective work on two construction projects” in New Orleans, Louisiana.
New Beginnings Enterprises and J. Fernando Arriola are “accused of providing defective labor and materials, failing to properly supervise construction on the properties, failing to obtain inspections required under building codes, failing to construct dwellings in accordance with plans and specifications and failing to perform agreements in a workmanlike manner,” according to the Louisiana Record.
Plaintiffs including Bartel Construction LLC seek $209,500 in damages “as additional sums for defective and incomplete work, lost profits, consequential damages and attorney’s fees.”
Read the court decisionRead the full story...Reprinted courtesy of