Seattle Washington Building Expert Directory

Tips for Drafting Construction Contracts

May 04, 2020 — Stuart Rosen - Construction Executive
When negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern. For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation. This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations. Contractor’s liability to the owner for delay damages It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.” Reprinted courtesy of Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Rosen may be contacted at srosen@proskauer.com

Monitoring Building Moisture with RFID – Interview with Jarmo Tuppurainen

February 22, 2018 — Aarni Heiskanen – aec business
I met Jarmo, the Technology Manager at Helsinki Metropolia University of Applied Sciences, at the leading event for housing markets in Helsinki (Asuntomarkkinat). He and his team had set up an impressive display of devices and structures in the KIRA-digi showroom. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, aec business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Appraisal Goes Forward Even Though Insurer Has Yet to Determine Coverage on Additional Claims

December 11, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's order granting the insured's motion to stay litigation and compel an appraisal was affirmed even though the insurer had not determined coverage on the insured's additional claims.Heritage Prop. & Cas. Ins. Co. v. Wellington Place HOA, 2023 Fla. App. LEXIS 6405 (Fla. Ct. App. Sept. 13, 2023). The insured homeowner's association reported roof damage to its insurer, Heritage, after Hurrican Irma struck. Heritage agreed the damage was covered, but issued no payment because the amount of loss was less than the deductible. The insured hired its own adjuster. The insured requested an extension of the policy's two year time limit to complete repairs because the claim was still in dispute and the insurer had not yet paid sufficient funds to allow necessary repairs. Heritage sent a revised estimate and asked the insured to send its adjuster's estimate in order to address any disputes. The insured submitted its adjuster's estimate of more than $6 million, including, for the first time, the cost to replace all the windows and sliding glass doors. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Calling the Shots

May 03, 2021 — Construction Executive
As of 2019, women accounted for 10% of the total construction workforce. That’s 1.2 million women in the field, sculpting the built environment and calling the shots. A smaller percentage of the industry’s population does not mean less ability to achieve success. According to The National Association of Women in Construction, 44% of women in construction serve in a professional and management capacity. As the pandemic lingers on, sourcing qualified candidates is becoming more difficult, and finding nuanced methods of retaining valuable employees remains at the forefront of modern business. One estimate cites a loss of 600,000 women from the overall U.S. workforce in September 2020. However, data suggest that construction employment for women has remained steady, compared with struggling sectors such as retail and hospitality. Plus, salary disparities are becoming less prominent in the construction sector where, according to NAWIC, women earn 99.1% of what men make, and the female population has seen steady growth since 2012. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Candis Jones Named to Atlanta Magazine’s 2022 “Atlanta 500” List

February 14, 2022 — Candis Jones - Lewis Brisbois Newsroom
Atlanta, Ga. (February 11, 2022) - Atlanta Partner Candis R. Jones has been named to Atlanta Magazine’s 2022 “Atlanta 500” list of the most powerful business leaders in Atlanta. This is the second year in a row she has received this recognition. To compile this list, the publication reviewed nominations from the public and consulted experts across various sectors. The magazine’s editors and writers considered not only the status of the nominees within their respective organizations, but also whether the nominees were visionary by, for example, leading programs for their communities or creating opportunities for employees. Read the court decision
Read the full story...
Reprinted courtesy of Candis Jones, Lewis Brisbois
Ms. Jones may be contacted at Candis.Jones@lewisbrisbois.com

California Cracking down on Phony Qualifiers

July 23, 2014 — Beverley BevenFlorez-CDJ STAFF
Garret Murai in his California Construction Law Blog stated that “California’s Senate Bill 862, and amended Business and Professions Code 7068.1” has given the California Contractors State License Board (CSLB) “additional enforcement authority to crack down on phony qualifiers by allowing the CLSB to take disciplinary action against a qualifier and a licensee if the qualifier is not actively involved in the construction activities of the licensee’s business.” Murai explained that “[r]enting a qualifier means that you pay an individual who holds a California contractor’s license to act as the Responsible Managing Officer (RMO) or Responsible Managing Employee (RMO) of a construction company when they have no actual involvement in the day-to-day operations of the company.” Read the court decision
Read the full story...
Reprinted courtesy of

Sales of New U.S. Homes Fell in February to Five-Month Low

March 26, 2014 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. fell in February to the lowest level in five months, a sign the industry may take time to pick up after inclement weather damped demand earlier in the year. Sales declined 3.3 percent to a 440,000 annualized pace, following a 455,000 rate in the prior month that was the strongest in a year, figures from the Commerce Department showed today in Washington. The median forecast of 77 economists surveyed by Bloomberg called for 445,000. Unusually frigid temperatures added to restraints including rising mortgage rates, higher property values, and a lack of supply that kept prospective buyers away from the market for new and existing properties. Bigger gains in employment and consumer sentiment would help spur the recovery in homebuilding, sustaining its contribution to economic growth and boosting earnings at companies such as Lennar Corp. and KB Home. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted at schandra1@bloomberg.net

Unfortunate Event Test Leads to Three Occurrences

December 02, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Second Circuit affirmed the finding of three occurrences in a highway accident after applying the unfortunate event test. Nat'l Liability & Fire Ins. Co. v. Itzkowitz, 2015 U.S. App. LEXIS 16387 (2nd Cir. Sept. 15, 2015). A dump box attached to a dump truck struck and damaged an overpass. The dump box then separated from the truck and landed in the right lane of the highway. Some thirty seconds to five minutes later, the Itzkowitz vehicle struck the detached dump box. Then, at some point between a few seconds and twenty minutes later, the Hershkowitz (second) vehicle struck the dump box. The insurer for the dump truck owner, National, argued there was one accident, or at most two separate accidents, under the policy. The district court found there were three occurrences and National appealed. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES