Fairfield Connecticut Building Expert Directory

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Failure to Comply with Sprinkler Endorsement Bars Coverage for Fire Damage

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
Despite its application stating otherwise, the insured's failure to install a sprinkler system in its building barred coverage for extensive damage caused by fire.American Way Cellular, Inc. v. Travelers Prop. Cas. Co. of Am., 2013 Cal. App. LEXIS 425 (Cal. Ct. App. May 30, 2013). American Way contacted a broker, A&J, regarding liability and property coverage. A&J sent American Way an application for a policy with Travelers. The application indicated American Way had a sprinkler system and fire detectors in its building. Travelers issued a policy with a Protective Safeguards Endorsement For Sprinkler Locations and Restaurants. The endorsement stated that as a condition of the insurance, the insured was required to maintain a sprinkler system. An exclusions section said the insurer would not pay for loss caused by fire if there was no sprinkler system. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Celebrating Excellence: Lisa Bondy Dunn named by Law Week Colorado as the 2024 Barrister’s Best Construction Defects Lawyer for Defendants

October 28, 2024 — David M. McLain – Colorado Construction Litigation
We are thrilled to announce that our very own Lisa Bondy Dunn has been recognized by Law Week Colorado as the 2024 Barrister’s Best Construction Defects Lawyer for Defendants. This prestigious accolade is a testament to Lisa’s dedication, expertise, and unwavering commitment to achieving the best outcomes for our clients. Lisa, a Partner at Higgins, Hopkins, McLain & Roswell (“HHMR”), has long been a leader in construction defect litigation, defending builders, contractors, developers, and design professionals in Colorado’s complex legal landscape. Her deep understanding of the industry and her relentless pursuit of practical, cost-effective solutions have earned her the respect of peers, clients, insurers, mediators, arbitrators, and courts alike. As noted by Law Week Colorado: “For over two decades, Lisa Dunn has represented developers, contractors and subcontractors in construction-related disputes. Dunn has spoken across the country on construction and insurance matters, and she’s worked on several appellate cases during her career. She’s admitted in four states, and has consulted and represented some of the nation’s largest builders.” Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

CDJ’s Year-End Review: The Top 10 CD Topics of 2014

December 31, 2014 — Beverley BevenFlorez-CDJ STAFF
Construction Defect Journal’s year-end review presents the top ten most popular topics featured in the journal in 2014. Some of the topics involved analysis of important construction defect cases, while others covered current events such as proposed state legislation. Most issues were heavily discussed on CDJ as well as in board rooms and during teleconferences. We hope you enjoy the look-back at 2014 interspersed throughout the issue, and we wish you and yours a prosperous 2015! CDJ’s #1 Topic of the Year: Indalex Inc. v. National Union Fire Ins. Co. of Pittsburgh, PA, 2013 Pa. Super 311 (Dec. 3, 2013) According to Darrin J. McMullen of Anderson Kill, “[t]he Indalex decision reverses a nearly decade-long trend of Pennsylvania decisions narrowing the scope of insurance coverage for construction and defect-related claims under commercial general liability insurance policies. Equally important, the Indalex ruling dealt a blow to the insurance industry’s continual efforts to win overbroad expansion of the rulings in Kvaerner Metals Div. of Kvaerner U.S., Inc. v. Commercial Union Ins. Co., Millers Capital Ins. Co. v. Gambone Bros. Dev. Co., and Erie Ins. Exchange v. Abbott Furnace Co., which found that claims of faulty workmanship in some circumstances may not constitute coverage-triggering ‘occurrences.’” Read the court decision
Read the full story...
Reprinted courtesy of

To Ease Housing Crunch, Theme Parks Are Becoming Homebuilders

January 29, 2024 — Patrick Sisson - Bloomberg
For visitors, Universal Studios Florida offers a chance to visit a fantastical land full of wizards, Minions and various characters from NBC Universal’s many film and television properties. But for the roughly 28,000 men and women who work at the 840-acre theme park and resort complex in Orlando, the troubles of the real world — like the rising cost of housing — are not far away. Central Florida has seen some of the nation’s fastest pandemic-era rent increases, thanks to a confluence of job growth, migration and housing underproduction that has put a strain on residents. The average tenant in the region saw their monthly rent jump by $600 between early 2020 and early 2023. According to the National Low Income Housing Coalition, the Orlando-Kissimmee-Sanford metro area has one of the worst affordable housing shortages in the US, with only 15 available units for every 100 extremely low-income renter households. The dire need for workforce housing is behind the entertainment conglomerate’s latest project in Central Florida: a 1,000-unit mixed-use development, set to open in 2026, that promises to give tenants who work in the service industry a short commute to the constellation of tourist attractions and hotels nearby. To launch the project, Universal donated 20 acres of land adjacent to the Orange County convention center. Called Catchlight Crossings and built in partnership with local developer Wendover Housing Partners, the project broke ground in November. Read the court decision
Read the full story...
Reprinted courtesy of Patrick Sisson, Bloomberg

Avoiding Construction Defect “Nightmares” in Florida

November 27, 2013 — CDJ STAFF
Describing it as a “nightmare,” Larry Tolchinsky writes about construction defects at the Willowbrook condominium complex in Florida. Writing on the website of his firm, Sackrin & Tolchinsky, Mr. Tolchinsky gives the history of the Willowbrook condo case, in which condo owners suffered problems with water intrusion and subsequent damage to their units. The builder has agreed to make repairs, though they are still suing owners who put up a website critical of the company. Mr. Tolchinsky notes that this is not “the usual way things happen in construction defect lawsuits,” and he gives the usual process. Under Florida law, homeowners must first notify those responsible of a “problem and its need for repair.” After this notice, the homeowner “will know within about 6 weeks’ time after sending that formal notice what the contractor’s position is going to be on things.” Read the court decision
Read the full story...
Reprinted courtesy of

Safety Officials Investigating Death From Fall

September 09, 2011 — CDJ STAFF

California safety officials are looking into the circumstances surrounding the death of a construction worker who fell from a roof in Tiburon, California. Another worker found Gabriel Vasquez unconscious at the site. Vasquez was later pronounced dead. The State Division of Occupational Safety and Health are trying to determine how Vasquez fell.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Loss Ensuing from Alleged Faulty Workmanship is Covered

July 19, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that under Montana law, water damage resulting from alleged faulty workmanship in repairing the insured's roof was covered. Leep v. Trinity Universal Ins Co., 2017 U.S. Dist. LEXIS 86759 (D. Mont. June 6, 2017). The insured's property was damaged in a hail storm. The insured contracted with Sprauge to repair the hail damage. Sprauge tore off and replaced roof lining and shingles. Sprague replaced a vent cap and tubes, but did not replace any vent piping or vents. The contract between the insured and Sprauge provided it was the owners' responsibility to check the exhaust vents for all furnaces and water heaters after the roofing project was completed. Subsequent to the repairs, water was found dripping from a bathroom fan. Moisture was also found on the second story emanating from the ceiling. Finally, in the attic, the furnace vent piping was disconnected and the furnace exhaust was venting into the attic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES