Cambridge Massachusetts Building Expert Directory

Addressing the Defective Stucco Crisis

November 28, 2018 — Wally Zimolong - Supplemental Conditions
I received several emails regarding the expose by Caitlin McCabe and Erin Arvedlund in the Philadelphia Inquirer titled “Rotting Within.” The story outlines the epidemic of defective stucco and other “building envelope” issues in Southeastern Pennsylvania that is causing homes to literally rot from within. Having litigated several of these cases, they are frustrating for both the attorneys that handle them and the homeowners who must deal with the reality that their home is rotting away. The story points to the multiple (and all too common) causes for the epidemic: unskilled subcontractors, lack of oversight and care, and poor construction drawings. The is no quick solution to the crisis and litigation regarding these defects is sure to proliferate. However, there is one potential solution that the story does not cover and which could help alleviate some of the challenges homeowners face in recovering damages for their claims. The Pennsylvania Legislature must act to change the insurance laws in Pennsylvania to make defective construction covered by a developer’s, contractor’s, and subcontractor’s commercial general liability policy (“CGL”). Most homeowners and many attorneys incorrectly assume that defective construction is covered by insurance. This assumption makes sense. If someone operates a car in a negligent manner and hits your car and causes damage, the negligent driver’s insurance company with cover your loss. In reality, Pennsylvania courts follows a minority of states that holds that generally speaking defective workmanship is not a “covered occurrence” under an insurance policy. (There are several exceptions to this rule and thorough discussion is beyond this blog post and would probably bore you.) Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Carolinas Storm Damage Tally Impeded by Lingering Floods

October 09, 2018 — Jim Parsons & Tom Sawyer - Engineering News-Record
As October rolls in, slow-moving flood crests and sluggish drainage persisting weeks after the passage of Hurricane Florence are leaving large eastern areas in the affected states too inundated for accurate damage assessments. The extent of damage is still largely uncalculated. In some cases, it’s believed to be worsening. Reprinted courtesy of Jim Parsons, Engineering News-Record and Tom Sawyer, Engineering News-Record Mr. Parsons may be contacted at sawyert@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

When is a Residential Subcontractor not Subject to the VCPA? Read to Find Out

December 01, 2017 — Christopher G. Hill - Construction Law Musings
The Virginia Consumer Protection Act (VCPA) can and often does apply to residential construction. The transaction between a residential contractor and an homeowner has been held to fall under the consumer transaction language of the VCPA and on occasion been used to avoid the issues with the economic loss doctrine in Virginia. However, there are limits to how far down the contractual chain the VCPA applies, particularly in the case where a supplier or subcontractor does not provide the services or materials for a personal, consumer purpose. An example of this fact is found in the case of Johnston v. Stephan. In that case, a couple hired a general contractor to build a home and the general contractor hired Cole Roofing System, Inc. to provide the roof of the home. The first couple subsequently sold the home and the second homeowners sought further work on the roof from Cole Roofing. After Cole Roofing refused further work, the homeowners brought an action seeking to enforce a warranty and for a violation of the VCPA. For the warranty claim, the homeowners relied on the contract between them and the prior homeowners that referenced a 10 year warranty on the roof and the subcontract between the homebuilder and Cole Roofing. Cole Roofing sought dismissal of the VCPA and warranty claims by demurrer and further sought by demurrer to have the matter dismissed as being filed after the running of the statute of limitations. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Virginia General Assembly Tweaks Pay-if-Paid Ban

April 03, 2023 — Christopher G. Hill - Construction Law Musings
Last year, the Virginia General Assembly passed into law a ban on the so-called pay-if-paid clauses, effective January 1, 2023. I shared my thoughts and concerns with the legislation as drafted at the time of its passage. During this most recent legislative session, and among some other construction-related bills, the General Assembly sought to clarify its past enactment. The enrolled bill fills in certain gaps in the law as follows:

For both private and public contracts, the General Contractor, if it has good reason to withhold any payment, now has a maximum of 50 days from receipt of a proper invoice to notify its subcontractor of the reason for the withholding, including the contractual noncompliance, the amount to be withheld, and the lower-tier subcontractor responsible for the contractual noncompliance.
For private contracts, the Owner now has 45 days in which to provide any written notice of intention to withhold payment. This notice must include the specific contractual non-compliance and the dollar amount to be withheld. NB- Owners do not need to specify the subcontractor responsible for the non-compliance.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Mexico's Richest Man Carlos Slim to Rebuild Collapsed Subway Line

November 01, 2021 — The Associated Press - Bloomberg
Mexico City (AP) -- Mexico’s richest man reached an agreement with Mexico City authorities Wednesday to rebuild or reinforce an elevated subway line that collapsed in May, killing 26 people. Telecom and construction magnate Carlos Slim said his Grupo Carso’s construction subsidiary would pay the cost of rebuilding the span that collapsed, and reinforcing other parts of the elevated line to meet higher standards in a city plagued with severe earthquakes. Grupo Carso said in a statement to the country’s stock market that the outlay did not constitute any admission of responsibility for the collapse, and would not “materially affect” the company’s business. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Commercial Real Estate in 2023: A Snapshot

January 17, 2023 — Adam J. Weaver - Gravel2Gavel Construction & Real Estate Law Blog
As we close out the last remaining weeks of 2022, all eyes look ahead to 2023. Below is a quick snapshot highlighting three trends and predictions that may continue to shape the commercial real estate landscape in 2023.

Office space and the digital economy present attractive investment opportunities and potential. Even with all of the chatter about office vacancies during the last three years, according to Moody’s Analytics, “it’s important to note that none of the regions across the U.S. have seen office vacancy rates dip below their pre-pandemic Q4 2019 levels.” This might be due to creative and reimagined office spaces as the return to office continues. The hybrid work format and flexibility in spaces will continue in 2023.
Data analytics and Proptech will continue to play a larger role, allowing property owners and tenants to collaborate to provide more efficiency, whether to achieve sustainability goals or leverage technology like immersive experiences to entice tenants to new spaces. An increase in demand for technology to solve issues will most likely continue in commercial real estate.

Read the court decision
Read the full story...
Reprinted courtesy of Adam J. Weaver, Pillsbury
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com

Counterpoint: Washington Supreme Court to Rule on Resulting Losses in Insurance Disputes

September 01, 2011 — Douglas Reiser, Builders Council Blog

This is the fourth installment of posts on Vision One v. Philadelphia Indemnity, a Washington Supreme Court case touching on Washington construction and insurance law. After Williams v. Athletic Field got so much coverage, I wished that I had provided a forum for argument on Builders Counsel. While we await that opinion from the Supreme Court, I decided to let a few good writers have at Vision One here on the blog. Last week, attorney Chris Carr weighed in. Today, insurance expert David Thayer returns to give his final impression. David provided an initial peak at the case earlier this year. Thanks to both Chris and David for contributing to the debate.

In August 2011 the Washington Supreme Court will rule on a pair of joined cases that involve critical insurance coverage issues. The outcome of the ruling will impact a large swath of policyholders in Washington State including builders, developers, and homeowners to name a few.

The cases are Vision One vs. Philadelphia Indemnity Insurance and Sprague vs. Safeco. The Vision one case comes from Division Two of the Appellate Court which overturned a lower court decision in favor the plaintiff, Vision One. Division Two decided that the collapse of a concrete pour during the course of construction did not constitute a resulting loss due to faulty workmanship. They further went on to redefine efficient proximate cause in a way that is harmful to policyholders by broadening rather than narrowing the meaning of exclusionary language in Philadelphia’s Builders Risk Policy.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES