Fairfield Connecticut Building Expert Directory

Good-To-Know Points Regarding (I) Miller Act Payment Bonds And (Ii) Payment Bond Surety Compelling Arbitration

December 22, 2019 — David Adelstein - Florida Construction Legal Updates
Every now and then I come across an opinion that addresses good-to-know legal issues as a corollary of strategic litigation decisions that are questionable and/or creative. An opinion out of the United States District Court of New Mexico, Rock Roofing, LLC v. Travelers Casualty and Surety Company of America, 2019 WL 4418918 (D. New Mexico 2019), is such an opinion. In Rock Roofing, an owner hired a contractor to construct apartments. The contractor furnished a payment bond. The contractor, in the performance of its work, hired a roofing subcontractor. A dispute arose under the subcontract and the roofer recorded a construction lien against the project. The contractor, per New Mexico law, obtained a bond to release the roofer’s construction lien from the project (real property). The roofer then filed a lawsuit in federal court against the payment bond surety claiming it is entitled to: (1) collect on the contractor’s Miller Act payment bond (?!?) and (2) foreclose its construction lien against the lien release bond furnished per New Mexico law. Count I – Miller Act Payment Bond Claiming the payment bond issued by the contractor is a Miller Act payment bond is a head scratcher. This claim was dismissed with prejudice upon the surety’s motion to dismiss. This was an easy call. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Protect Projects From Higher Repair Costs and Property Damage

March 04, 2024 — Michael Teng - Construction Executive
Every aspect of a jobsite costs more today, from materials and labor to tools and equipment. Take construction input costs for example. While relatively flat in 2023, they remain almost 40% higher than they were pre-pandemic. With borrowing costs still high in the face of a stubbornly strong economy, project financing will remain a challenge. Still, contractors are expected to break more ground in 2024, fueled in part by the CHIPS Act, the Inflation Reduction Act and the Infrastructure Investment and Jobs Act. Despite wages growing and the labor market remaining tight, many businesses are expected to dive deeper into their backlogs. Meanwhile, the economy is expected to grow with a chance for a short and mild recession. As industry leaders gauge economic pressures, it’s clear businesses must manage their costs—and financial risks in 2024. It’s a year where insurance and safety should take priority. Below are economic trends to monitor, and insurance strategies to help protect this year’s bottom line. Reprinted courtesy of Michael Teng, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Review your Additional Insured Endorsement

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
In his blog, Construction Contractor Advisor, Craig Martin explained the importance of reviewing your additional insured endorsement. Martin pointed out that in Mississippi, the “Fifth Circuit Court of Appeals recently ruled in Woodward, LLC v. Acceptance Indemnity Insurance Company, that a general contractor, named as an additional insured, did not have coverage for claims that a subcontractor performed faulty work.” The problem “was the language in the additional insured endorsement, which provided coverage for ongoing operations, not completed operations.” While Martin admitted that the case applies to Mississippi, he concluded that “the issue Midwestern readers should consider is the court’s conclusion that non-conformance with the plans, in essence a construction defect claim, arises from completed operations.” Read the court decision
Read the full story...
Reprinted courtesy of

Eminent Domain Bomb Threats Made on $775M Alabama Highway Project

July 03, 2022 — Derek Lacey - Engineering News-Record
Multiple bomb threats have been made against Alabama transportation officials, law enforcement and others in reaction to eminent domain plans for a major highway expansion project. Reprinted courtesy of Derek Lacey, Engineering News-Record Mr. Lacey may be contacted at laceyd@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

First Suit Filed for Losses Caused by COVID-19

March 30, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Last week, the first lawsuit was filed seeking insurance coverage for business-interruption due to losses caused by COVID-19. The case, Cajun Conti, LLC, et al. v. Certain Underwriters at Lloyd's of London, ,et al., was filed in Louisiana. A New Orleans restaurant, Oceana Grill," seeks a declaratory judgment that its "all risks" policy issued by Lloyd's covers losses resulting from the closure of its restaurant due to the Governor's order restricting public gatherings and the Mayor of New Orleans' order closing restaurants. The lawsuit contends that "contamination of the insured premises by the coronavirus would be a direct physical loss needing remediation to clean the surfaces of the establishment." The lawsuit further alleges the policy contains no exclusions for a "viral pandemic." The suit seeks a declaration that "the policy provides coverage to plaintiffs for any future civil authority shutdowns of restaurants in the New Orleans area due to physical loss from coronavirus contamination and that the policy provides business income coverage in the event that the coronavirus has contaminated the insured premises." The obvious dispute will be whether the coronavirus constitutes a "direct physical loss or damage" as required by the policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Montana Theater Threatened by Closure due to Building Safety

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
Phil Henderson, owner of Stevensville Hardware which is adjacent to the theater, has sued the Stevensville Playhouse, alleging that one of the theater building’s walls leans over into his property, according to the Bitterroot Star. Henderson stated that the leaning wall is interfering with construction plan, and he also alleges that the building is not safe and should be condemned. A building inspector hired by Henderson declared that “…it seems necessary to notify the Stevensville Playhouse that their structure is to be immediately considered unsafe for entry, occupancy, etc.” However, another engineering firm presented a different view on the situation: “The playhouse has withstood many snow storms and earthquakes during its life and will likely continue to function well into the future. We do not mean to downplay the need to perform the recommended repairs, but we do not feel that the building needs to be condemned at this point.” Read the court decision
Read the full story...
Reprinted courtesy of

Veolia Agrees to $25M Settlement in Flint Water Crisis Case

February 19, 2024 — James Leggate - Engineering News-Record
Engineering firm Veolia North America agreed to a $25-million settlement to resolve a federal class action case related to its work for the city of Flint, Mich., during the city’s lead-in-water crisis, the company and attorneys for the plaintiffs announced Feb. 1. Veolia is the second engineering firm that worked for the city to settle with city residents, and the deal came ahead of a class-action trial scheduled to start later this month. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES