Fairfield Connecticut Building Expert Directory

Under Privette Doctrine, A Landowner Delegates All Responsibility For Workplace Safety to its Independent Contractor, and therefore Owes No Duty to Remedy or Adopt Measures to Protect Against Known Hazards

September 29, 2021 — Krsto Mijanovic, Jeffrey C. Schmid & John M. Wilkerson - Haight Brown & Bonesteel
In Gonzalez v. Mathis (2021 WL 3671594) (“Gonzalez”), the Supreme Court of California held that a landowner generally owes no duty to an independent contractor or its workers to remedy or adopt other measures to protect them against known hazards on the premises. The Court applied the Privette doctrine which establishes a presumption that a landowner generally delegates all responsibility for workplace safety to its independent contractor. (See generally Privette v. Superior Court (1993) 5 Cal.4th 689; SeaBright Ins. Co. v. US Airways, Inc. (2011) 52 Cal.4th 590.) As such, the independent contractor is responsible for ensuring that the work can be performed safely despite a known hazard on the worksite, even where the contractor and its workers are unable to take any reasonable safety precautions to avoid or protect themselves from the known hazard. In Gonzalez, the landowner, Mathis, had hired an independent contractor, Gonzalez, to clean a skylight on his roof. To access the skylight, Gonzalez needed to utilize a narrow path between the edge of the roof and a parapet wall. While walking along this path, Gonzalez slipped and fell to the ground, sustaining serious injuries. Gonzalez alleged this accident was caused by several dangerous conditions on the roof, including a slippery surface, a lack of tie-off points to attach a safety harness, and a lack of a guardrail. Gonzalez was aware of all of these hazards prior to the accident. Reprinted courtesy of Krsto Mijanovic, Haight Brown & Bonesteel, Jeffrey C. Schmid, Haight Brown & Bonesteel and John M. Wilkerson, Haight Brown & Bonesteel Mr. Mijanovic may be contacted at kmijanovic@hbblaw.com Mr. Schmid may be contacted at jschmid@hbblaw.com Mr. Wilkerson may be contacted at jwilkerson@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (6/26/24) – Construction Growth in Office and Data Center Sectors, Slight Ease in Consumer Price Index and Increased Premiums for Commercial Buildings

July 22, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, U.S. interest rates remain uncertain, construction firms continue to use artificial intelligence, New York City updates commercial zoning regulations, and more!

According to analysts, high vacancy rates and declining rents have hurt San Francisco’s office market so badly that it could take almost 20 years to recover. (Eric McConnell, Yahoo)
The New York City Council approved updated commercial zoning regulations that expand where businesses can be located in the city, more than double the space for small-scale clean manufacturing, and enable adaptive reuse projects involving existing buildings. (Joe Burns, Construction Dive)
The insurance industry is responding to the proliferation of extreme weather events and the risks associated with operating commercial buildings in vulnerable areas by increasing premiums. (Renea Burns, Tim Coy, Niall Williams, Deloitte)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Rights Afforded to Employees and Employers During Strikes

October 16, 2018 — Wally Zimolong - Supplemental Conditions
One of the most powerful weapons in labor’s arsenal is a strike. Like most powerful weapons there is a dichotomy in a strike. On one hand, it can bring about concessions from management that labor seeks. On the other hand, it can permanently change the relationship between management and labor. However, one thing is certain, strike are – to put it mildly – chaotic. During this chaotic period, employees and employers may wonder what rights they have during union-initiated strikes. We provide some brief explanations below, along with how union litigation can help enforce your rights. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Structural Failure of Precast-Concrete Span Sets Back Sydney Metro Job

February 23, 2017 — Chris Webb - Engineering News-Record
A key component of Australia’s biggest public transport infrastructure project—Sydney’s $6.3-billion Metro North West—is the subject of a critical and detailed technical report describing how an elevated viaduct span failed at a stitch joint between two precast segments during construction last September. Project officials say the affected span, which did not suffer a progressive collapse, has since been removed and its replacement fast-tracked to avoid further delays. Little additional detail was provided. Read the court decision
Read the full story...
Reprinted courtesy of Chris Webb, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Unrelated Claims Against Architects Amount to Two Different Claims

July 30, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Second Circuit found that two claims arising from the same project were unrelated, creating two separate payments by the insurer for the two separate claims. Dormitory Auth. of New York v. Continental Cas. Co., 2014 U.S. App. 12088 (2nd Cir. June 23, 2014). In 1995, the State agency contracted with the insured architectural firm to design and oversee the construction of a new dormitory at City University of New York. Plans drawn by the architects erred in their estimate of the steel requirement. To recover losses from the resulting delay and expense, the agency sent a demand letter in May 2002 to the architects detailing the Steel Girt Tolerance issue. After the project was finished in 2001, another problem was discovered: excess accumulations of snow and ice were sliding off the building onto sidewalks a considerable distance away. The Ice Control Issue was studied during the winter of 2003-04. The conclusion was that the design of the facade failed to account for temperature variations appropriate for a building in New York. The problem could not be resolved by adding canopies, which would have been a cheaper fix. Study of the problem continued into 2005. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Virginia Joins California and Nevada in Passing its Consumer Privacy Act

March 15, 2021 — Kyle Janecek – Newmeyer Dillion
California tends to be on the forefront in consumer privacy laws within the United States. However, there is a growing momentum for other states to join California in legislating consumer privacy rights, as well as pushes for federal legislation. The latest state to join in and pass consumer privacy legislation is Virginia, with its Virginia Consumer Data Protection Act (VCDPA). With Virginia joining the fray, several questions arise, such as how closely does the VCDPA follow California's legislation? How, if at all, does it differ from already-existing legislation? What do businesses need to comply with the VCDPA, if at all? WHAT IS THE VIRGINIA CONSUMER DATA PROTECTION ACT? The VCDPA largely mimics elements from its Californian cousins, the California Consumer Privacy Act (CCPA) as modified by the California Privacy Rights Act (CPRA). The main features of the law include: (a) issuing the right to request what information is collected; (b) the right to correct information provided; (c) the right to deletion; (d) providing notice to consumers regarding the collection of their data; and (e) protecting consumer data. Further, the consumer requests, akin to the CCPA, do require verification, and similarly phrased data security practices that rely on how "reasonable" they are, depending on the volume and type of information at issue. Though, the VCDPA does expand on this slightly, requiring "data protection assessments" to determine the security of protected information, how it is shared and used, the benefits in sharing the information and harm resulting from any breaches. Read the court decision
Read the full story...
Reprinted courtesy of Kyle Janecek, Newmeyer Dillion
Mr. Janecek may be contacted at kyle.janecek@ndlf.com

Coverage for Faulty Workmanship Denied

June 29, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The court found there was no coverage for the insureds' alleged negligent failure to construct a building. Evanston Ins. Co. v. DCM Contracting, 2020 U.S. Dist. LEXIS 63977 (N.D. Ga. Feb. 28, 2020). Turning Point Church sued DCM Contracting for faulty workmanship on a construction project. Turning Point sent a demand letter to DCM on August 18, 2017 and filed suit in December. Evanston did not receive notice of Turning Point's claims and the lawsuit until May 15, 2018. Evanston filed suit for a declaratory judgment and moved for summary judgment. The court first considered the late notice. The policy required notice "as soon as practicable" DCM was also required to provide copies of demands, notices, or legal papers to Evanston. Here, DCM did not give notice to Evanston until nine months after receipt of Turning Point's demand. A phone communication with DCM's agent between August 2017 and May 2018 was insufficient. DCM provided no documents, including the summons and complaint, to the agent. DCM waited five months to forward the underlying lawsuit. This was a breach of the policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES