Seattle Washington Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

How To Lock Disputes Out Of Your Project In Construction

July 22, 2019 — Anastasios Koutsogiannis – LetsBuild
Disputes are seen as one of the main threats for the successful completion of a project in construction. There is a plethora of factors which could lead to a construction dispute (e.g. contracts, behavior, environment) but, strangely enough, the industry seems to invest more attention on the resolution of a conflict instead of its prevention. Thanks to the progress that digital technologies have witnessed during the last few years, there is a good chance that things in construction will change for the better soon. The ability to exchange crucial updates in real time, while keeping a detailed record of everything that happens on the field adds an extra level of protection to your project and ensures that all agents are on the same page. In an effort to shed some light on the issue of construction disputes, we present below four tips that could help your team to lock conflicts out of your project: 1. Standardize your processes Before you kickstart your project, it is of paramount importance that you standardize all your systems and processes. In that way, you will be able to add extra clarity to your workflow and eliminate misunderstandings. Once you have achieved that, you can replicate the same process to your future projects. The more you manage to repeat the same project structure the better your team will become in completing their tasks without ending up in any kind of conflict. In that sense, standardization could be a long-term investment for your organization. 2. Go digital As soon as your processes are defined, it is time for the digital journey to begin. Finding the right tool for your project will result in a streamlined construction process where all the members of the team are on the same page without any room for costly mistakes or disagreements. Furthermore, with the help of digital solutions it becomes easier for project managers to measure the performance on site and monitor the completion of the set benchmarks. Like that, all payments will be on time and the program of the project will reflect reality. 3. Be extra careful with the contracts A poorly-written contract can have a big impact on the effort to lock disputes out of your construction project. While putting together a new contract, you should always make sure that you have taken into account all the different scenarios for your project. Either that is a delay due to weather conditions or an accident on site everything should be described in detail in the contracts and be well understood by those in charge. In any other case, things can get a bit risky and a costly dispute might wait to happen. 4. Hold regular meetings with all stakeholders Last but certainly not least, meet regularly with all project stakeholders. The frequent contact with the different members of your team will allow you to discuss and resolve any problematic situations before they grow out of proportion. What is more, regular meetings will help both your field teams and the people in the office to remain aligned and will eliminate the possibility of having people working on outdated versions of the program. Of course, these meetings don’t need to be time-consuming or even in person. With the help of technology, you can keep these meetings short and to the point. In that manner, everybody involved will be able to get the most out of them. Final word All in all, it becomes clear that locking disputes out of your project in construction requires continuous work and a carefully-elaborated plan. Thankfully, the emergence and progress of digital solutions have made this process much easier contributing significantly to the development of the industry far from disputes and project misunderstandings. About the author: Anastasios Koutsogiannis is Content Marketing Manager at LetsBuild. Read the court decision
Read the full story...
Reprinted courtesy of Anastasios Koutsogiannis, LetsBuild

Turner Construction Selected for Anaheim Convention Center Expansion Project

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
The Anaheim, California city council selected Turner Construction Company “to manage a $180 million expansion of the Anaheim Convention Center, a venue that hosted 238 tradeshows, conventions, meetings and consumer events in 2013,” according to Construction Digital. “Turner’s Southern California office calls Anaheim home, and we are pleased to be working on such a great project in our own backyard,” Kevin Dow, Vice President and General Manager of Turner’s Southern California office told Construction Digital. Read the court decision
Read the full story...
Reprinted courtesy of

Wendel Rosen Construction Attorneys Recognized by Super Lawyers

July 30, 2018 — Garret Murai - California Construction Law Blog
Wendel Rosen Construction Practice Group Co-Chairs, Garret Murai and Quinlan Tom, have been selected for inclusion as 2018 Northern California Super Lawyers in the area of Construction Litigation. Murai and Tom are among 26 other attorneys at the firm who were selected as either 2018 Northern California Super Lawyers or Rising Stars by Thompson Reuters. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Plehat Brings Natural Environments into Design Tools

May 01, 2019 — Aarni Heiskanen - AEC Business
Natural elements are an essential part of the built environment. However, BIM tools offer almost no support to landscape architecture. Plehat is introducing a new solution that helps architects and decision-makers to understand the dynamics of nature and make smart design choices. Plehat used photogrammetric 3D models of Uunisaari islands, to the south of Helsinki. The experimenters modeled the buildings and the plants on the island and used game engine software to create a virtual reality (VR) experience. They called the app the “Landscape Time Machine”. The technology solution they developed paved the way for new software that the company will launch later this year. In 2018, Plehat, a landscape design startup, received funding from the Finnish national KIRA-digi digitalization project to carry out a test. The experimentation demonstrated how seasonal changes and weather conditions affect plants, and how the environment can be visualized and analyzed virtually. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Congratulations to Nicholas Rodriguez on His Promotion to Partner

November 25, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is very proud to announce that Nick Rodriguez has been promoted to the position of partner with the firm! Nick has been with BWB&O since 2019 and is licensed to practice law in California and the U.S. District Courts. Nick’s practice focuses on complex construction defect matters, as well as personal injury and wrongful death claims. During his time with the firm, Nick has successfully represented numerous clients through alternative dispute resolution and has taken matters to trial where he has received favorable jury verdicts. He also supervises and manages a team of associates in the Newport Beach office. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Injured Subcontractor Employee Asserts Premise Liability Claim Against General Contractor

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
In an interesting opinion, an injured employee of an electrical subcontractor sued the general contractor of a parking garage project under a premise liability theory after being injured when stepping on an uncovered floor drain at the project site. There is no discussion in the opinion as to workers compensation immunity. Rather, the discussion centers on the injured employee’s premise liability claim as to whether the general contractor “breached its duty to maintain the premises in a reasonably safe condition by leaving the drain uncovered and failing to warn of the danger of the uncovered drain.” Pratus v. Marzucco’s Construction & Coatings, Inc., 46 Fla.L.Weekly D186a (Fla. 2d DCA 2021) The trial court granted summary judgment in favor of the general contractor finding that the drain was open and obvious on the site. The Second District Court of Appeal reversed the summary judgment with a discussion as to premise liability claims, particularly as it pertains to a business invitee, which is what the injured employee of the electrical subcontractor was. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Venue for Miller Act Payment Bond When Project is Outside of Us

December 02, 2019 — David Adelstein - Florida Construction Legal Updates
The proper venue for a Miller Act payment bond claim is “in the United States District Court for any district in which the contract was to be performed and executed, regardless of the amount in controversy.” 40 U.S.C. s. 3133(b)(3)(B). Well, there are a number of federal construction projects that take place outside of the United States. For these projects, where is the correct venue to sue a Miller Act payment bond if there is no US District Court where the project is located? A recent opinion out of the Southern District of Florida answers this question. In U.S. ex. rel. Salt Energy, LLC v. Lexon Ins. Co., 2019 WL 3842290 (S.D.Fla. 2019), a prime contractor was hired by the government to design and construct a solar power system for the US Embassy’s parking garage in Burkina Faso. The prime contractor hired a subcontractor to perform a portion of its scope of work. The subcontractor remained unpaid in excess of $500,000 and instituted a Miller Act payment bond claim against the payment bond surety in the Southern District of Florida, Miami division. The surety moved to transfer venue to the Eastern District of Virginia arguing that the Southern District of Florida was an improper venue. The court agreed and transferred venue. Why? Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES