Fairfield Connecticut Building Expert Directory

High Court Case Review Frees Jailed Buffalo Billions Contractor CEO

August 22, 2022 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
Hidden amid the U.S. Supreme Court's flurry of high-profile rulings that ended its current term—such as overturning Roe v. Wade and scaling back federal regulation of greenhouse gas emissions—was a less-noticed decision to take a case next year that could change the fortunes of a convicted New York contractor who was serving a federal prison term for bid-rigging. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Subcontractors Eye 2022 with Guarded Optimism

October 11, 2021 — Louise Poirier - Engineering News-Record
While work continues to be plentiful for specialty contractors across the five-state region of Arkansas, Louisiana, Mississippi, Oklahoma and Texas, concerns remain for how the project landscape will continue to evolve as the impacts of the COVID-19 pandemic continue to weigh on the world. Reprinted courtesy of Louise Poirier, Engineering News-Record Ms. Poirier may be contacted at poirierl@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Defects in Texas High School Stadium Angers Residents

March 07, 2014 — Beverley BevenFlorez-CDJ STAFF
According to WFAA News, many residents of Allen, Texas were upset when their tax dollars were spent on a new high school football stadium, and they are angry now that alleged construction defects may cause the stadium to close, and perhaps not even reopen again this fall. There “is a disproportionately large amount of our tax dollars that goes just to Allen ISD," Rachel Palmer, an Allen resident, told WFAA News. However, Ben Pogue, president of Pogue Construction, the stadium’s general contractor called the situation “a road bump.” WPAA News also interviewed Dr. Simon Chao of the Department of Civil Engineering at the University of Texas at Arlington: "Cracking is fairly common in concrete," Chao stated. "The problem is the damage water may cause by getting in the cracks.” Read the court decision
Read the full story...
Reprinted courtesy of

Top Five Legal Mistakes in Construction

April 04, 2022 — Jonathan A. Cass, Nicholas F. Morello & John A. Greenhall - Construction Executive
Many contractors repeatedly make the same mistakes in negotiating contracts. Here are the most common mistakes contractors make—and how they can be avoided. 1. Not Being Careful With Force Majeure Clauses To protect themselves from liability in the event of unforeseen circumstances like fires, floods, wars, unusual delays in deliveries, strikes, pandemics or acts of God, contractors should ensure their contracts contain robust force majeure provisions. These provisions state that in the event of any extenuating circumstances outside of its control, the contractor is not liable for any damages that result from a delay to the project completion date and is entitled to a time extension. This clause has been critical in addressing COVID-19-related disruptions and the current material shortages. Contractors should be wary, however, of “no damage-for-delay” language, which often appears in conjunction with these clauses. Reprinted courtesy of Jonathan A. Cass, Nicholas F. Morello and John A. Greenhall, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Cass may be contacted at jcass@cohenseglias.com Mr. Greenhall may be contacted at jgreenhall@cohenseglias.com Mr. Morello may be contacted at nmorello@cohenseglias.com Read the court decision
Read the full story...
Reprinted courtesy of

Montana Federal Court Upholds Application of Anti-Concurrent Causation Clause

November 08, 2021 — Tred R. Eyerly - Insurance Law Hawaii
Interpreting Montana law, the federal district court found that the policy's anti-concurrent causation clause prevented coverage for the insured's damaged home. Ward v. Safeco Ins. Co. of Am., 2021 U.S. Dist. LEXIS 149051 (D. Mont. Aug. 9, 2021). Plaintiff was advised by her tenants that water was bubbling up from the ground. It was determined that water was leaking from a main pipe serving the property. Subsequently, this old pipe was abandoned, left in the ground, and replaced with a new pipe in a new path with new excavation. Nevertheless, the insured reported the incident to her agent under her Landlord Protection Policy issued by Safeco, but reported there was no damage to the property. Two months later, it was discovered a pipe burst again. The insured called her agent, who maintained the loss would not be covered, but agreed to submit a claim to Safeco. Safeco hired an inspector. A report stated that a portion of cracks found in the concrete perimeter of the home were not new and that the shape of the structure on which the house sat could explain their presence. The report noted that new cracks in the foundation could have been caused by a lack of care to make sure that the foundation was sufficient supported by consolidated soil during the excavation of the new water line. Based upon this report, Safeco denied coverage based upon the earth movement and water damage exclusions. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Michigan Civil Engineers Give the State's Infrastructure a "C-" Grade, Improving from "D+" Grade in 2018

May 08, 2023 — The American Society of Civil Engineers
LANSING, MI. — The Michigan Section of the American Society of Civil Engineers (ASCE) released the 2023 Report Card for Michigan's Infrastructure today, with 14 categories of infrastructure receiving an overall grade of 'C-', an improvement over the 'D+' grade issued in the state's 2018 report card. That means Michigan's infrastructure systems are improving but are still in average condition and require attention. Michigan's grade is on par with the national average of 'C-' given in the 2021 Report Card for America's Infrastructure. Civil engineers graded Michigan's aviation (C), bridges (D+), dams (C-), drinking water (D+), energy (D), inland waterways (C), public parks (C), rail (C), roads (D), schools (C-), solid waste (C+), stormwater (D), transit (C-), and wastewater (C). The report also included a chapter on the state's broadband infrastructure, which did not receive a grade due to insufficient available data. Michigan policymakers have driven progress in the last five years to improve infrastructure assets by implementing short-term funding solutions to address decades of deferred maintenance, including surface transportation funding through the Rebuilding Michigan plan and improved water infrastructure systems through the MI Clean Water Plan. The state will also benefit from recent federal infrastructure investments included in the Bipartisan Infrastructure Law (BIL), Coronavirus Aid, Relief, and Economic Security (CARES) Act, and American Rescue Plan Act (ARPA). However, Michigan generally lacks sufficient long-term funding mechanisms to ensure all infrastructure sectors reach and sustain a state of good repair. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Hail Drives Construction Spending in Amarillo

October 25, 2013 — CDJ STAFF
Amarillo had a hailstorm in May and it’s still having an effect on the construction industry there. Prior to the May 28 hailstorm, the city issued 223 permits for roofing projects, worth a total of $1.9 million. But in the four months after the hailstorm, the city issued 13,696 roofing permits worth about $151.4. During the same nine months of 2012, the total was only $6.9 million. The Amarillo Globe-News reports that there has been a slowing of residential roof work, but the commercial roofing is still going strong. Scott McDonald, an Amarillo building official told the paper that a commercial roof can exceed a million dollars. “The commercial aspect is much more complicated, and we’re just now getting started,” said Mr. McDonald. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES