FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Parties to an Agreement to Arbitrate May be Compelled to Arbitrate with Non-Parties

February 28, 2022 — Paul R. Cressman Jr. - Ahlers Cressman & Sleight PLLC
In a recent case decided by Division III of the Washington Court of Appeals, David Terry Investments, LLC – PRC v. Headwaters Development Group LLC,[1] the court held that parties to an arbitration agreement can be compelled to arbitrate related claims with non-parties to the agreement based on the doctrine of equitable estoppel. The case involved six joint venture agreements to develop three separate properties in Spokane, two joint venture agreements per property. One entity, David Terry Investments, LLC – PRC (“DTI”), owned by David Terry, was a partner in each of the six joint venture agreements. DTI joint ventured with S.G. Spady Consulting (“SGSC”) and with Headwaters Development Group LLC (“HDG”) separately for each of the three properties. HDG owned the three properties, and SGSC was to provide construction management advice. Steve Spady was the principal of both HDG and SGSC. Stoneridge was a licensed general contractor, the principal of which was also Steve Spady. Read the court decision
Read the full story...
Reprinted courtesy of Paul R. Cressman Jr., Ahlers Cressman & Sleight PLLC
Mr. Cressman may be contacted at paul.cressman@acslawyers.com

---

Additional Insured Is Covered Under On-Going Operations Endorsement Despite Subcontractor's Completion of Work

December 20, 2017 — Tred Eyerly - Insurance Law Hawaii
Although the homeowners did not own their homes when the subcontractors completed their work, the general contractor was still covered as an additional insured for the homeowners' suits based on the ongoing operations endorsement in the subcontractors' policies. McMillin Mgmt. Servs. v. Fin. Pac. Ins. Co., 2017 Cal. App. LEXIS 1000 (Cal. Ct. App. Nov. 14, 2017). McMillin was the developer and general contractor for the project. Among the subcontractors were Martinez Construction Concrete Contractor, Inc. and Rozema Corporation. Martinez performed concrete flatwork between 2003 and November 2005. Rozema performed lath and stucco work between March 2003 and October 2005. Lexington issued CGL policies to Martinez and Rozema. McMillin was an additional insured under both policies, "but only with respect to liability arising out of your [i.e., Martinez's or Rozema's] ongoing operations performed for [McMillin]." An exclusion provided that the insurance did not apply to property damage occurring after the insured subcontractor had completed operations on behalf of the additional insured. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly, Insurance Law Hawaii
Mr Eyerly may be contacted at te@hawaiilawyer.com

---

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Dave McLain included in the 2023 edition of The Best Lawyers in America

March 06, 2023 — David M. McLain – Colorado Construction Litigation
Colleagues and friends: I am pleased to share with you that I have been recognized in the 2023 edition of The Best Lawyers in America for my work in construction law. This honor comes as a surprise and is a testament to the dedication and hard work of my team at Higgins, Hopkins, McLain & Roswell, LLC. As many of you know, my practice focuses on the defense of complex construction lawsuits on behalf of developers, general contractors, and other construction professionals. I have been fortunate enough to work with some of the largest home builders and general contractors in the state and country, regional and custom builders, and numerous insurance carriers over the years. Through these experiences, I have been able to gain valuable insights into the construction industry, and I am proud to be considered an expert in this field. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Burden Supporting Termination for Default

January 11, 2021 — David Adelstein - Florida Construction Legal Updates
Terminating a contractor for default is a “‘drastic sanction’ and ‘should be imposed (or sustained) only for good grounds and on solid evidence.’” Cherokee General Corp. v. U.S., 150 Fed.Cl. 270, 278 (Fed.Cl. 2020) (citation omitted). This is true with any termination for default because terminating a contract for default is the harshest recourse that can be taken under a contract. It is a caused-based termination. For this reason, the party terminating a contract for default needs to be in a position to carry its burden supporting the evidentiary basis in exercising the default-based (or caused-based) termination. Stated differently, the party terminating a contract for default needs to justify the reasonableness in terminating the contract for default. A party looking to terminate a contract for default should smartly work with counsel to best position its justification in exercising the termination for default. Likewise, a contractor terminated for default should immediately work with counsel to best position the unreasonableness or the lack of justification for the default-based termination. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Musk’s Cousins Battle Utilities to Make Solar Rooftops Cheap

April 15, 2015 — John Lippert and Christopher Martin – Bloomberg
In September 2013, Hawaiian Electric Co. told thousands of customers they couldn’t connect their new solar panels to its distribution grid. In some neighborhoods, HECO said, its system couldn’t absorb any more unused energy from home solar arrays. The moratorium, which lasted 13 months, made Hawaii a central battleground in the effort by utilities to control the rapid growth of independent solar companies across the U.S. And it was a big deal to people such as Robert Gould, a retired Northwest Airlines pilot living near Honolulu. He’d just paid $53,000 to have solar panels installed. Gould and other customers protested loudly to state officials. They finally got help from Lyndon Rive, the CEO of SolarCity. The San Mateo, California, company is the biggest installer of rooftop solar panels in the U.S. and has 10,000 Hawaiian customers, Bloomberg Markets magazine reports in its May issue. Rive studied the situation and zeroed in on a key fact: HECO had never directly measured how much solar its grid could handle, relying on computer simulations instead. “Because the technology is brand-new, no one had ever done this in the field before,” says Colton Ching, HECO’s vice president for energy delivery. Reprinted courtesy of John Lippert, Bloomberg and Christopher Martin, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

---

Eliminating Waste in Construction – An Interview with Turner Burton

June 29, 2020 — Aarni Heiskanen - AEC Business
I had the pleasure of interviewing Turner Burton, President of Hoar Construction. We discussed waste in construction and how his company is on a mission to eliminate it. Can you say a few words about yourself and your company? I grew up around construction and this company, hearing about the business from both my grandfather and my father. I started working on job sites in high school forming concrete, continued working on projects throughout college, and since graduating from college, I’ve taken on different roles in the company to ensure I understand all aspects of the business. Hoar Construction was founded 80 years ago, and throughout our history, we’ve been committed to learning from every project to improve our processes and deliver the best building experience possible for our clients and partners. But it’s the relentless pursuit of improvement that really sets us apart as builders – to always strive to be the best and do the right thing for our customers and partners. There’s something to be said for setting a goal that you’ll always be working toward. It fosters hard work, collaboration, and productive effort. If we’re always working to find a better way, then we will always be improving. That effort drives better results for our owners and everyone we work with. Essentially, we’re always working toward something. Always improving. Always in process. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---