Seattle Washington Building Expert Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Constructive Changes – A Primer

October 02, 2018 — Jonathan R. Mayo - Smith Currie
A “constructive change” occurs when an owner action or omission not formally acknowledged by the owner to be a change in the contact’s scope of work forces the contractor to perform additional work. Constructive changes are not formal change orders, but informal changes that could have been ordered under a contract’s changes clause if the change had been recognized by the owner. The constructive change doctrine recognizes that being informally required to do extra work is similar to a formal change order and should be governed by similar principles. Thus, if it is found that a constructive change order did occur, the contractor may be entitled to payment for additional costs incurred, and an extension to the contract performance period. Constructive changes most often arise where there is a dispute regarding contract interpretation, defective plans and specifications, acceleration or suspension of work, interference or failure to cooperate with the contractor, misrepresentation or nondisclosure of superior knowledge or technical information, over inspection, or a delay in providing requested information crucial to the contractor’s ability to continue work. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan R. Mayo, Smith Currie
Mr. Mayo may be contacted at jrmayo@smithcurrie.com

So You Want to Arbitrate? Better Make Sure Your Contract Covers All Bases

August 16, 2021 — Stephanie Nolan Deviney - ConsensusDocs
As a General Contractor, you may prefer to arbitrate any contractual disputes rather than engage in protracted litigation. Many Courts favor arbitration clauses and will enforce them if there is a sufficient reason to do so. However, there are several issues that a General Contractor should consider when including an arbitration clause in its construction agreement with its client. When an arbitration clause is not properly crafted, questions can arise as to who must arbitrate? Who decides whether to arbitrate? Who selects the arbitrator? What will the subject matter of the arbitration be? A look at a recent case in Pennsylvania highlights the need for properly crafted arbitration clauses. A Recent Case Highlights The Importance Of Arbitration Clauses In TEC Construction, LLC v. Greg Rich and Lora Rich filed in the Court of Common Pleas, Allegheny County, Pennsylvania, TEC Construction, LLC (“TEC”) and Greg and Lora Rich (the “Riches”), entered into a Construction Agreement with an arbitration clause. Specifically, the parties to the Construction Agreement, TEC and the Riches, agreed to arbitrate any disputes with the American Arbitration Association. Five subcontractors completed the work under the Construction Agreement but none of the subcontractors agreed to arbitrate. Read the court decision
Read the full story...
Reprinted courtesy of Stephanie Nolan Deviney, Fox Rothschild LLP (ConsensusDocs)
Ms. Deviney may be contacted at sdeviney@foxrothschild.com

Conspirators Bilked Homeowners in Nevada Construction Defect Claims

March 28, 2012 — CDJ STAFF

Courthouse News has a summary of the current lawsuit over a Nevada conspiracy to defraud homeowners by taking control of homeowner boards and then providing inadequate repairs. Homeowners in eight Las Vegas area communities are involved in the suit, which claims that the conspirators purchased units in the communities and then transferred fractional interests to others to allow them to run for HOA board elections. The suit claims that David Amesbury and his firm helped manipulate the elections.

Once homeowner boards were controlled by the conspirators, Nancy Quon, the construction defect attorney whose recent death appears to be by suicide, handled the litigation against homebuilders. She would settle out of court, engaging Silver Lining Construction to “do very minor and superficial repairs” to the homes. The remainder of the money was split by the conspirators. The suit also notes that the construction defect claims were “frivolous,” and?in addition to the negative publicity?caused the homes to lose at least 5% of their value.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Insurers Refuse Indemnification of Subcontractors in Construction Defect Suit

November 13, 2013 — CDJ STAFF
SMG Stone Co. Inc. and J. Colavin & Son Inc. were hired by Webcor Construction LP to install stone floor tiles at the Ritz-Carlton residences at the L.A. Live complex in Los Angeles. But the tiles began to crack even before installation was finished. The building management had all the tiles ripped out and replaced, although only 10% of the tiles were defective. The building management then claimed Webcor owed them $40 million, but settled for $8 million. $7 million of that claim was paid by Steadfast Insurance Co., with the remaining $1 million paid by Webcor. The two other insurers involved, American Home and The Insurance Company of the State of Pennsylvania, are attempting to deflect Webcor or Steadfast from making claims against them. Both insurers claim no obligation to indemnify the contractor or subcontractors as the claims do not involved “property damage,” as defined in the policy. Read the court decision
Read the full story...
Reprinted courtesy of

Construction of New U.S. Homes Declines on Plunge in South

July 23, 2014 — Victoria Stilwell – Bloomberg
Housing starts unexpectedly declined in June to a nine-month low, led by a record plunge in the South that shows the construction industry must still overcome hurdles before it can contribute more strongly to U.S. economic growth. Work began on 893,000 homes at an annualized rate, down 9.3 percent from a 985,000 pace in May that was weaker than previously estimated, according to figures from the Commerce Department issued today in Washington. Other reports showed manufacturing was gaining steam this month and fewer Americans filed claims for jobless benefits last week as consumer sentiment hovered near this year’s high. A shortage of buildable lots and experienced construction workers, higher prices and mortgage rates that have climbed from record lows mean residential real estate will struggle to help the world’s largest economy. The figures, along with a decline in building permits, corroborate Federal Reserve Chair Janet Yellen’s view that progress in the housing market has been “disappointing.” Read the court decision
Read the full story...
Reprinted courtesy of Victoria Stilwell, Bloomberg
Ms. Stilwell may be contacted at vstilwell1@bloomberg.net

Equities Favor Subrogating Insurer Over Subcontractor That Performed Defective Work

August 04, 2015 — Christopher Kendrick and Valerie A. Moore – Haight Brown & Bonesteel LLP
In Valley Crest Landscape v. Mission Pools (No. G049060, filed 6/26/15, ord. pub. 7/2/15), a California appeals court held that equities favor an insurer seeking equitable subrogation over a subcontractor that agreed to defend and indemnify claims arising out of its performance of work under the subcontract. Valley Crest contracted to build a pool at the St. Regis Hotel in Dana Point. Valley Crest subcontracted with Mission Pools to perform the work. The master contract contained an indemnity clause in favor of St. Regis, and the subcontract contained an indemnity clause in favor of Valley Crest. An intoxicated guest who was rendered quadriplegic after diving in the shallow end of the pool sued the hotel, Valley Crest, Mission and others involved in the design, construction and operation of the pool. The suit included allegations that the pool depth was improperly marked; there was inadequate warning signage; and the pool finish caused the pool to appear deeper than it was. Valley Crest tendered its defense to Mission Pools under the subcontract’s indemnity agreement. When Mission did not respond, Valley crest filed a cross-complaint for indemnity. All parties ultimately reached a settlement with the injured plaintiff, leaving Valley Crest’s cross-complaint against Mission Pools. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com; Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

L.A. Mixes Grit With Glitz in Downtown Revamp: Cities

May 13, 2014 — James Nash and Nadja Brandt – Bloomberg
Near streets so gritty they were used as the backdrop for a shootout in the next “Fast & Furious” movie, million-dollar condos and $38 racks of lamb beckon the urban pioneers of Los Angeles. The rehab of warehouses and factories in the Arts District is the latest wave in a revival transforming the core of the second-largest U.S. city. Since 2011, about $7 billion has been poured into downtown. A decade ago its most prominent residents were the homeless. Now condos sell for a median of $523.36 a square foot -- more than in Beverly Hills. Alma, Bon Appetit magazine’s best new U.S. restaurant in 2013, is a few blocks from the convention center the city plans to renovate. “All of a sudden, overnight, you have more cranes going up in downtown L.A. than any other neighborhood in Southern California, by far,” said Lew Horne, head of the regional CBRE Real Estate Group Inc. (CBG) office. Mr. Nash may be contacted at jnash24@bloomberg.net; Ms. Brandt may be contacted at nbrandt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of James Nash and Nadja Brandt, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES