Construction Litigation Roundup: “Just Hanging Around”
August 14, 2023 —
Daniel Lund III - LexologyA subcontractor asserting a payment bond claim for “standby” time for its equipment on the Cline Avenue bridge project (over Indiana Harbor and Ship Canal in East Chicago, Indiana) received pushback from the payment bond surety.
In fact, the duration of the standby time occurred after the surety’s principal, the general contractor, had been placed in default and terminated on the general contract. According to the surety: “After termination of the contract… it is impossible for labor, materials, and equipment to have been furnished for use in performing the terminated contract.” The surety filed a motion for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Used French Fry Oil Fuels London Offices as Buildings Go Green
December 10, 2015 —
Siobhan Wagner – BloombergPricewaterhouseCoopers LLP’s office above Charing Cross railway station in London is cooled, heated and fueled by an unlikely source: used cooking oil.
The system, which helped the property become the greenest building in the U.K. capital, uses oil refined less than two miles away at London Bridge. It also helps prevent an invisible problem: “fatbergs” formed when oils dumped in drains and pipes congeal with baby wipes and diapers and block the city’s sewers.
“We’re using London’s waste to fuel a London office building,” said Jon Barnes, head of building at PwC. The system contributed toward a one-third reduction in electricity costs after a two-year refurbishment of the One Embankment Place office building that finished last year.
Read the court decisionRead the full story...Reprinted courtesy of
Siobhan Wagner, Bloomberg
Consequential Damages From Subcontractor's Faulty Work Constitutes "Property Damage" and An "Occurrence"
September 03, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe New Jersey appellate court found that the unintended and unexpected consequential damages caused by the subcontractor's defective work constituted "property damage" and an "occurrence." Cypress Point Condo. Ass'n v. Adria Towers, L.L.C., 2015 WL 4111890 (N.J. Super. Ct. App. Div. July 9, 2015).
The insured developer hired subcontractors to perform all of the construction work at a condominium project. The subcontractors failed to properly install the roof, flashing, gutters and leaders, brick and EIFS facade, windows, doors and sealants. The AOAO sued the developer, who served as the general contractor, its insurers, and various subcontractors.The AOAO conceded that replacement costs did not constitute "property damage" and an "occurrence" under the policy.
The faulty workmanship, however, also caused consequential damages to the common areas and unit owners' property, including damage to steel supports, exterior sheathing and interior sheathing and sheetrock, insulation and other interior areas of the building. Nevertheless, the trial judge determined there was no property damage or "occurrence", and granted summary judgment to the insurers.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Pennsylvania Civil Engineers Give the State's Infrastructure a "C-" Grade
November 28, 2022 —
American Society of Civil EngineersPENNSYLVANIA. — The Pennsylvania Council of the American Society of Civil Engineers (ASCE) released the 2022 Report Card for Pennsylvania's Infrastructure today at three congruent news conferences across the state including Harrisburg, Lehigh Valley, and Pittsburgh, with 15 categories of infrastructure receiving an overall grade of a "C-". This is the same grade issued by the council in its 2018 report. A "C-" means Pennsylvania's infrastructure is in mediocre condition and requires attention. Pennsylvania's aviation and rail networks are helping to drive economic growth in the region and an improved roadway network is helping increase efficiency for the regional and national economies, but an aging infrastructure network and struggling water systems threaten the health, safety and welfare of the region. Civil engineers graded aviation (B-), bridges (D+), dams (C), drinking water (D), energy (C), hazardous waste (B-), levees (C), parks (C+), ports (C+), rail (C), roads (C-), solid waste (C+), stormwater (D), transit (D), and wastewater (D-).
"Considering Pennsylvania's aging infrastructure and its critical role in our state's economy, policy makers must continue to prioritize dedicated funding to update and improve all infrastructure assets," said Rep. Mike Carroll, D-118. "Failure to do so will seriously harm the quality of life for every citizen."
"This report shows that Pennsylvania's infrastructure has seen some noteworthy improvements and that our lawmakers are prioritizing the built environment, but out-of-sight, out-of-mind systems such as water and wastewater pipelines are lacking the necessary attention," said David DiGioia, chair, 2022 Report Card for Pennsylvania's Infrastructure. "With help from the Bipartisan Infrastructure Law, we could improve our communities for generations if we double down on investment and close our funding gaps across all sectors included in this report."
The Report Card was created as a public service to citizens and policymakers to inform them of the infrastructure needs in their state. Civil engineers used their expertise and school report card-style letter grades to condense complicated data into an easy-to-understand analysis of Pennsylvania's infrastructure network. ASCE State and Regional Infrastructure Report Cards are modeled after the national Infrastructure Report Card, which gave America's infrastructure an overall grade of 'C-' in 2021.
To view the report card and all five categories, visit https://infrastructurereportcard.org/state-item/Pennsylvania/.
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
Read the court decisionRead the full story...Reprinted courtesy of
Homeowners Sue Over Sinkholes, Use Cash for Other Things
January 06, 2012 —
CDJ STAFFQuoting one homeowner as saying that his house “can fall in the ground for all I care, I made my money,” the Tampa Bay Times looks at the issue of sinkhole claims in Florida. Homeowners “have paid off mortgages, put in pools, replaced roofs, or otherwise used money from sinkhole claims to do something besides fix sinkhole damage.
It’s been tough for insurance companies. Citizens Property Insurance took in $32 million in premiums for sinkhole coverage in 2010, but paid out $245 million in sinkhole claims. The Tampa Bay Times notes that some of those claims come from settling problems caused by their repairs, including one settlement of $350,000 for repairs to a house worth $39,000.
One couple, after receiving $217,000 from Citizens, sold the house to a company that bought unrepaired sinkhole homes for $190,000. The home has been sold since and remains unrepaired.
Sometimes the preferred solution by the insurance company isn’t the cheapest either. One couple was informed that Citizens was going to spend $150,000 to have the hole filled with grout. After they settled with the insurance company, they fixed the problem by installing steel piers, at a cost of about $45,000.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Home Numbers Remain Small While Homes Get Bigger
June 28, 2013 —
CDJ STAFFCatherine Rampell reports in the New York Times that while the number of single-family homes built in 2012 was still at the very bottom of the range, since the government starting recording this data in 1973, the medium size for these homes is at its largest ever. According to data collected by the Census Bureau, these homes also have more bedrooms and bathrooms than previously. Of all homes built in 2012, forty-one percent had four or more bedrooms and thirty percent had three or more bathrooms. Both of these were the highest percentages in those categories.
Meanwhile, the size of newly-built rental units declined in 2012. While still larger than the average rental unit built in 1999 (the earliest date given in the article), there has been little change over the last decade. During the same period, the size of sale units in multi-family buildings did show an increase.
Read the court decisionRead the full story...Reprinted courtesy of
Another Exception to Fraud and Contract Don’t Mix
January 18, 2021 —
Christopher G. Hill - Construction Law MusingsHere at Construction Law Musings, we’ve discussed the fact that, in Virginia, the “economic loss rule” generally renders claims of fraud and construction contracts like oil and water. This is true in most states, including Florida.
What this means is that as a general rule where any party is supposed to perform under a contract, and fails to do so, the Virginia courts will dismiss a fraud claim out of a desire to avoid turning any breach of contract (read “broken promise”) case into a claim for fraud. As you have likely gathered by the title of this post, there are exceptions. One is a properly plead Virginia Consumer Protection Act (“VCPA”) claim.
Another, found in a recent Loudoun County, VA Circuit Court opinion in Madison v. Milton Home Systems Inc., is so called fraud in the inducement (in other words, inducing a person to enter the contract under false pretenses). In Madison the Court analyzed several counts based upon a modular home contract and so called “performance agreement” guarantying that the home would be installed by the manufacturer in the event that it’s installer failed to perform.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Are COVID-19 Claims Covered by Builders Risk Insurance Policies?
May 04, 2020 —
Jason M. Adams, Gibbs Giden Locher Turner Senet & Wittbrodt LLP and Cheryl L. Kozdrey, Saxe Doernberger & Vita, P.C.If you are an attorney, insurance broker, or other professional representing developers and contractors, then your clients have likely reached out with concerns about losses related to COVID-19. One common question is whether there is potential coverage under builders risk insurance policies.
The short answer is: It depends. As with most questions pertaining to insurance coverage, the answers depend on the specific policy language and underlying facts required to trigger coverage. Builders risk policies are even more fact specific due to the lack of uniformity of base policy forms and endorsements between insurance carriers.
The first step in any analysis is to gather facts and carefully document any impending and potential damages or delays. The facts are crucial because the coverage analysis may vary depending on the specific reason the project was shut down. For example, the analysis would be different if the project was shut down as a result of an express government order, such as those in Northern California and Washington, versus the project shutting down as a result of workers testing positive for COVID-19. Properly analyzing builders risk coverage involves a granular account of the facts and damages, and can require a great deal of hair splitting with respect to specific policy language.
Regardless of the strength of the insured’s facts and damages, or the breadth of its policy language, the policyholder still likely faces an uphill battle in finding coverage for COVID-19 related claims. The unfortunate reality of most builders risk policies is that they are property policies that require some evidence of physical loss or damage to trigger coverage. Whether or not COVID-19 claims constitute property damage will be the subject of great debate and litigation over the coming months and years. The outcome will likely depend on how the insured’s jurisdiction ultimately rules on the litany of COVID-19 cases that have already been filed – specifically, how broadly each court interprets the meaning of “physical loss or damage.”
Although these key issues have yet to be clearly defined by the courts, some policies are better than others and there are specific variables that could affect the likelihood of coverage. For example, some of the more policyholder-friendly insurance programs may contain coverage extensions for delay in completion, business interruption, loss of rental income, or civil authority that may not be tied to the property damage requirement, and which would tend to support coverage for COVID-19 claims.
Even if the insured crosses the initial threshold and can demonstrate a covered claim, the following common endorsements and exclusions may require additional analysis depending on the facts.
- Virus or Pandemic Exclusions: Virus or pandemic exclusions are not as common on builders risk policies as they may be on other forms of coverage. However, they do exist and, if present, result in a significant barrier to coverage. As with the policy itself, every endorsement is different and should be analyzed in terms of the express language contained in the endorsement and the facts.
- Abandonment or Cessation of Work: Most builders risk policies include provisions that preclude coverage in the event of the abandonment of the project or a lengthy cessation of work. As a result, the insured should take steps to articulate to the carrier that the project has not been abandoned, and that there exists an intent to return as soon as possible. The insured should also maintain a record of ongoing project oversight and protection efforts taken during the period when construction operations are suspended.
- Security and Safety Requirements: Many builders risk policies contain provisions requiring the insured to maintain protective safeguards and security protocols throughout the pendency of the project. Safety fencing, lighting and security guards are common examples. The policy should be analyzed to ensure that the policyholder can meet any such requirements during a COVID-19 related shutdown. For example, can the insured continue to staff a security guard? If not, arrangements will likely need to be made with the carrier depending on the language of the policy.
- Insurable Limits: Builders risk policies are typically underwritten based upon the total completed value of the structure, including materials and labor. The insured will need to analyze the policy to consider whether increased material or labor costs as a result of COVID-19 will alter the terms of coverage, trigger any escalation clauses, or result in an increase in premium due. If increased cost projections become apparent, the insured should report these changes to the carrier immediately.
- Extensions of Coverage: The insurance industry was facing a hard market even before the COVID-19 pandemic, which resulted in higher premiums and limited coverage options. The COVID-19 pandemic has only exacerbated these issues and it may be difficult to obtain coverage extensions on projects that have been shut down. The insured should work with its risk management team (risk manager, insurance broker and lawyer) to engage the carriers to negotiate any necessary coverage extensions resulting from COVID-19 related project delays.
To summarize, builders risk coverage for COVID-19 claims is far from certain, but not impossible. Insureds should provide notice of a claim to all potentially applicable carriers in order to preserve their rights. The insured should also report increased construction cost and articulate its intent to return to the project to preserve their escalation clause and avoid arguments that they have abandoned the project. The insured should continue to document its claims and damages, and be ready to substantiate its claims and push back on any coverage denial. Throughout the entirety of this process, the insured should work with its risk management team to get out in front of any extensions it may need to complete the project. In a climate where insurance carriers are receiving an insurmountable number of claims, the insured should be prepared to fight for coverage and not simply throw up its hands in the face of a denial. Given the intense social, legislative and executive pressure to cover COVID-19 claims, there may be a tendency for the courts to find coverage in gray areas, particularly if the insured was fortunate enough to have purchased one of the broader coverage forms referenced above.
About the Authors
Jason M. Adams, Esq. (jadams@gibbsgiden.com) is a partner at Gibbs Giden representing construction professionals in the areas of Construction Law, Insurance Law and Risk Management and Business/Civil Litigation. Adams is also a licensed property and casualty insurance broker and certified Construction Risk & Insurance Specialist (CRIS). Jason represents developers, contractors, public entities, investors, lenders, REITs, design professionals, and other construction professionals at all stages of the construction process. Jason is a published author and sought-after speaker at seminars across the country regarding high level construction risk management and insurance topics. Gibbs Giden is nationally and locally recognized by U. S. News and Best Lawyers as among the “Best Law Firms” in both Construction Law and Construction Litigation. Chambers USA Directory of Leading Lawyers has consistently recognized Gibbs Giden as among California’s elite construction law firms.
Cheryl L. Kozdrey, Esq. (clk@sdvlaw.com) is an associate at Saxe Doernberger & Vita, P.C., a national insurance coverage law firm dedicated exclusively to policyholder representation and advocacy. Cheryl advises insurance brokers, risk managers, and construction industry professionals regarding optimal risk transfer strategies and insurance solutions, including key considerations for Builder’s Risk, Commercial General Liability, D&O, and Commercial Property policies. She assists clients with initial policy reviews, as well as renewals and modification(s) of existing policies to ensure coverage needs are satisfied. Cheryl also represents policyholders throughout the claims process, and in coverage dispute litigation against insurance carriers. She is currently working on some of the largest construction defect cases in the country. Cheryl is a published author and is admitted to practice in the State of California and all federal district courts within the State.
Read the court decisionRead the full story...Reprinted courtesy of
