Defining Constructive Acceleration
March 22, 2021 —
David Adelstein - Florida Construction Legal UpdatesWhen it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim.
In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
NY Gov. Sets Industry Advisory Council to Fix Public Contracts Process
February 01, 2022 —
James Leggate - Engineering News-RecordA New York construction industry advisory group, created under a law Gov. Kathy Hochul signed in December, will study and recommend adjustments to state public contracting to address damages incurred by contractors, subcontractors and others because of payment delays on public projects.
Reprinted courtesy of
James Leggate, Engineering News-Record
Mr. Leggate may be contacted at leggatej@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
NJ Court Reaffirms Rule Against Coverage for Faulty Workmanship Claims and Finds Fraud Claims Inherently Intentional
September 20, 2021 —
Anthony L. Miscioscia & Frank J. Perch, III - White and Williams LLPAwarding summary judgment to an insurer under both liability and directors & officers (D&O) coverage parts, a New Jersey trial court reaffirmed the principle that claims of defective workmanship without resulting “property damage” are not covered under a general liability policy, and further dismissed claims for fraud and breach of fiduciary duty, finding that such claims were inherently intentional and do not state a covered “occurrence.”
In Velez v. AR Management Company, et al., 2021 N.J. Super. Unpub. LEXIS 1675 (Law Div. Bergen Co. Aug. 10, 2021), owners of a condominium unit rebuilt after a fire sued the condominium association, several association board members, the association’s property management company and the general contractor for the reconstruction work. The owners’ suit alleged faulty workmanship and incomplete repairs. In addition, the owners asserted fraud and breach of fiduciary duty claims against the management company, alleging conflicts of interest and self-dealing between the management company and the general contractor, which had common ownership.
In a third-party complaint, the management company sought coverage from the condo association’s liability and D&O insurer. The court dismissed the D&O coverage claim, noting that the management company was not a director or officer or otherwise entitled to insured status for the D&O coverage part.
Reprinted courtesy of
Anthony L. Miscioscia, White and Williams LLP and
Frank J. Perch, III, White and Williams LLP
Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com
Mr. Perch may be contacted at perchf@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Shea Homes CEO Receives Hearthstone Builder Humanitarian Award
February 12, 2014 —
Beverley BevenFlorez-CDJ STAFFBert Selva, Shea Homes CEO, received the Hearthstone Builder Humanitarian Award at the 2014 NAHB International Builders’ Show in Las Vegas, Nevada, according to Big Builder. Selva “has served for 11 years on HomeAid's board of directors,” and “is a big supporter of the nonprofit that works to provide housing for homeless families, victims of natural disasters, and veterans.” Furthermore, “Shea Homes has built eight HomeAid shelter projects valued at more than $5.2 million and has contributed nearly $850,000 to HomeAid and its chapters, making it one of the group's largest benefactors.” Not only does Selva actively support HomeAid, he also “serves as a national vice president of the Muscular Dystrophy Association.”
"I ask myself, 'How would it feel if that were me or my family?'" Selva told Big Builder. "When you personalize it, it becomes a lot more real and that's the motivation for me."
The award “includes recognition at an event during the 2014 International Builders' Show and a cash award to a charity of his choice.”
Read the full story, Jennifer Goodman’s Article...
Read the full story, John McManus’s Article... Read the court decisionRead the full story...Reprinted courtesy of
New York’s Comprehensive Insurance Disclosure Act Imposes Increased Disclosure Requirements On Defendants at the Beginning of Lawsuits
February 07, 2022 —
Craig Rokuson & Lisa M. Rolle - Traub Lieberman Insurance Law BlogOn December 31, 2021, New York Governor Kathy Hochul signed into law the Comprehensive Insurance Disclosure Act, which amends Section 3101(f) of the Civil Practice Law & Rules (CPLR) to require the automatic disclosure of insurance-related items within sixty days of the filing of an answer in a civil suit. For lawsuits pending as of the effective date of the Act, the disclosures required by Section 3101(f) must be provided by March 1, 2022.
Pursuant to amended Section 3101(f), defendants (including third-party defendants, cross-claim defendants, and counterclaim defendants) must provide the following information to plaintiffs within sixty days of answering the affirmative pleading, accompanied with a certification from both the defendant and his/her/their/its defense counsel that the disclosures are accurate and complete:
- Copies of all insurance policies that may be liable to satisfy a judgment in the lawsuit, including the insurance application.
- The contact information of any individuals responsible for adjusting the claim on each policy, including his/her/their phone number and email address. If a TPA is involved, his/her/their contact information must also be disclosed.
Reprinted courtesy of
Craig Rokuson, Traub Lieberman and
Lisa M. Rolle, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com
Ms. Rolle may be contacted at lrolle@tlsslaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Are Untimely Repairs an “Occurrence” Triggering CGL Coverage?
November 16, 2020 —
Christopher G. Hill - Construction Law MusingsAll Class A commercial contractors in Virginia are required to have a minimum level of Commercial General Liability (CGL) coverage. As a general rule, this insurance is there for damage to property or persons arising from an “occurrence” that is covered by the policy. Many cases that are litigated relating to coverage for certain events under a CGL policy turn on the definition of “occurrence” and whether the event leading to a request for coverage constitutes an “occurrence.”
A recent case in Fairfax County, Virginia, Erie Insurance Exchange v. Spalding Enterprises, et al., is just such a case. In the Spalding Enterprises case, the Court considered the following scenario. A homeowner, Mr. Yen contracted with Spalding Enterprises to fix some fire damage at his home. Spalding promised the repairs would be complete in October of 2019. However, after Mr. Yen paid a $300,000.00 deposit, Spalding Enterprises stated that the work would not be completed until November of 2019. Yen then fired Spalding Enterprises and sued for breach of contract, constructive fraud, and violation of the Virginia Consumer Protection Act. Spalding Enterprises sought coverage from Erie Insurance for the claim and Erie denied coverage and sought a declaratory judgment that the events alleged in the Complaint by Mr. Yen did not fall under the definition of “occurrence” in the CGL policy held by Spalding Enterprises.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Prevent Costly Curb Box Damage Due on New Construction Projects
May 11, 2020 —
Bob Welker - Construction ExecutiveFor new construction projects in areas with acidic soils, keeping curb boxes in good working order is critical to avoid compromised water service, angry customers, and costly repair and replacement.
Traditionally, a curb box is composed of a metal tube that connects the cast iron base to a cast iron lid/cap. It is necessary for water line repairs and shut off in case of flooding. Typically, they are buried six to eight feet below ground, beneath the frost line. Curb boxes are found on every water line that connects a building to a city water main.
One major challenge is that many areas across the United States—including the East Coast, South, upper Midwest and Pacific Northwest—have acidic soil that rapidly corrodes cast iron infrastructure, including curb boxes. Soil with a pH of six or less is considered acidic.
Reprinted courtesy of
Bob Welker, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Breach of a Construction Contract & An Equitable Remedy?
September 22, 2016 —
David Adelstein – Florida Construction Legal UpdatesIn payment or collection-type lawsuits, the party suing for money sometimes asserts a claim for unjust enrichment or quantum meruit as an alternative equitable remedy to a breach of contract claim. Frankly, sometimes a party will do this as a means to throw everything against the wall hoping something, just something, sticks. However, if there is a contract by and between the parties, equitable claims such as unjust enrichment or quantum meruit will invariably fail. They will fail because a party cannot circumvent a contract simply because their recourse may prove better under an equitable theory. It doesn’t work like that! And, it should not!
Read the court decisionRead the full story...Reprinted courtesy of
David M. Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com