CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Construction Litigation Roundup: “It’s None of Your Business.”

May 22, 2023 — Daniel Lund III - Lexology
“It’s none of your business.” So said a construction surety resisting discovery of its underwriting file in the context of the surety’s affirmative $2 million indemnity claim (on a $25M bond), and a Missouri federal court agreed. In response to the surety’s indemnity suit, the defaulted principal contractor and additional corporate indemnitors offered up defenses of “lack of consideration and the doctrine of unclean hands, laches, waiver and/or estoppel, among others.” The indemnitors also issued written discovery to the surety seeking to obtain the surety’s underwriting file – which would reveal the underpinnings of the surety’s decision to issue the bond to the contractor – asserting “that the underwriting and due diligence documents are relevant to the[] lack of consideration defense. [Indemnitors] claim that ‘[t]his defense is based on Defendants' belief that Plaintiff did not conduct any reasonable inquiry into any Defendants' ability to pay or financial resources and therefore Plaintiff did not rely on the financial condition of each Defendant in determining whether to issue the bonds.’" Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Condominium Association Responsibility to Resolve Construction Defect Claims

July 23, 2014 — Nicholas D. Cowie – Maryland Condo Construction Defect Law Blog
The Maryland Court of Special Appeals recently issued an opinion in Greenstein v. Council of Unit Owners of Avalon Court Six Condominium Inc. finding that an association can be sued by its unit owner members if it fails to take timely legal action against a developer. In that case, the association was aware of construction defects, but failed to take action to preserve its claim and then filed a lawsuit against the developer too late, after the statute of limitations expired. As a result, the suit against the developer was dismissed and the association was forced to assess its unit owner members for the $1 million in repair costs. Some of the unit owners then sued their association, seeking to recover the cost of their assessments on the ground that the association was negligent in failing to pursue a timely legal action against the developer. On appeal, the court was asked to decide whether state law permits owners to sue their condominium association for negligently failing to sue a developer for common element construction defects. The court, in an unpublished opinion, found that an association could be held liable to its members. The court said: “The duty to maintain, repair and replace the common elements together with the exclusive right to initiate litigation regarding the common elements [which was stated in a provision of the association’s bylaws] creates a concomitant obligation on the part of the [association] to pursue recovery from [the developer] on behalf of [the unit owners] for damage to the common elements caused by [the developer’s] negligence, breach of contract or violation of any applicable law.” Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Maryland Condo Construction Defect Law Blog
Mr. Cowie may be contacted at ndc@cowiemott.com

---

Employee Handbooks—Your First Line of Defense

April 15, 2015 — Craig Martin – Construction Contractor Advisor
This spring has been busy with questions about employee handbooks. Perhaps it is because the NLRB just issued a directive on the legality of various clauses usually contained in handbooks. Or perhaps it’s because employers, including construction companies, are realizing the importance that handbooks play in defending against claims of harassment. Employee Handbooks Are Important Employee handbooks are an employer’s first line of defense in claims of harassment. A key provision to any employee handbook is an anti-harassment provision that includes:

• A definition of harassment;
• The process to complain about harassment;
• A commitment to investigate all claims of harassment; and
• An assurance that no one will be retaliated against for reporting harassment.

Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Engineers Propose 'River' Alternative to Border Wall

May 10, 2017 — Frank K. Johnson - Engineering News-Record
Of all the ideas that have been suggested for the border wall, there is one that may help to bring together Mexico and the U.S., instead of pitting the countries against each another over illegal immigration. I’m part of a group of civil engineers in Massachusetts that has conceived of a program that is based on a recently acquired patent for an advanced concrete construction technology for building large-scale, monolithic concrete structures capable of physically partitioning two countries while serving to promote economic development. This fast and thrifty construction method and our proposed program prove that, as far as creativity is concerned, civil engineering isn’t dead yet. Read the court decision
Read the full story...
Reprinted courtesy of Frank K. Johnson, ENR
ENR may be contacted at ENR.com@bnpmedia.com

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

ASCE Statement on House Passage of the Water Resources Development Act of 2024

August 05, 2024 — Marsia Geldert-Murphey, P.E., President of the American Society of Civil Engineers
WASHINGTON — The American Society of Civil Engineers (ASCE) commends the House of Representatives for passing H.R. 8812, the bipartisan Water Resources Development Act (WRDA) for 2024. The House WRDA 2024 bill will help improve America's ports and inland waterways, enhance flood risk management and storm risk reduction programs, and prioritize ecosystem restoration. While we urge the Senate to swiftly vote on its version of WRDA, we are encouraged that our nation's critical water resources infrastructure remains a congressional priority. The House version of WRDA includes several key provisions to enhance the safety of America's dams and levees, which each received a 'D' on the 2021 Report Card for America's Infrastructure, as well as provisions to modernize the nation's inland waterways system, which received a 'D+' in the 2021 Report Card. This includes one of ASCE's top legislative priorities for this year, the reauthorization of the National Dam Safety Program through 2028. But beyond the reauthorization, this bill reduces restrictions on the amount of funds states can receive in National Dam Safety Program State Assistance Grants; improves access to the High Hazard Potential Dam Rehabilitation Grant Program; and requires the incorporation of low-head dams into the National Inventory of Dams. Each of these provisions are critical to ensuring the long-term safety of our nation's dams and ASCE applauds the House for their inclusion. Furthermore, ASCE was pleased to see that the House legislation extends the National Levee Safety Program through 2033, which will help support the establishment of state levee safety programs, develop and publish national guidelines for levee safety, and enhance flood protection nationwide. While these measures are not included in the Senate version of WRDA, we encourage lawmakers to ensure they are included in a final conference version of the bill. We thank the House of Representatives for moving forward WRDA 2024 and strongly encourage the Senate to pass its version so that Congress can keep this vital water resources legislation on a biennial schedule and ensure our nation's dams, levees, ports, and inland waterways can support the American economy and protect public safety. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 160,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

---

Insurance Measures Passed by 2015 Hawaii Legislature

June 10, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The 2015 Hawaii legislative session passed three insurance-related bills which have all been signed by the governor. Bills that have been enacted are the following: SB0589 - We previously devoted this post to the legislation. The bill provides relief for residents in lava zones on the Big Island. The bill limits the number of property policies that an insurer can refuse to renew in a lava zone. Further, a moratorium on the issuance of policies can be lifted in a state of emergency due to the threat of imminent disaster from a lava flow. SB0736 - Provisions relating to reimbursement for accident and health or sickness insurance benefits are amended. Further, the bill provides that prior to initiating any recoupment or offset demand efforts, an entity must send a written notice to the health care provider at least 30 days prior to engaging in recoupment or offset efforts. An entity may not initiate recoupment or offset efforts more than 18 months after the initial claim payment was received by the health care provider or health care entity. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Following Pennsylvania Trend, Federal Court Finds No Coverage For Construction Defect

December 08, 2016 — Tred R. Eyerly – Insurance Law Hawaii
Bound by Pennsylvania law, the federal district court found there was no coverage for defects in the installation of a roof. State Farm Fire & Cas. Co. v. Kim's Asia Constr., 2016 U.S. Dist. LEXIS 138915 (E.D. Pa. Oct. 5, 2016). Kim's Asia Construction contracted to remove and dispose of Powerline Imports, Inc.'s roof, and then install a new roof. After completion of the project, Powerline sued, alleging that Kim's Asia's negligent construction of the roof caused the roof to leak, even in minor rain storms. Kim's Asia made additional repairs, but the leaks continued. Powerline had to hire a new contractor to remove and dispose of the roof and install another roof. Powerline then sued Kim's Asia. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---